Fairfield Connecticut Building Expert Directory

Experts Weigh In on Bilingual Best Practices for Jobsites

February 22, 2018 — Jim Parsons – ENR
It’s the rare construction firm that doesn’t cite people as its most important resource. And over the past two decades, that asset has become increasingly bilingual. Indeed, more than 27% of workers in construction are Hispanic or of Latino ethnicity, according to the most recent available data from the U.S. Bureau of Labor Statistics (BLS). Read the court decision
Read the full story...
Reprinted courtesy of Jim Parsons, Engineering News-Record

Construction Worker Dies after Building Collapse

November 18, 2011 — CDJ STAFF

A Bronx construction worker died when the pillars gave way in the basement where he was working. The two-story commercial building collapsed, burying Mr. Kebbeh under about six feet of rubble. The New York Times reports that firefighters dug him out with their bare hands. Mr. Kebbeh was taken to Jacobi Medical Center where he died. Two other construction workers escaped unharmed.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

BWBO Celebrating Attorney Award and Two New Partners

July 14, 2016 — Beverley BevenFlorez-CDJ STAFF
Congratulations is due to Nicole Whyte of Bremer Whyte Brown & O’Meara LLP (BWBO) for being recognized as one of America’s Top 100 Attorneys by America’s Top 100, which identifies the top 100 attorneys in each state. In an email release, the firm stated, “We are pleased to celebrate this lifetime achievement and it is an honor to have Ms. Whyte listed alongside her esteemed peers.” Furthermore, BWBO announced that two of their attorneys have been promoted to partner: Alex Giannetto and Benjamin Price. “Mr. Giannetto believes that hard work, dedication, caring about clients and work product, and surrounding himself with good people, has helped him become successful in his profession,” as stated in an email release. “To be successful you have to surround yourself with successful people,” Mr. Price stated. “A combination of humility, confidence, and hard work is also important.” Read the court decision
Read the full story...
Reprinted courtesy of

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

Builders Seek to Modify Scaffold Law

June 28, 2013 — CDJ STAFF
New York’s scaffold law dates back to 1885 and requires contractors and building owners to take measures to protect worker from falls through “proper protection.” And although the law is more than 125 years old, Lou Colettie of the Building Trades Employers Association clams that the law “is going to destroy the construction industry.” On the other side, a former director of the NYC Central Labor Council says that builders want to get rid of the law because of “greed.” The New York Daily News notes that when workers using scaffolds or ladders are injured, the contractor must prove the site was safe. According to the claims of the building industry, this would let workers get settlements if their injuries were their own fault, such as working while intoxicated or failing to observe their employer’s safety procedures. A bill is currently working its way through the New York legislature that would make the employee’s actions relevant in an injury lawsuit. There have been past unsuccessful attempts to repeal the law, this year opponents are pushing to just amend it. Read the court decision
Read the full story...
Reprinted courtesy of

Forethought Is Key to Overcoming Construction Calamities

February 10, 2020 — Mitch Cohen - Construction Executive
Without warning, an under-construction structure in the southern United States suffered a catastrophic collapse. The tragedy resulted in the death of several people. As a result, engineering and construction post-collapse forensics experts engaged in an 18-month investigation. Those involved in the design and build project included the general contractor hired by the owner, a prime engineer, a consulting peer-review engineer and a prime structural design firm supported by a sub-consulting structural engineer. Although significant cracking was noticed several weeks before the failure, no one sounded the alarm or deemed the cracking worthy of corrective action. In their findings, forensic experts found the collapse resulted from the combined failure of the general contractor, engineers and even the owner, who all failed to shut down the work once the cracking reached unacceptable levels and/or take the appropriate actions needed to secure the public safety and mitigate the risk. This was even after the general contractor requested that the engineer-of-record and design manager assess the structure’s extreme cracking. Consequently, the choice to not seriously investigate the crack or seek an independent peer review to design a rectification plan contributed directly to the tragedy. This is typically referred to within the industry as a “negligent professional design error.” Reprinted courtesy of Mitch Cohen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Cohen may be contacted at mitch.cohen@rtspecialty.com

From the Ashes: Reconstructing After the Maui Wildfire

November 27, 2023 — Grace Calengor - Construction Executive
On Tuesday, Aug. 8, a wildfire on the Hawaiian island of Maui ravaged the town of Lahaina, killing nearly 100 people and stranding thousands of survivors, many of whom remain displaced today. The loss of life makes this the deadliest American wildfire on record, while the material cost in property damage has been estimated at upwards of $5 billion. The response to the disaster has involved firefighters and other emergency personnel—and also engineering and construction professionals. One of them is Tam Kim, director of operations for West Maui Construction Inc., a civil contractor on the island. Originally from Oregon, Kim fell in love with Hawaii when he visited on a surfing vacation; eventually he took his technology background and helped found a startup company on Maui in 2008. Eight years later, the startup relocated to Oahu, but Kim stayed on Maui to forge a different path, one that would lead him somewhere he never imagined. Reprinted courtesy of Grace Calengor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Law Client Alert: Hirer Beware - When Exercising Control Over a Job Site’s Safety Conditions, You May be Held Directly Liable for an Independent Contractor’s Injury

April 06, 2011 — Mark VonderHaar and Yvette Davis

On February 24, 2011, the California Court of Appeal held in Jeffrey Tverberg, et al v. Fillner Construction, Inc. that the imposition of direct liability on a hirer turns on whether the hirer exercised retained control of worksite safety in such a manner that affirmatively contributed to the independent contractor’s injury. Twice, Tverberg, an independent contractor hired by a general contractor's subcontractor, asked the general contractor to make the job site safe by covering up open holes created by another unrelated subcontractor while Tverberg was working at the site. After Tverberg was injured at the site by falling in a hole, he sued both the general contractor and the subcontractor which had hired him.

The Court of Appeal reasoned that when the general contractor instructed another subcontractor to create a condition that was potentially dangerous (i.e., creating open and uncovered bollard holes), and simultaneously required Tverberg to perform unrelated work near the open holes, the general contractor s conduct may have constituted a negligent exercise of its retained control which affirmatively contributed to Tverberg’s injury. The Court also reasoned that the general contractor affirmatively assumed responsibility for the safety of the workers near the holes by only requiring stakes and safety ribbon, and negligently discharged that responsibility which resulted in injury.

Read the full story...

Reprinted courtesy of Mark VonderHaar and Yvette Davis of Haight Brown & Bonesteel. Mr. VonderHaar can be contacted at mvonderhaar@hbblaw.com and Ms. Davis at ydavis@hbblaw.com.