Not So Fast, My Friend: Pacing and Concurrent Delay
April 25, 2022 —
William E. Underwood - ConsensusDocsWhen critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays.
Pacing versus Concurrent Delay
As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief.
Read the court decisionRead the full story...Reprinted courtesy of
William E. Underwood, Jones Walker LLP (ConsensusDocs)Mr. Underwood may be contacted at
wunderwood@joneswalker.com
Edward Beitz and William Taylor Recognized by US News – Best Lawyers as a "Lawyer of the Year"
August 31, 2020 —
Edward Beitz & William Taylor - White and WilliamsWhite and Williams is proud to announce that Edward Beitz and William Taylor have been recognized by U.S. News – Best Lawyers® as a “Lawyer of the Year” in their respective practices in Philadelphia. Ed was named in the area of Medical Malpractice and Bill was named in Construction Law. "Lawyer of the Year" recognitions are awarded to individual lawyers with extremely high overall peer-feedback for a specific practice area and geographic location.
Ed is a member of the Healthcare Group and focuses his practice on medical malpractice defense, defending doctors, nurses, physician assistants and hospitals at the trial and appellate court levels, as well as general liability matters. He has successfully defended numerous medical malpractice cases at trial involving complex issues of the human anatomy, such as cardiac surgery, neurosurgery, orthopedic surgery, nursing care, obstetrical complications, nerve injury and vascular injury. Ed has authored briefs on appellate issues in healthcare and coverage matters to the Superior Court of Pennsylvania, the New Jersey Appellate Division and the Third Circuit Court of Appeals.
Reprinted courtesy of
Edward Beitz, White and Williams and
William Taylor, White and Williams
Mr. Beitz may be contacted at beitze@whiteandwilliams.com
Mr. Taylor may be contacted at taylorw@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Flag on the Play! Expired Contractor’s License!
October 02, 2015 —
Yas Omidi – California Construction Law BlogIt’s football season again. Which means, of course, that in addition to touch downs and field goals, you’ll also see hooting and hollering when the ref throws down a yellow flag signaling that a foul has been committed.
In Judicial Council of California v. Jacob Facilities, Inc., Case Nos. A140890, A141393 (August 20, 2015), The California Court of Appeals for the First District threw down its own yellow flag under the dreaded Business and Professions Code section 7031, finding that a contractor was required to disgorge all monies received on a project – to the tune of a whopping $18 million – when its parent company allowed the subsidiary’s contractor’s license to lapse when it rebranded a new company to perform the work of the old company but never formally assigned the contract. I think someone in marketing may be in big trouble.
Read the court decisionRead the full story...Reprinted courtesy of
Yasmeen, Omidi, Wendel Rosen Black & Dean LLPMs. Omidi may be contacted at
yomidi@wendel.com
Construction Litigation Roundup: “Apparently, It’s Not Always Who You Know”
December 16, 2023 —
Daniel Lund III - LexologyA respondent party in a pair of international arbitrations on the losing end of roughly $285,000,000 in adverse awards attacked the awards based upon arbitrator bias.
“If there is one bedrock rule in the law of arbitration, it is that a federal court can vacate an arbitral award only in exceptional circumstances. … The presumption against vacatur applies with even greater force when a federal court reviews an award rendered during an international arbitration.”
Applying the Federal Arbitration Act (according to the court, the international arbitrations were “seated” in the United States and fell under the New York Convention, such that the FAA is required to be the basis for vacatur efforts), the court examined assertions that certain alleged non-disclosures by the panel “concealed information related to the arbitrators’ possible biases and thereby ‘deprived [respondent] of [its] fundamental right to a fair and consensual dispute resolution process.’” The aggrieved party urged that one arbitrator’s undisclosed nomination of another arbitrator to serve as president of another arbitral panel – “a position that sometimes pays hundreds of thousands of dollars” – possibly influenced the second arbitrator to side with the first. Assertions were also levied that the arbitrators’ undisclosed work with the attorneys for the claimant in other arbitrations “allowed them to become familiar with each other, creating a potential conflict of interest.”
Read the court decisionRead the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
New OSHA Fall Rules to Start Early in Minnesota
June 14, 2011 —
CDJ STAFFMinnesota has elected to implement the new OSHA rules concerning fall prevention in residential construction on June 20, well before OSHA’s September 15 deadline. Brian Johnson, reporting in Finance and Commerce, quotes Pam Perri, the executive vice president of the Builders Association of Minnesota, “this is the worst time to implement a new rule.” Ms. Perri notes “In Minnesota, education time for the residential construction industry is between November and March 1, not in the middle of the construction season.”
Mike Swanson of Rottlund Homes estimated that the new regulations would add between $200 to $500 to the cost of a house and that he felt the current safety regulations were adequate. OSHA officials are quoted that there continues “to be a high number of fall-related deaths in construction.”
Read the fully story…
Read the court decisionRead the full story...Reprinted courtesy of
Hurdles with Triggering a Subcontractor Performance Bond
April 05, 2017 —
David Adelstein – Florida Construction Legal UpdatesThere have been a couple of decisions as of late, particularly in federal court, that have gone in favor of a performance bond surety and against a general contractor’s claim against a subcontractor’s performance bond. These decisions have been so unfavorable that they may be swaying certain internal decisions to move to subcontractor default insurance with, perhaps, subcontractors that pose less risk. From the general contractor’s perspective, if they have to stop the management of the job and progress to jump through hoops to trigger the performance bond’s obligations, rightfully or wrongfully, the bond may not provide them the value they need. Performance bonds are an appropriate product in many instances, but there should be more consistency regarding the actual trigger of a subcontractor’s performance bond obligations. Project teams need to absolutely understand what efforts they need to take, and how they need to take such efforts, in order to properly trigger a performance bond’s obligations. This is a must (and I have presented many seminars on this very issue). Or, the general contractor should move away from the traditional AIA /standard performance bond form, which is the direction I always go when I am involved in the drafting of a performance bond.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
The Secret to an OSHA Inspection
December 02, 2015 —
Craig Martin – Construction Contractor AdvisorWouldn’t it be nice to know ahead of time what an OSHA inspector will be looking for when he comes to your work site? Well, I know the secret. And, it’s not really a secret. Just look at OSHA’s top ten citation standards and it becomes quite clear.
In 2015, OSHA’s top ten most frequently cited violations are:
1. Fall protection (C)
2. Hazard communication
3. Scaffolding (C)
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
BOOK CLUB SERIES: Everything You Want to Know About Construction Arbitration But Were Afraid to Ask
October 30, 2023 —
Marissa L. Downs - The Dispute ResolverI recently had the pleasure of speaking with construction law notables John Foust and Andy Ness to discuss the release of their new book—
Construction Arbitration: The Advocate’s Practical Guide. The goal of their book: to teach attorneys what they need to know to maximize their effectiveness in the arbitration context. To that end, the book covers every aspect of the arbitration process including motion practice, conduct as an advocate, presentation of the case, and post-hearing submissions. Read on for Andy and John’s candid, behind-the-scenes take on how this book came to be and why you should get your copy now, while supplies last!
Q: Who is the target audience for this book?
Andy: In the editing process (and in writing my own chapter on Navigating an International Construction Arbitration) I pretended that I was speaking with a construction lawyer who was a few years out of law school, with some litigation experience, who was getting ready to take on a significant and complex construction arbitration for the first time. The book presupposes knowledge of the basics and tries to anticipate the questions that would be asked when you are trying to think through the whole arbitration process from start to finish. What should my pleadings look like? How much discovery am I likely to be able to obtain? How should my demeanor be different from what I would do in a courtroom? How much should I object during the hearing? In a nutshell, it’s “What do I need to know to maximize my chances of success in the arbitration setting?”
Read the court decisionRead the full story...Reprinted courtesy of
Marissa L. Downs, Laurie & Brennan, LLPMs. Downs may be contacted at
mdowns@lauriebrennan.com