Seattle Washington Building Expert Directory

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Requirement to State a “Sum Certain” No Longer a Jurisdictional Bar to Government Contract Claims

November 13, 2023 — Marcos R. Gonzalez - ConsensusDocs
The Boards of Contract Appeals, Court of Federal Claims, and the Federal Circuit have long held that the elements of a claim under the Contract Disputes Act (“CDA”) to be jurisdictional. Those requirements are as follows: (a) Claims generally.– (1) Submission of contractor’s claims to contracting officer.–Each claim by a contractor against the Federal Government relating to a contract shall be submitted to the contracting officer for a decision. (2) Contractor’s claims in writing.—Each claim by a contractor against the Federal Government relating to a contract shall be in writing. (3) Contracting officer to decide Federal Government’s claims.–Each claim by the Federal Government against a contractor relating to a contract shall be the subject of a written decision by the contracting officer. Read the court decision
Read the full story...
Reprinted courtesy of Marcos R. Gonzalez, Peckar & Abramson, P.C.
Mr. Gonzalez may be contacted at mgonzalez@pecklaw.com

Professional Liability and Attorney-Client Privilege Bulletin: Intra-Law Firm Communications

January 07, 2015 — David W. Evans & Stephen J. Squillario – Haight Brown & Bonesteel LLP
Attorney-Client Privilege Protects Confidential Communications Between Law Firm Attorney Representing Current Client and Firm’s General Counsel Regarding Disputes with Client Who Later Files Malpractice Suit In a case of first impression in California, Edwards Wildman Palmer LLP v. Superior Court (No. B255182 - filed November 25, 2014), Division Three of the Second District Court of Appeal addressed the question of whether the attorney-client privilege applies to intrafirm communications between law firm attorneys concerning disputes with a current client, when that client later sues the firm for malpractice and seeks to compel production of such communications. The court concluded that when an attorney representing a current client seeks legal advice from the law firm’s designated in-house “general counsel” concerning disputes with the client, the attorney-client privilege applies to their confidential communications. The court held that adoption of the so-called “fiduciary” or “current client” exceptions to the attorney-client privilege is contrary to California law because California courts are precluded from creating implied exceptions to the statutorily created attorney-client privilege. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Stephen J. Squillario, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com; Mr. Squillario may be contacted at ssquillario@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Road Project to Improve Access to Peru's Machu Picchu Site

June 04, 2024 — C.J. Schexnayder - Engineering News-Record
Reaching the Incan citadel of Machu Picchu is historically famous for its difficulty. The site’s remote location was a factor in the Spanish conquistadors overlooking it as they swept Peru for its riches. Archaeologist and politician Hiram Bingham had been seeking another “lost” Incan city when he happened across it in 1911. Reprinted courtesy of C.J. Schexnayder, Engineering News-Record Mr. Schexnayder may be contacted at schexnayderc@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

No Coverage for Faulty Workmanship Based Upon Exclusion for Contractual Assumption of Liability

August 06, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Supreme Court for West Virginia determined the policy's contractual assumption exclusion barred coverage for the general contractor based upon claims of faulty workmanship. J.A. St & Assocs. v. Bitco Gen. Ins. Corp., 2019 W. Va. LEXIS 205 (May 1, 2019). J.A. Street & Associates, Inc. entered a contract with the developer, Thundering Herd Development, L.L.C., to build a commercial shopping center on seventy-eight acres of land. Street agreed to oversee the site preparation for the development and the construction of many of the buildings. Thundering Herd retained an engineering firm, S&ME, Inc. to do geotechnical exploration and to provide advice regarding land preparation for the shopping center. Thundering Heard also entered an agreement with the Target Corporation to construct a store on a pad to be prepared at the shopping center. Street hired subcontractors to prepare the site by grading the land and installing fill material. A slope was constructed at the rear of the proposed Target site, but it failed, causing a landslide, damage to the pad, and damage to adjacent property owned by a third party. Thundering Heard incurred $721,875 in additional costs to repair this slope, reconstruct the Target site, and compensate the neighbor for the damage to the adjacent property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

How One Squirrel Taught us a Surprising Amount about Insurance Investigation Lessons Learned from the Iowa Supreme Court

April 03, 2019 — Graham C. Mills - Newmeyer & Dillion
A recent decision issued by the Iowa Supreme Court, City of West Liberty, Iowa v. Employers Mutual Casualty Company, highlights the importance for a policyholder to investigate a loss fully so that a wide range of evidence can be gathered and presented to show why there is coverage. The facts of City of West Liberty are a little unusual, but its lesson is not limited to Iowa insurance law; the issues litigated in this case show the value of investigating what caused a loss regardless of whether the loss occurred in California, Iowa, or elsewhere. Background on the Case City of West Liberty involved an insurance coverage dispute between a municipality owned electrical power plant and its insurance company. The dispute arose from a single adventurous squirrel who climbed onto an outdoor electrical transformer, touching two different parts of the power plant: a portion of the steel frame and a bare cable clamp. In doing so, the squirrel created a “conductive path,” in the words of the Iowa Supreme Court, between the high voltage clamp and the grounded frame. The path, once created, caused significant damage to the transformer and other electrical equipment at the city’s power plant. The city submitted a claim for the resulting damage, but the insurance company denied it. The insurer denied based on an exclusion in the insurance policy for property damage “caused by arcing or by electrical currents other than lightning.” According to the insurance company, the squirrel had no role in causing the damage; all of the damage resulted from arcing, which was excluded from coverage. The ensuing lawsuit focused upon whether the squirrel had a role in causing the damage. If yes, then there would be coverage according to Iowa insurance law; when a loss results from two causes, one of which is covered and the other is not, then there is coverage if the loss occurs from the covered cause. Due to this legal standard, the city contended that, apart from the arcing causing any damage, the squirrel caused the damage too. Because the insurance policy provided protection against mischievous actions performed by squirrels, the city contended that it was entitled to coverage, even if the excluded arcing contributed to the same damage too. Unfortunately, for the city, the Iowa Supreme Court rejected that argument, finding instead that the property damage resulted only from the arcing, which was excluded from coverage. In reaching its conclusion, the court absolved the squirrel of any wrongdoing, finding that it did not cause any of the property damage. Read the court decision
Read the full story...
Reprinted courtesy of Graham C. Mills, Newmeyer & Dillion
Mr. Mills may be contacted at graham.mills@ndlf.com

Mid-Session Overview of Colorado’s 2017 Construction Defect Legislation

March 16, 2017 — David McClain - Colorado Construction Litigation
As the 2017 Colorado legislative session reaches the halfway point, I thought it an opportune time to provide a quick overview of the construction defect bills introduced so far this session. Senate Bill 17-045, “Concerning a Requirement for Equitable Allocation of the Costs of Defending a Construction Defect Claim,” sponsored by Senators Grantham and Angela Williams and Representatives Duran and Wist, was introduced on January 11th and assigned to the Senate Business, Labor, and Technology Committee. This bill affects construction defect actions in which more than one insurer has a duty to defend a party by providing that if the carriers cannot agree regarding how to allocate defense costs within 45 days of the filing of a contribution action, a court must conduct a hearing regarding the apportionment of the costs of defense, including reasonable attorneys’ fees, among all carriers sharing in the duty to defend within 60 days after an insurer files its claim for contribution, unless the carriers agree to resolve the issue through a mutually agreeable, alternative process. The bill further provides that the court must make a final apportionment of costs after entry of a final judgment resolving all of the underlying claims against the insured. The bill also makes clear that an insurer seeking contribution may also make a claim against an insured or additional insured who chose not to procure liability insurance during any period of time relevant to the underlying action. Finally, the bill states that a claim for contribution may be assigned and that bringing such a claim does not affect any insurer’s duty to defend. The Senate Business, Labor, and Technology Committee heard SB 17-045 on February 8th and referred the bill, as amended, to the Senate Appropriations Committee. Read the court decision
Read the full story...
Reprinted courtesy of David M. McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

WA Supreme Court Allows Property Owner to Sue Engineering Firm for Lost Profits

February 25, 2014 — Beverley BevenFlorez-CDJ STAFF
In the Daily Journal of Commerce, Scott A. Smith and James H. Wendell discussed the recent Washington Supreme Court decision in Donatelli v D. R. Strong Consulting Engineers. The court’s ruling casts “doubt on a company's ability to limit its liability for economic losses arising out of a contract dispute.” The Donatellis hired D. R. Strong Consulting Engineers to develop vacant land in King County, however, the “project did not go according to plan and the real estate market collapsed before the project was completed,” according to the Daily Journal of Commerce. The “Donatellis lost their property through foreclosure” and then “sued the engineering firm for more than $1.5 million in lost profits.” D. R. Strong Consulting Engineers asked for the negligence claims to be dismissed “because the parties' contract contained a provision limiting the engineering firm's liability to the amount of its fee for ‘any injury or loss on account of any error, omission, or other professional negligence.’” However, the Washington Supreme Court ruled that “the case could proceed in the trial court on a theory that the engineers could be liable if they made negligent misrepresentations that induced the Donatellis to enter into the contract in the first place.” Smith and Wendell stated that because of “this decision, engineering, architectural, construction, and other professional service companies may now face damage claims they thought they were contractually protected against.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES