Fairfield Connecticut Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Fourth Circuit Holds that a Municipal Stormwater Management Assessment is a Fee and Not a Prohibited Railroad Tax

April 22, 2019 — Anthony B. Cavender - Gravel2Gavel
On February 15, the U.S. Court of Appeals for the Fourth Circuit decided Norfolk Southern Railway Co. v. City of Roanoke, et al.; the Chesapeake Bay Foundation was an Intervenor-Defendant. The Fourth Circuit held that a large stormwater management fee (stated to be $417,000.00 for the year 2017) levied by the City of Roanoke against the railroad to assist in the financing of the City’s permitted municipal stormwater management system was a permissible fee and not a discriminatory tax placed on the railroad. The Railroad Revitalization and Regulatory Reform Act of 1976 specifically provides that states and localities may not impose any tax that discriminates against a rail carrier, 49 U.S.C. § 11501. Accordingly, the issue confronting the Fourth Circuit was whether the assessment was fee and not a tax. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Pentagon Has Big Budget for Construction in Colorado

January 17, 2013 — CDJ STAFF
The Pentagon is an important source of construction contracts, and one place where they’re acutely aware of this in Colorado Springs, Colorado. Luckily for the town’s economy, the military awarded $400 million in construction contracts to Colorado, many of them in the town of Colorado Springs. Projects in Colorado Springs include facilities for a helicopter unit at Fort Carson and renovations at the Air Force Academy. The new operation center for defense intelligence at Buckley Air Force Base will be built in nearby Aurora. The price tag on the operations center is $117 million. Meanwhile, the military has thousands of both civilian and military employees who will be using these facilities. Read the court decision
Read the full story...
Reprinted courtesy of

New Jersey Judge Found Mortgage Lender Liable When Borrower Couldn’t Pay

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the New Jersey Law Journal, Freedom Mortgage Corporation has to pay treble damages and legal fees after Bergen County Superior Court Judge Gerald Escala found the company “liable under New Jersey’s Consumer Fraud Act for providing a home refinance loan to a 70-year-old borrower it should have known would be unable to make the payments.” “Escala further ruled that Freedom Mortgage must hold off on obtaining a foreclosure judgment for a year to allow an opportunity for borrower Mamie Major to look for someone to buy the property or to obtain refinancing elsewhere,” the New Jersey Law Journal reported. Read the court decision
Read the full story...
Reprinted courtesy of

No Duty to Defend Construction Defect Claims under Kentucky Law

March 25, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court determined that the insurer was not obligated to defend construction defect claims under Kentucky law. Westfield Ins. Co. v. Kentuckiana Commercial Concrete, LLC, 2023 U.S. Dist. LEXIS 222674 (W.D. Ky. Dec. 14, 2023). HRB, the owner of an apartment complex, filed an arbitration demand against the general contractor, Doster Commercial Construction, for allegedly doing faulty concrete work in the construction of the apartments. Doster added its concrete subcontrator Kentuckiana Commercial Concrete - and 16 other subcontractors - to the arbitration. Kentuckiana tendered the claim to its insurer, Westfield. Wesfield defended. Doster claimed it was an additional insured under the Westfield policy and also sought coverage. Westfield refused the defend Doster. Westfield argued there was no "occurrence." Westfield then sued both Doster and Kentuckiana in federal court, seeking a declaration that it had no duty to defend either. Westfield moved for a judgment on the pleadings. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Caterpillar Forecast Tops Estimates as Construction Recovers

January 28, 2014 — Shruti Date Singh – Bloomberg
Caterpillar Inc. (CAT), the largest maker of mining and construction equipment, forecast earnings and revenue for 2014 that topped analysts’ estimates as the recovery in the U.S. building industry spurs sales of bulldozers and excavators. Sales will be about $56 billion plus or minus 5 percent, the company said in a statement today. The average of 13 estimates compiled by Bloomberg was $55.5 billion. Profit will be $5.85 a share excluding $400 million to $500 million in restructuring costs. That’s more than the $5.77 average estimate. Peoria, Illinois-based Caterpillar also said it approved a $10 billion share buyback plan through 2018 and will repurchase about $1.7 billion in stock in the first quarter that will complete its previous authorization. Read the court decision
Read the full story...
Reprinted courtesy of Shruti Date Singh, Bloomberg
Ms. Singh may be contacted at ssingh28@bloomberg.net

Pennsylvania Supreme Court Dismisses Appeal of Attorney Fee Award Under the Contractor and Subcontractor Payment Act

February 16, 2016 — William J. Taylor – White and Williams LLP
In late December, the Supreme Court of Pennsylvania dismissed, as improvidently granted, the appeal in Waller Corporation v. Warren Plaza, Inc., No. 6 WAP 2015 (December 21, 2015). As a result, the Superior Court’s holding in that case that there is no good faith exception to the attorney fee provision of the Pennsylvania Contractor and Subcontractor Payment Act (CASPA), 73 P.S. §§ 501-516, remains intact. In its decision in Waller, 95 A.3d 313 (Pa. Super. 2014), the Superior Court considered if there was a “good faith” exception to the interest and penalties provision of CASPA, 73 P.S. § 512(a), and whether there was a similar good faith exception to the attorney fee provision of the statute, 73 P.S. § 512(b). The court held that while an award of interest and penalties under § 512(a) could be denied if a party had a good faith basis for withholding payments due under a construction contract, no such exception exists for an award of attorney fees under § 512(b). Rather, an award of attorney fees is appropriate for the “substantially prevailing party” under a CASPA claim, and a claimant can be the substantially prevailing party even if the other party withheld payments in good faith. Read the court decision
Read the full story...
Reprinted courtesy of William J. Taylor, White and Williams LLP
Mr. Taylor may be contacted at taylorw@whiteandwilliams.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES