Fairfield Connecticut Building Expert Directory

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

California Court of Appeals Says, “We Like Eich(leay)!”

March 30, 2016 — Garret Murai – California Construction Law Blog
Time is money. And nowhere can than be best observed than on a construction project. Project delays can mean lost profits for owners, liquidated damages for general contractors, and increased material, labor, field overhead, and home office overhead costs for general contractors and subcontractors alike. Pricing the impact of delays, however, can be thorny. Particularly, for home office overhead. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Coyness is Nice. Just Not When Seeking a Default Judgment

March 04, 2019 — Garret Murai - California Construction Law Blog
As Morrissey of the Smith’s sang: Coyness is nice, but Coyness can stop you, from saying all the things in life you’d like to. It’s not uncommon in litigation to see a complaint asking for “damages according to proof.” Call it laziness. Call it hiding the ball. Call it coy, even. I call it risky. And here’s why: If a defendant doesn’t appear and you need to seek a default judgment against him, her, or it, you are barred from doing so, since you are limited to recovering the amount you sought. And last I checked, something of nothing is nothing. In Yu v. Liberty Surplus Insurance Corporation, California Court of Appeals for the Fourth District, Case No. G054522 (December 11, 2018), one plaintiff found this out the hard way, although perhaps not quite in the way they expected it. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen
Mr. Murai may be contacted at gmurai@wendel.com

Workarounds for Workers' Comp Immunity: How to Obtain Additional Insured Coverage when the Named Insured is Immune from Suit

May 25, 2020 — Bethany L. Barrese - Saxe Doernberger & Vita, P.C.
Construction is an inherently risky business, fraught with the potential for human error. Despite best efforts to ensure safety, accidents involving construction workers are common, with consequences ranging from your run-of-the-mill trip and fall to much more serious and debilitating injuries. A worker who is injured on the job generally receives workers’ compensation benefits through their employer. Most states have enacted statutes stating that this is the exclusive remedy available from the employer, effectively making employers immune against civil lawsuits that might otherwise be brought by their injured employees. However, workers’ compensation benefits do not always fully compensate the employee for their injuries. In the construction industry, this often leads to lawsuits against upstream parties, such as a general contractor or project owner. Read the court decision
Read the full story...
Reprinted courtesy of Bethany L. Barrese, Saxe Doernberger & Vita, P.C.
Ms. Barrese may be contacted at blb@sdvlaw.com

North Carolina Learns More Lessons From Latest Storm

October 16, 2018 — Pam Radtke Russell - Engineering News-Record
There’s no big wall planned to protect North Carolina’s coast from storm surge. There’s no massive tunnel system proposed to keep floodwaters away from populated areas. There are no grant-funded resilience competitions to help the state plan to manage water more effectively. Read the court decision
Read the full story...
Reprinted courtesy of Pam Radtke Russell, ENR
Ms. Russell may be contacted at Russellp@bnpmedia.com

Overview of New Mexico Construction Law

June 25, 2019 — Walter F. Crowson - Snell & Wilmer Under Construction Blog
We’ve seen an uptick in out-of-state companies working on construction projects in New Mexico. The following is an overview of some of the nuances of New Mexico construction law about which companies may want to be aware. Construction Contract Issues Limitation of Liability Clauses are usually Enforceable, but Anti-Indemnity Clauses Are Not New Mexico courts have enforced limitation of liability clauses included in construction contracts. See Fort Knox Self Storage, Inc. v. W. Techs., Inc., 140 N.M. 233, 237 (N.M. Ct. App 2006). New Mexico law recognizes the difference between contracts that insulate a party from any and all liability and those that simply limit liability. Fort Knox Self Storage, Inc., 140 N.M. 233 at 237. An exculpatory clause immunizes a party from liability, whereas a limitation of liability clause merely curtails liability. Id. A limitation of liability clause has been held not to violate New Mexico public policy because the party “still bears substantial responsibility for its actions.” Id.; see also Cowan v. D'Angelico, 2010 WL 11493789, *6 (D. N.M. Apr. 26, 2010). Read the court decision
Read the full story...
Reprinted courtesy of Walker F. Crowson, Snell & Wilmer
Mr. Crowson may be contacted at wcrowson@swlaw.com

Key Amendments to Insurance Claims-Handling Regulations in Puerto Rico

September 23, 2019 — Andres Avila & Richard W. Brown - SDV Insights
Policyholders in Puerto Rico should be aware of significant benefits provided by recent amendments to the Insurance Code. New rules establish an expedited method of property insurance dispute resolution, mandatory expedited partial payments in the event of catastrophic events, and protection against bad faith claims handling by insurers. Appraisal Process with a Puerto Rican Twist A key amendment is the establishment of an appraisal process, widely used for many years in the United States and now adopted in Puerto Rico. Commercial and personal property insurers in Puerto Rico shall include, in their policies, a clause for an appraisal process according to Article 11.150 of the Insurance Code of Puerto Rico, 26 L.P.R.A. § 101 et seq. (“the Code”). The appraisal process provides both policyholders and insurers the option to submit insurance claims to an impartial umpire if a dispute arises over the value of covered damages or losses. The umpire and appraisers do not have authority to resolve coverage or legal issues. They can only resolve disputes over the quantum claimed for losses already determined to be covered by the insurer. Id. Each party is required to pay its own appraiser’s fees and split equally the fees of the umpire. Id. Reprinted courtesy of Andres Avila, Saxe Doernberger & Vita, P.C. and Richard W. Brown, Saxe Doernberger & Vita, P.C. Mr. Avila may be contacted at ara@sdvlaw.com Mr. Brown may be contacted at rwb@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Three L’s of Real Estate Have New, Urgent Meaning

April 15, 2024 — Mark Gongloff - Bloomberg
What will it take to make Americans stop rushing headlong into climate peril? Cheaper housing in safer places, for one thing. But maybe big red flags on property listings will help, too. Redfin Corp., the digital real estate company, last week added air-quality data to its listings as part of its “climate risks” feature, which aims to warn homebuyers of the chances their dream home could succumb to a global-warming nightmare. Using data from the climate research firm First Street Foundation, Redfin estimates a property’s current and predicted risk levels for flooding, wildfires, extreme heat, high winds — and now days when the Environmental Protection Agency’s Air Quality Index tops 100, a category known as “unhealthy for sensitive groups.” Read the court decision
Read the full story...
Reprinted courtesy of Mark Gongloff, Bloomberg

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES