Fairfield Connecticut Building Expert Directory

The National Labor Relations Board Joint Employer Standard is Vacated by the Eastern District of Texas

April 22, 2024 — Andrew G. Vicknair - The Dispute Resolver
Many employment laws use the concept of joint employer to make more than one business entity responsible for complying with employment law obligations towards employees who to varying degrees work for, or under the direction of entities who are not technically the employees primary employer. Nowhere is that issue more prevalent than in contractor subcontractor relationships. Over the years the National Labor Relations Board (NLRB) has developed various tests for determining joint employer status. Unless a business entity is an employer of individuals, the NLRB has no jurisdiction over a dispute between the workers and a business entity for whom they work. It is important for contractors to understand the importance of being an employer and the obligations that flow from such status. Likewise, it is also important to understand when a contractor may be classified as a “joint employer” over certain individuals. Depending on the specific laws involved, such a finding of joint-employer status can happen under the “joint employer doctrine” which often exists in subcontractor and temporary employment arrangements. The “joint-employer doctrine” may render a contractor responsible for another company’s employment liabilities. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Anticipatory Repudiation of a Contract — The Prospective Breach

July 05, 2021 — David Adelstein - Florida Construction Legal Updates
There are instances where a party can engage in the anticipatory repudiation of their obligations under a contract. In essence, this is basically a party prospectively breaching the contract by repudiating their obligations in the contract. A prospective breach of contract occurs where there is absolute repudiation by one of the parties prior to the time when his performance is due under the terms of the contract. Such a repudiation may be evidenced by words or voluntary acts but the refusal must be distinct, unequivocal, and absolute. Moreover, repudiation can be shown where one party makes additional demands not included in the initial agreement:

The law is clear that where one party to the contract arbitrarily demands performance not required by the contract and couples this demand with a refusal to further perform unless the demand is met, the party has anticipatorily repudiated the contract, which anticipatory repudiation relieves the non-breaching party of its duty to further perform and creates in it an immediate cause of action for breach of contract. 24 Hr Air Service, Inc. v. Hosanna Community Baptist Church, Inc., 46 Fla. L. Weekly, D1344a (Fla. 3d DCA 2021) (quotations and citations omitted).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

White and Williams Earns Tier 1 Rankings from U.S. News "Best Law Firms" 2017

November 03, 2016 — White and Williams LLP
White and Williams received one National Tier 1 ranking and four Metropolitan Tier 1 rankings in U.S. News - Best Lawyers® "Best Law Firms" for 2017. Firms included in the “Best Law Firms” list are recognized for professional excellence with persistently impressive ratings from clients and peers. Achieving a tiered ranking signals a unique combination of quality law practice and breadth of legal experience. National Tier 1 Insurance Law Metropolitan Tier 1 Boston Insurance Law Product Liability Litigation - Defendants Philadelphia Real Estate Law Tax Law Metropolitan Tier 2 Boston Mergers and Acquisitions Law Philadelphia Construction Law Insurance Law Tax and Estates Law Metropolitan Tier 3 Boston Employment Law - Management Labor Law - Management Litigation - Labor and Employment Philadelphia Patent Law Read the court decision
Read the full story...
Reprinted courtesy of

Supreme Court Declines to Address CDC Eviction Moratorium

August 04, 2021 — Zachary Kessler, Amanda G. Halter & Adam Weaver - Gravel2Gavel Construction & Real Estate Law Blog
In a closely watched 5-4 decision, the U.S. Supreme Court sided against the challengers to the eviction moratorium issued by the Centers for Disease Control and Prevention (CDC), keeping a stay in place that leaves the eviction ban in effect through July 31. The CDC has indicated it will not renew the eviction moratorium when it expires at the end of the month. The CDC’s eviction moratorium was first adopted at the expiration of the CARES Act’s limited eviction protection for federally funded rental properties. The more broadly applicable order, extended under both the Trump and Biden administrations, prohibited landlords from evicting tenants unable to pay due to the financial impacts of the COVID-19 pandemic, when the tenant confirmed in writing that they had done their best to make any partial payment, were at risk of becoming homeless or having to move into unsafe group housing, and earn below a set income limit. The CDC extended the order most recently on June 24. In announcing that one-month extension, CDC director Dr. Rochelle Walensky indicated that it would be the order’s final extension. Reprinted courtesy of Zachary Kessler, Pillsbury, Amanda G. Halter, Pillsbury and Adam Weaver, Pillsbury Mr. Kessler may be contacted at zachary.kessler@pillsburylaw.com Ms. Halter may be contacted at amanda.halter@pillsburylaw.com Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

It’s Too Late, Lloyd’s: New York Federal Court Finds Insurer Waived Late Notice Defense

June 05, 2023 — Latosha M. Ellis & Janine A. Hanrahan - Hunton Insurance Recovery Blog
A New York federal judge recently ruled that an insurer waived its late notice defense because a generic reservation of rights was insufficient to preserve it. As a result, the policyholder’s claim was preserved despite being submitted more than three months after the loss—a delay which would ordinarily be fatal under New York law. The decision underscores the importance both of timely submission of claims and careful attention to reservation of rights letters. Background Mave Hotel Investors LLC (“Mave”) owns a small hotel in Manhattan that was insured by Certain Underwriters at Lloyd’s, London (“Lloyd’s”). From October 2017 to October 2020, Mave contracted with a housing network to temporarily house homeless families and their children in the hotel. When the contract with the housing network terminated in October 2020, Mave alleged that the rooms were severely damaged and that it had to pay $1.4 million to repair them. Reprinted courtesy of Latosha M. Ellis, Hunton Andrews Kurth and Janine A. Hanrahan, Hunton Andrews Kurth Ms. Ellis may be contacted at lellis@HuntonAK.com Ms. Hanrahan may be contacted at jhanrahan@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

De-escalating The Impact of Price Escalation

August 10, 2021 — Brian C. Padove - ConsensusDocs
What happens when construction material prices abruptly rise by 15%, 35%, 50%? Moreover, what happens to a construction project when such volatility occurs? While there is no definite answer, delays in procuring such materials and associated cost overruns will likely impact the construction project. The last 15 months contractors have had to work through extraordinary construction material price increases, such as a 90% price increase for lumber from April 2020 to April 2021. While there is no statistic quantifying the impact these increases have had on the construction industry, the increases surely have had an influence, whether it has been through lost profits, delays, or damage to contractors’ otherwise strong reputation for timely performance. Considerations Prior To Contract Execution The first way to mitigate price escalation is identifying materials most susceptible to price volatility during the bidding process and then having an open discussion with upstream parties regarding the potential price volatility. Additionally, the bid may also include either (1) an allowance for the materials providing additional funds, if necessary, should the material price increase, or (2) a shortened timeframe in which the bid is open, which would lessen the time in which a price shift may occur. Read the court decision
Read the full story...
Reprinted courtesy of Brian C. Padove, Watt, Tieder, Hoffar & Fitzgerald, LLP
Mr. Padove may be contacted at bpadove@watttieder.com

New Jersey Supreme Court Rules that Subcontractor Work with Resultant Damage is both an “Occurrence” and “Property Damage” under a Standard Form CGL Policy

September 01, 2016 — Beverley BevenFlorez-CDJ STAFF
According to a client alert by the firm Peckar & Abramson, P.C. (P&A), “In a recent significant decision, the Supreme Court of New Jersey held that defective work of a subcontractor that causes consequential property damage is both an ‘occurrence’ and ‘property damage’ under the terms of a standard form commercial general liability (“CGL”) insurance policy.” Patrick J. Greene, Jr., and Frank A. Hess of P&A wrote that the Cypress Point Condominium Assoc., Inc. v Adria Towers, LLC, 2016 N.J. Lexis 847 (Aug.4,2016) “decision is important in New Jersey and in other jurisdictions that had relied upon the influential New Jersey case, Weedo v. Stone–E–Brick, Inc., 81 N.J. 233 (1979), that had determined that such claims involved non-insured ‘business risks.’” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES