Seattle Washington Building Expert Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

What Makes Building Ventilation Good Enough to Withstand a Pandemic?

January 11, 2021 — Linda Poon - Bloomberg
In October, students at the University of Illinois, Urbana-Champaign, held an intimate jazz concert at a bar downtown, with an audience of about 20 peers and faculty members — all of whom held digital passes indicating they’d recently tested negative for Covid-19. Two jazz ensembles performed, sometimes with masks and coverings for their instruments, and other times without. Behind the scenes, mechanical engineering professor Ty Newell tinkered with the airflow, turning the exhaust and recirculation fans on and off at different points during the night. His students monitored for changes in the air quality, using a special instrument to measure the concentrations of carbon dioxide and fine particulate matter, both key to determining if a building is well ventilated. The experiment sought to highlight the significance of proper ventilation, something that Newell said hadn’t been paid enough attention, until now. As evidence suggesting Covid-19 can spread through aerosol transmission continues to mount, health experts are focused less on sanitizing surfaces and more on improving indoor air quality. In December, the U.S. Centers for Disease Control and Prevention finally put out its ventilation recommendations to combat Covid-19, based on standards set by ASHRAE, or the American Society of Heating, Refrigerating and Air-Conditioning Engineers. Read the court decision
Read the full story...
Reprinted courtesy of Linda Poon, Bloomberg

Milhouse Engineering and Construction, Inc. Named 2022 A/E/C Building a Better World Award Winner

September 12, 2022 — Milhouse Engineering and Construction, Inc.
CHICAGO, IL, Sept. 07, 2022 (GLOBE NEWSWIRE) -- PSMJ has awarded Milhouse Engineering and Construction, Inc. (Milhouse) their 2022 Building a Better World award. This recognition is given to a firm in the Architecture, Engineering, and Construction industries that significantly and positively impacts the communities they serve. This highly regarded award is chosen by a panel of industry visionaries and leaders based on the impact and nature of the activities completed by the organization. "Firms nominated for an A/E/C Building a Better World Award come in all sizes, from less than 10 architects to over 10,000 civil engineers. What they share is a realization that giving time and resources to those less fortunate is the right thing to do. And more and more, the most sought-after candidates for open positions are judging firms on their level of corporate social responsibility," says Frank A. Stasiowski, FAIA, Founder and CEO of PSMJ Resources, Inc. In 2012, Milhouse established Milhouse Charities, the 501c3 non-profit arm of the Milhouse family of companies. Milhouse Charities supports the Milhouse vision "to be a positive impact" by supporting the education, exposure and advancement of underrepresented youth and minorities in science, technology, engineering and math (STEM). Since its founding in 2012, Milhouse Charities has invested over $1 Million and 7,000 hours of community service into STEM, resource, and mentorship programs. The organization has made a global impact having done service in Illinois, Indiana, Pennsylvania, New York, Atlanta, and throughout Africa. About Milhouse Engineering and Construction, Inc. Milhouse Engineering and Construction, Inc. is a full-service engineering firm offering expertise in civil, mechanical, electrical, structural and environmental engineering, as well as construction and program management. We deliver creative solutions to complex problems around the globe. Driven by our diverse perspectives, we challenge the status quo to pursue a brighter future for the communities we serve. Milhouse has been named a 'Best & Brightest Companies to Work For' for 17 years in a row and is ranked as an 'ENR Top 500 Design Firm'. Follow us on LinkedIn and Facebook. Read the court decision
Read the full story...
Reprinted courtesy of

Make Prudent Decisions regarding your Hurricane Irma Property Damage Claims

September 14, 2017 — David Adelstein - Florida Construction Legal Updates
Hurricane Irma barreled down on us with all of her forceful winds and torrential rains. She was scary and relentless. There was mass evacuation. Commercial flights were booked. Trains were booked. There was gridlock with the concern as to whether gas would even be available. There were many people that did not evacuate, uncertain as to the eventual path Irma would take. Originally projecting an easterly course, people on the east coast evacuated to the west coast, central Florida or out-of-state. She then shifted to a westerly course forcing people on the west coast to evacuate to the east coast, central Florida, or out-of-state. It was chaos stemming from the total unpredictability of Mother Nature. It was chaos stemming from the dreadful images of Hurricane Harvey. Mother Nature and all of her uncertainty is undoubtedly frightening, as proven by her devastation throughout the amazing state of Florida. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Allegations That COVID-19 Was Physically Present and Altered Property are Sufficient to Sustain COVID-19 Business Interruption Suit

May 24, 2021 — Michael S. Levine & Joseph T. Niczky - Hunton Insurance Recovery Blog
On Wednesday, a federal judge in Texas denied Factory Mutual’s Rule 12(c) motion for judgment on the pleadings, finding that the plaintiffs adequately alleged that the presence of COVID-19 on their property caused covered physical loss or damage in the case of Cinemark Holdings, Inc. v. Factory Mutual Insurance Co., No. 4:21-CV-00011 (E.D. Tex. May 5, 2021). This is the third COVID-19-related business interruption decision from Judge Amos Mazzant since March, but the first in favor of a policyholder. Taken together, the three decisions have two key takeaways and provide a roadmap for policyholders in all jurisdictions. First, the Cinemark decision recognizes that the alleged presence of COVID-19 viral particles that physically altered the policyholder’s property is sufficient under federal pleading standards and controlling state law. In its motion, FM relied on Judge Mazzant’s recent decision in Selery Fulfillment, Inc. v. Colony Insurance Co., No. 4:20-CV-853, 2021 WL 963742 (E.D. Tex. Mar. 15, 2021), which dismissed a lawsuit alleging that the policyholder’s losses were caused by government orders that closed its business, rather than from the actual presence of the virus on its property. The Court held that government orders alone do not constitute physical loss or damage, and declined to rule on whether the physical presence of the virus does. Judge Mazzant reached the same conclusion weeks later in Aggie Investments, L.L.C. v. Continental Casualty Co., No. 4:21-CV-0013, 2021 WL 1550479 (E.D. Tex. Apr. 20, 2021). Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Joseph T. Niczky, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Niczky may be contacted at jniczky@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Florida Adopts Daubert Standard for Expert Testimony

October 07, 2019 — Michael L. DeBona - The Subrogation Strategist
Seven months ago, the Florida Supreme Court declined to adopt Daubert as the standard for admitting expert testimony in Florida state courts. In DeLisle v. Crane Co., 258 So. 3d 1219 (2018), the court reaffirmed that “Frye, not Daubert, is the appropriate test in Florida.” On May 23, 2019, however, Florida’s high court did an about-face. In In Re: Amendment to the Florida Evidence Code, No. SC19-107, the Florida Supreme Court overruled its decision in DeLisle and declared that Florida will now apply the Daubert standard to determine whether scientific evidence is admissible. The Daubert standard comes from the case of Daubert v. Merrell Dow Pharm., Inc., 509 U.S. 579 (1993), which held that the longstanding Frye test[1] for admitting expert testimony was superseded by Rule 702 of the Federal Rules of Evidence. Daubert instructed that federal judges should act as “gatekeepers” to ensure expert testimony is rooted in scientifically valid principles and that those principles are properly applied to the facts at issue. In determining whether scientific evidence should be admitted, Daubert sets forth several factors to consider: the testability of the theory or technique; the peer review and publication of the theory or technique; the error rate for the technique; the standards controlling the technique’s operation; and the general acceptance of the theory or technique.[2] The Daubert standard is generally considered a more onerous test than Frye, precluding expert testimony that might otherwise go to the jury under Frye.[3] Whereas Frye is a single factor test that applies only to new or novel science, Daubert is a multifactor test that applies to all expert testimony. Since Daubert, a growing number of states have moved away from the Frye test in favor of the Daubert standard; it is now followed by a majority of jurisdictions in the country. In 2013, the Florida State legislature attempted to move Florida in this direction by amending the Florida Evidence Code to codify the Daubert standard. But because the Florida Supreme Court is vested with the power to make procedural rules and it was unclear whether the Daubert standard was a procedural or substantive rule, it was uncertain whether the 2013 Daubert amendments were controlling law. Then in 2017, in In Re: Amendment to the Florida Evidence Code, No. SC16-181, the Florida Supreme Court expressly declined adopting the Daubert amendments to the extent they were procedural. This decision signaled that, if faced with the Daubert standard on appeal from a litigated case, the Florida Supreme Court would reaffirm that Frye – not Daubert – controlled the admissibility of expert testimony in Florida state courts. Read the court decision
Read the full story...
Reprinted courtesy of Michael L. DeBona, White and Williams LLP
Mr. DeBona may be contacted at debonam@whiteandwilliams.com

Colorado Introduces Construction Defect Bill for Commuter Communities

January 23, 2013 — CDJ STAFF
A Colorado State Senator has introduced a bill suggesting a change to the way that construction defect claims are handled in "transit-oriented developments." And what are these? According to the bill these are "any multi-family residential or mixed-use project within one-half mile of any commuter rail stop, commuter light rail stop, or commuter bus stop." So the bill would treat homes with good public transportation differently from those not so convenient to public transportation. The bill, SB 52, would institute a right to repair for construction defects in these developments. Construction defect claims would be referred to binding arbitration. Further, construction professionals could not be sued for environmental conditions related to transit, commercial, public, or retail use. Read the court decision
Read the full story...
Reprinted courtesy of

He's the Top U.S. Mortgage Salesman. His Daughter Isn't Buying It

July 16, 2014 — Lorraine Woellert – Bloomberg
David Stevens, chief executive officer of the Mortgage Bankers Association, has spent his career lauding the merits of homeownership. One person still isn’t buying it: his daughter. Sara Stevens, 27, knows interest rates are low, rents are high and owning a home can build wealth. She also had a front-row seat to the worst real-estate slump since the Great Depression. “The world has changed,” she said. Six years since the collapse of Lehman Brothers triggered a financial meltdown, some young adults are more risk averse and view the potential upsides of status and wealth more skeptically than before the crisis, altering the homeownership calculation. It’s more than the weight of student loans, an iffy job market and tight credit -- even those who can buy are hesitant. Read the court decision
Read the full story...
Reprinted courtesy of Lorraine Woellert, Bloomberg
Ms. Woellert may be contacted at lwoellert@bloomberg.net

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES