Fairfield Connecticut Building Expert Directory

Construction Costs Must Be Reasonable

May 17, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to proving a construction cost, particularly a cost in dispute, the cost must be REASONABLE. Costs subject to claims must be reasonably incurred and the party incurring the costs must show the costs are reasonable. An example of the burden falling on the contractor to prove the reasonableness of costs is found in government contracting. “[T]here is no presumption that a [government] contractor is entitled to reimbursement ‘simply because it incurred…costs.’” Kellogg Brown & Root Services, Inc. v. Secretary of Army, 973 F.3d 1366, 1371 (Fed. Cir. 2020) (citation omitted). Stated differently, a federal contractor is not entitled to a presumption of reasonableness just because it incurs costs. Id. In government contracting, the Federal Acquisition Regulations (known as “FAR”) puts the burden of reasonableness on the contractor that incurred the costs. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Constructive Suspension (Suspension Outside of an Express Order)

December 13, 2022 — David Adelstein - Florida Construction Legal Updates
In the federal procurement arena, there is a concept known as “constructive suspension.” Constructive suspension, while known in the federal arena, should reasonably apply to all projects when work is stopped outside of an express order to stop the work based on the law below. An unreasonable suspension is an unreasonable suspension and an express order to stop the work does not negate the effects of what really amounts to a suspension. “Constructive suspension occurs when work is stopped absent an express order by the contracting officer and the government is found to be responsible for the work stoppage.” P.R. Burke Corp. v. U.S., 277 F.3d 1346, 1359 (Fed. Cir. 2002). The government delay must be unreasonable to support a constructive acceleration claim. Id. “To demonstrate such a constructive suspension of work, the contractor must show that the delay (1) was for an ‘unreasonable length of time,’ (2) was proximately caused by the government’s actions, and (3) resulted in some injury to the contractor.” Fireman’s Fund Ins. Co. v. U.S., 2001 WL 36415627, *6 (Fed.Cl. 2001) (citation omitted). “Relative to proving that the delay was directly caused by the government, the contractor must concomitantly show that it was not delayed by any concurrent cause that would have independently generated the delay during the same time period even if it does not predominate over the government’s action as the cause of the delay.” Beauchamp Const. Co. v. U.S., 14 Cl.Ct. 430, 437 (Cl.Ct. 1988). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Residential Building Sector: Peaking or Soaring?

October 01, 2013 — CDJ STAFF
Forbes notes that residential builders and remodelers are one of the fastest-growing groups of privately held companies, but is that growth going to continue? Tim McPeak, an analyst at Sageworks, said, “aside from the strong sales growth, these companies have a relatively healthy 4.6% net profit margin.” Another analyst, Scott Cresswell of The Bonadio Group, said that his “clients who do multifamily are exponentially off the charts with new work. Cresswell also noted that firms in the Northeast are also experiences labor shortages, particularly with wood-frame construction, since, “there are not a lot of carpenters out there.” As a result of the new construction, some workers are more money from overtime. A further hike in interest rates may stop this growth. Mr. McPeak noted that “the expectation of everyone is we’re going to see rates rise.” Read the court decision
Read the full story...
Reprinted courtesy of

Statutory Bad Faith and an Insured’s 60 Day Notice to Cure

April 11, 2018 — David Adelstein - Florida Construction Legal Updates
A recent case came out in favor of an insured and against a first-party property insurer in the triggering of a statutory bad faith action. Florida’s Fifth District Court of Appeal in Demase v. State Farm Florida Insurance Company, 43 Fla. L. Weekly D679a (Fla. 5th DCA 2018) held that if an insurer pays a claim after the 60-day notice to cure period provided by Florida Statute s. 624.155(3), this “constitutes a determination of an insurer’s liability for coverage and extent of damages under section 624.155(1)(b) even when there is no underlying action.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

In Colorado, Repair Vendors Can Bring First-Party Bad Faith Actions For Amounts Owed From an Insurer

December 20, 2012 — BRADY IANDIORIO, HIGGINS, HOPKINS, MCLAIN & ROSWELL
With the aftermath of Sandy still being felt up and down the Eastern seaboard, the question of many victims turns to how they can rebuild their lives and homes. One of the first things many people do is call on their insurance carriers to help rebuild whatever damaged property they have. In a recent case here in Colorado, those rebuilding efforts got reaffirmed by a Court of Appeals case, Kyle W. Larson Enterprises, Inc., Roofing Experts, d/b/a The Roofing Experts v. Allstate Insurance Company, --- P.3d ----, 2012 WL 4459112 (Colo. App. September 27, 2012). The facts of the case are pretty straightforward and could describe many repair vendors in numerous situations. Roofing Experts contracted with four homeowners insured by Allstate to repair their damaged roofs. The contracts provided that repair costs would be paid from insurance proceeds. The contracts also allowed Roofing Experts full authority to communicate with Allstate regarding all aspects of the insurance claims. Before work began, Roofing Experts met with adjusters from Allstate to discuss the four homes and the amount of each claim. After receiving approval for the claims, Roofing Experts began the repairs. During construction, Roofing Experts discovered additional repairs were necessary to maintain certain manufacturer’s warranties and to conform to applicable building codes. Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandorio, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Iandorio can be contacted at iandiorio@hhmrlaw.com

Kiewit Selected for Rebuild of Collapsed Baltimore Bridge

September 02, 2024 — Jim Parsons - Engineering News-Record
Kiewit Infrastructure Co. has been tapped to rebuild Baltimore’s I-695/Francis Scott Key Bridge under a progressive design-build procurement announced Aug. 29 by the Maryland Transportation Authority (MDTA). Work on the expected four-year reconstruction effort is scheduled to begin next year. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Former Mayor Arrested for Violating Stop Work Order

October 30, 2013 — CDJ STAFF
The former mayor of Springfield, Florida has been arrested on charges of insurance fraud. More than a year ago, an investigator for the Bureau of Workers’ Compensation found that an employee of Walker’s construction company was working without workers’ compensation and issued a stop work order. Walker’s employees continued work. The charges were delayed because Walker challenged the stop work order. Once it was determined that the stop work order was issued properly, Walker was charged with a third-degree felony. Read the court decision
Read the full story...
Reprinted courtesy of

New York Condominium Association Files Construction Defect Suit

December 10, 2015 — Beverley BevenFlorez-CDJ STAFF
According to The Real Deal, “The condominium association at 15 Union Square West has filed a $5 million lawsuit against developer Brack Capital Real Estate eight years after the building first launched sales, alleging that the firm did not deliver the quality of units it promised when residents originally signed their contracts.” Alleged problems include roof leaks, lack of terrace landscaping, and patchy electrical work, The Real Deal reported. A spokesperson for Brack stated, “We stand behind our product and are very proud of it.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES