Fairfield Connecticut Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Homebuilders Leading U.S. Consumer Stocks: EcoPulse

February 14, 2014 — Anna-Louise Jackson and Anthony Feld – Bloomberg
Shares of U.S. homebuilders are leading consumer discretionary stocks as the new home market is poised to rebound faster than other cyclical purchases this year. The Standard & Poor’s Supercomposite Homebuilding Index -- made up of Toll Brothers Inc. (TOL), NVR Inc. and nine others -- has risen 20 percent since Nov. 11. The S&P 500 GICS Consumer Discretionary Sector Index -- which includes Lennar Corp. (LEN), PulteGroup Inc. (PHM), D.R. Horton Inc. and 81 other companies such as Home Depot Inc. and Lowe’s Cos. -- is up 1.9 percent during the same period. This follows about 10 months when homebuilders lagged behind by 45 percentage points. Shares of companies that construct new residences are a source of relative strength in what’s proven to be a “more difficult market” this year, as the S&P 500 slid almost 6 percent in less than three weeks, said Michael Shaoul, chairman and chief executive officer of Marketfield Asset Management LLC in New York, which has more than $20 billion in assets. The recent rally in homebuilders suggests “a very important transition of leadership within the consumer discretionary sector” is underway, benefiting this segment of the broader cyclical group, he said. Ms. Jackson may be contacted at ajackson36@bloomberg.net; Mr. Feld may be contacted at afeld2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Anna-Louise Jackson and Anthony Feld, Bloomberg

Difficulty in Defending Rental Supplier’s Claim Under Credit Application

October 11, 2021 — David Adelstein - Florida Construction Legal Updates
In construction, one of the easiest claims to prove from a burden of proof standpoint is that of a supplier, particularly a rental equipment supplier. Oftentimes, these claims are more in the realm of a collection claim because a rental supplier will generally be able to establish that a party opened an account with them, signed a credit application and personal guaranty, and equipment was rented and even delivered to a specific jobsite during set dates. Defending these claims is not so easy. And even if there is a defense as it relates to some amounts, there needs to be an upside challenging those amounts when factoring in the attorney’s fees, costs, and interest on the other amounts and on continuing the dispute. An example of the difficulty in defending these claims from rental suppliers can be found in the recent case of Custom Design Expo, Inc. v. Synergy Rents, Inc., 2021 WL 4125806 (Fla. 2d DCA 2021). Here, a contractor rented equipment (e.g, forklifts) from a supplier. The equipment was rented on an open account and the contractor signed a personal guaranty. The supplier sued the contractor for about $81,000 that remained unpaid. The supplier appeared to waste no time and moved for summary judgment with an affidavit from its credit manager. The credit manager affirmed that the contractor executed a credit application for purposes of renting equipment on an open account, the application contained a personal guaranty, and the credit application formed the basis of a contract. The credit manager authenticated the credit application and affirmed that the contractor owed it about $81,000 in unpaid amounts for rental equipment that was furnished under the credit application. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Biden's Next 100 Days: Major Impacts Expected for the Construction Industry

May 10, 2021 — Tom Ichniowski, Pam Radtke Russell & Bruce Buckley - Engineering News-Record
As President Joe Biden’s busy first 100 days in office—which included enactment of a $1.9-trillion pandemic rescue bill and proposals for two other massive measures—wrap up, the months ahead also are expected to generate plenty of legislative and regulatory action with major impact for the construction sector. Reprinted courtesy of Tom Ichniowski, ENR, Pam Radtke Russell, ENR and Bruce Buckley, ENR Mr. Ichniowski may be contacted at ichniowskit@enr.com Ms. Russell may be contacted at Russellp@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Litigation Roundup: “I Never Had a Chance”

May 29, 2023 — Daniel Lund III - Lexology
“I never had a chance.” Such was the plea of a general contractor to a Maryland federal court after having been terminated for failure to perform. “The Agreement provides no express right to cure,” found the court, weighing in on the contractor’s wrongful termination claim. Indeed, the contract was also very clear on termination, allowing for termination for cause on numerous bases, including a common catchall: if the contractor “persistently fails to perform the provisions of this Agreement.” In advance of the actual date of termination, the owner wrote to the contractor, in accordance with the contract: “Notice is also given that seven days from the date of this correspondence, [owner] will exercise its [termination] rights under Section 13.2.2.2 of the Contract." The communication from the owner contained no discussion of allowing the contractor an opportunity to cure its alleged default. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

New Window Insulation Introduced to U.S. Market

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Construction Digital, Nitto has introduced PENJEREX, “a new transparent energy-saving window insulation film to the US Market” that may “satisfy the requirement for enhanced energy efficiency and CO2 reduction in the housing industry.” The film is transparent, while still providing insulation, which helps maintain “the natural look of the home,” reported Construction Digital. The product “is said to improve insulation by reducing heat transfer by 35 percent.” Read the court decision
Read the full story...
Reprinted courtesy of

The Results are in, CEO/Founding Partner Nicole Whyte is Elected to OCBA’s 2024 Board of Directors!

October 09, 2023 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is excited to share that CEO/Founding Partner Nicole Whyte has been elected to the Orange County Bar Associations (“OCBA”) slate of four open Board of Directors for a three-year term beginning January 2024, alongside Casey Johnson (Aitken Aitken Cohn LLP), William O’Neill (Ross, Wolcott, Teinert & Prout LLP), and Lesley Young (Orange County District Attorney’s Office). “It is one of the greatest honors of my career to have been elected to the OCBA board of directors. Thank you to all those who supported me; I will work tirelessly as your representative to serve our bar and community. I am especially excited to work alongside President Elect Christina Zabat-Fran and the other esteemed members of the board. I look forward to applying my skills and knowledge to serve our legal community as we work to promote excellence, integrity and honor in our profession, and to improve the practice for all.” – Nicole Whyte Nicole is honored to have the opportunity to continue her support with the OC legal community. For over two decades, she has served on various OCBA legal committees and boards. Nicole currently serves on the board of OCBA Master’s Division and is the 2023 Board President of the Public Law Center, the largest pro-bono law firm in Orange County. She is also a current board member of the Sonenshine Pro Bono Committee. Nicole is a founding fellow of the OC Bar Foundation and served as secretary for the Robert Banyard Inn of Court for eight years. Nicole plans to call upon her experience serving on various boards, and her many years of law practice and management experience, to help identify and support the needs of the OCBA and its thriving and diverse OC legal community. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

Safeguarding the U.S. Construction Industry from Unfair Competition Abroad

November 07, 2022 — Ric Macchiaroli - Gravel2Gavel Construction & Real Estate Law Blog
In April 2015, the U.S. International Trade Commission (ITC) issued an exclusion order prohibiting the importation of certain foreign-made crawler cranes into the United States for a period of at least 10 years. That order was the result of a 20-month investigation by the ITC, initiated by a Wisconsin-based crane manufacturer based on allegations of patent infringement and trade secret misappropriation by a China-based company. Defined by powerful injunctive remedies, unique rules, and a lightning-fast docket, the ITC can help protect American industry from unfair acts in the importation of articles into the United States. This post explores the traits that make the ITC an attractive venue for potential complainants. ITC Site Plan The ITC is a specialized trade court located in Washington, D.C., that has broad authority to investigate and remedy unfair trade practices. One of the ITC’s primary functions is to conduct unfair import investigations, also known as “section 337” investigations, after the authorizing statute. A section 337 investigation can be instituted based on any number of unfair acts, including, but not limited to, patent infringement (utility and design), registered and common law trademark infringement, copyright infringement (including violations of the Digital Millennium Copyright Act), trade dress infringement, and trade secret misappropriation. Business torts such as passing off, false advertising, and tortious interference with business relations have also formed the bases of investigations. Read the court decision
Read the full story...
Reprinted courtesy of Ric Macchiaroli, Pillsbury
Mr. Macchiaroli may be contacted at ric.macchiaroli@pillsburylaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES