Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?
September 26, 2022 —
David Adelstein - Florida Construction Legal UpdatesIs the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question.
Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair.
For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
"Decay" Found Ambiguous in Collapse Case
August 31, 2020 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court granted, in part, the insured's motion for summary judgment seeking coverage for a collapse of a church's ceiling. Derbyshire Baptist Church v. Church Mut. Ins. Co., 2020 U.S. Distl LEXIS 113346 (E.D. Va. June 29, 2020).
A large portion of the sanctuary ceiling of the insured's church collapsed. A claim was filed with the insurer. The insurer hired a forensic engineer who found the collapse was caused by the disconnection of wire support hangers from the wood roof beams. Further, "the redistribution of load on the hangers resulted in a progressive failure of the hangers and their supported components." Based on these findings, the insurer denied coverage.
The policy excluded coverage for collapse, but in the Additional Coverage portion of the policy, collapse caused by "decay that is hidden from view" was covered. The court pondered the meaning of "decay," which was not defined in the policy.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Despite Increased Presence in Construction, Women Lack Size-Appropriate PPE
September 26, 2022 —
Robin Marth - Construction ExecutiveFit. Functionality. Comfort. These are absolute musts for any employee wearing personal protective equipment (PPE) for work. Yet for many women in the workplace, finding PPE that fits well remains a challenge.
In 2021, women comprised 11% of construction workers, 7.9% of truck drivers and 29% of manufacturing employees (Bureau of Labor Statistics), and their numbers in these fields continue to increase. Unfortunately, their options for proper-fitting PPE are not growing.
"It's difficult to find PPE that fits women, because there is limited availability of these products, or suppliers do not offer them at all," says Brandy Bossle, owner and principal consultant at Triangle Safety Consulting LLC. "We really need suppliers to go out of their way to offer PPE that's cut for both men and women."
Private fleet driver and Women in Trucking Image Team member Carol Nixon agrees, saying, "You can find men's hats, gloves, jackets and safety vests everywhere, but not with a female fit."
Women can be shaped differently from head to toe—their faces, shoulders, waists, fingers and toes are often narrower, and they often have shorter torsos, among other differences.
In order for PPE to fit many women comfortably and properly, these proportions need to be taken into account. In fact, OSHA states on its website that PPE used by women should be based on female body measurement data and that employers should offer PPE in sizes suitable for women.
Reprinted courtesy of
Robin Marth, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Ms. Marth may be contacted at
media@jjkeller.com
New York Court Permits Asbestos Claimants to Proceed Against Insurers with Buyout Agreements
December 06, 2021 —
Patricia B. Santelle & Frank J. Perch, III - White and Williams LLPA recent New York federal district court decision addresses a number of issues in the context of asbestos coverage involving an insolvent insured, holding that policy buyout agreements between the insured and its insurers did not bar actions by certain tort judgment creditors against some of the settling insurers, and further finding that such agreements can constitute fraudulent conveyances, especially where the proceeds of the settlement are not reserved for payment of insured claims.
In the litigation pending in the Western District of New York (Mineweaser v. One Beacon Insurance Company, et al., No. 14-CV-0585A), certain asbestos plaintiffs sought recovery from excess insurers for judgments obtained against an insolvent asbestos supplier (Hedman Resources, formerly known as Hedman Mines), which ceased operations in 2007 due to insolvency. Hedman had at one time been a subsidiary of Gulf & Western. As of 2009-2011, the excess insurers of Gulf & Western were advised of exhaustion of primary insurance as well as Hedman’s insolvency.
Reprinted courtesy of
Patricia B. Santelle, White and Williams LLP and
Frank J. Perch, III, White and Williams LLP
Ms. Santelle may be contacted at santellep@whiteandwilliams.com
Mr. Perch may be contacted at perchf@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Mediation Scheduled for Singer's Construction Defect Claims
February 11, 2013 —
CDJ STAFFA judge has scheduled mediation and trial over the claims of Rihanna that her Beverley Hills home suffers from construction defects. The singer claims that the previous owners, Adriana and Heather Rudomin, did not disclose construction defects which lead to flooding from water leaks in January 2010.
The Rudomins did not appear at the February 7th hearing, and the judge fined them $500. They will be required to explain their absence on March 12. The mediation will begin on May 7. The trial has been scheduled for February 24, 2014, and is expected to last three weeks.
Read the court decisionRead the full story...Reprinted courtesy of
Health Care Construction Requires Compassion, Attention to Detail and Flexibility
July 01, 2019 —
Coker Barton - Construction ExecutiveWhen it comes to renovating and expanding hospitals, there is one principle that everyone can agree on: patients, family and hospital staff must be placed at the forefront of every stage of the job, ultimately dictating the project’s timeline. For a health care project to be a success, a general contractor needs to have industry-specific experience, must emphasize communication and scheduling and—most importantly—have a passion for the industry.
Capably and safely work in a health care environment
Health care requires a level of detail and understanding of the industry that is not found in other construction sectors. Builders must focus on infection control and interim life safety measures to protect patients, visitors and staff. There is accountability involved that goes beyond completing a project right on schedule.
For example, the expansion of The Studer Family Children’s Hospital at Sacred Heart in Pensacola, Fla., included a new 175,000-square-foot tower in addition to building out space above the Neonatal Intensive Care Unit. Anytime the contractor is building next to or over patients, especially those who are most vulnerable, it is on alert. It sets up containment areas, which help maintain the negative pressure in the construction area by pulling air in versus blowing dirty air out, as well as keep dust and other contaminants inside the construction area. There is no room for mistakes, which is why these techniques require more training and experience to properly execute.
Reprinted courtesy of
Coker Barton, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
New California Standards Go into Effect July 1st
July 01, 2014 —
Beverley BevenFlorez-CDJ STAFFGarret Murai on his California Construction Law Blog reminded readers that the California Building Energy Efficiency Standards and the New Listing Law Requirements goes into effect on July 1st of this year.
According to Murai, the new “California Building Energy Efficiency Standards include: (1) the 2013 California Energy Code, Part 6, (2) the 2013 California Administrative Code, Chapter 10, Part 1 and (3) the energy provisions of the 2013 CALGreen, Part II, Title, 25, of the California Code of Regulations.”
Furthermore, Murai pointed out that “Assemby Bill 44, which amended the Subletting and Subcontracting Fair Practices Act, also known as the Listing Law, was signed into law,” which requires prime contractors "to disclose the contractors license numbers of subcontractors performing work in excess of 0.5% of the prime contractor’s total bid or, in the case of bids for the construction of streets, highways, or bridges, in excess of 0.5% of the prime contractor’s total bid or $10,000, whichever is greater.”
Read the court decisionRead the full story...Reprinted courtesy of
Contractor Definition Central to Coverage Dispute
July 22, 2024 —
Stacy R. Goldscher & Tracy M. Lewis - Wood Smith Henning & BermanHow do you define the term "contractor?" In the case of California Specialty Insulation Inc. v. Allied World Surplus Lines Insurance Company, No. B324805 (2024), the court ultimately honored the reasonable expectations of the insured and ordered that the insurer defend and indemnify in an underlying suit stemming from the policy. This case involves a commercial general liability insurance policy issued by Allied World Surplus Lines Insurance Company (Allied) to California Specialty Insulation, Inc. (CSI). The central issue is whether Allied World is obligated to defend and indemnify CSI against a negligence claim stemming from a construction site accident. The dispute hinges on the interpretation of a policy exclusion for bodily injury to employees of any "contractor," a term not defined in the policy.
Factual Background
In 2017 Air Control Systems. Inc. (Air Control) was contracted to perform improvement work at a Los Angeles building and subsequently hired CSI to install duct insulation. In 2019, Jason Standiford, and Air Control employee, filed a negligence lawsuit against CSI, alleging injuries from a 2017 incident where a CSI employee allegedly drove a scissor lift into a ladder Standiford was on, causing him to fall. CSI requested Allied World to defend it in the Standiford lawsuit. Initially, Allied World accepted the defense, but later withdrew, citing the Contractor Exclusion in the policy. CSI filed for declaratory relief, leading to cross-motions for summary judgment. The trial court ruled in favor of CSI, finding the term contractor ambiguous and construing it in CSI's favor. Allied World appealed the decision.
Reprinted courtesy of
Stacy R. Goldscher, Wood Smith Henning & Berman and
Tracy M. Lewis, Wood Smith Henning & Berman
Ms. Goldscher may be contacted at sgoldscher@wshblaw.com
Ms. Lewis may be contacted at tlewis@wshblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
