Seattle Washington Building Expert Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Fix for Settling Millennium Tower May Start This Fall

August 17, 2020 — Nadine M. Post - Engineering News-Record
With the lengthy and complex permitting and approval process complete and almost all the other details worked out, construction could begin in mid-November on the estimated $100-million shoring fix for the 645-ft-tall Millennium Tower in San Francisco. The perimeter pile upgrade for the 58-story residential condominium building, which has settled more than 17 in. toward the northwest since its completion in 2009, was originally expected to begin earlier this year. Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Why Federal and State Agencies are Considering Converting from a “Gallons Consumed” to a “Road Usage” Tax – And What are the Risks to the Consumer?

August 26, 2015 — Roger Hughes – California Construction Law Blog
“‘We’re going to have to find another way to finance the upkeep of the roads,’ Gov. Jerry Brown said earlier this year in rolling out his 2015 budget. Governor Brown gave no specifics, but last fall he signed a law that set up a commission to study a ‘road usage charge’ with a call to ‘establish a pilot program by Jan. 1, 2017…'” – San Jose Mercury News, January 27, 2015 This Change, It’s a Coming (Maybe) Many states and the federal government are seriously considering converting from a “gallons consumed” tax levy to a “miles driven” program for determining gasoline tax. There are several compelling reasons for such a change. First, our roads are falling apart while revenue from current highway taxes fall woefully short of our current and projected needs. In the meantime, the number of miles driven by all-electric cars that pay no gas tax, is increasing rapidly; and by hybrids that pay substantially reduced tax; and worse for the taxing authorities, by increasingly efficient gas-powered cars. All of this means rapidly dropping gas tax revenues. Seeing this trend, local, state and the federal governments are making a major push to convert from a consumption based tax to a “miles driven” tax. This a good thing for those of us that believe increased investment in our transportation infrastructure is of high national concern. Read the court decision
Read the full story...
Reprinted courtesy of Roger Hughes, Wendel Rosen Black & Dean LLP
Mr. Hughes may be contacted at rhughes@wendel.com

Purse Tycoon Aims at Ultra-Rich With $85 Million Home

September 24, 2014 — John Gittelsohn and Nadja Brandt – Bloomberg
The eight-bedroom, 15-bath Beverly Hills, California, mansion has $5,600 toilets, a wall of caramel onyx and an 18-seat screening room with doors clad in Italian lizard skin. Asking price: $85 million. Rapper Jay Z has taken two tours of the hillside aerie with views that sweep from downtown Los Angeles to the Pacific Ocean. The estate was developed by Bruce Makowsky, who made his fortune selling handbags through department stores and the QVC television channel. “There was a void of homes for super-wealthy people, and that’s why I did it,” Makowsky said while sitting near a curved 54-foot (16-meter) glass wall that slides open to an infinity pool with iPad-controlled fountains. “I don’t think there’s anybody who’s served up $85 million-to-$100 million homes at this level for somebody to step into and buy.” Mr. Gittelsohn may be contacted at johngitt@bloomberg.net; Ms. Brandt may be contacted at nbrandt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn and Nadja Brandt, Bloomberg

SunEdison Gets Shinsei Bank Funding for Japan Solar Power Plant

March 12, 2015 — Ehren Goossens – Bloomberg
(Bloomberg) -- SunEdison Inc., a U.S. solar developer, got financing from Tokyo-based Shinsei Bank Ltd. for a large-scale project in the country. The 9.6-megawatt Tarumizu project on the southern Japanese island of Kyushu will power about 3,000 homes, Maryland Heights, Missouri-based SunEdison said Wednesday in a statement. The project is under construction and expected to be completed in September. Financial details weren’t disclosed. Read the court decision
Read the full story...
Reprinted courtesy of Ehren Goossens, Bloomberg
Mr. Goossens may be contacted at egoossens1@bloomberg.net

Harmon Towers Demolition Still Uncertain

January 23, 2013 — CDJ STAFF
It would be a "gift" to MGM Resorts if they were able to tear down the Harmon Tower, according to an article in the New York Times, as analysts are cited that a hotel would "struggle during this economic downturn." Further, William Robinson, a professor of economics at the University of Nevada, Las Vegas, noted that "MGM has tried to cut back on the whole project," adding that "if you are a conspiracy theorist, you thin they are just looking for a way to get out of it." Professor Robinson thinks they would be unlikely to rebuild if allowed to tear down the building. MGM Resorts has a different take on the matter. Alan M. Feldman, MGM's senior vice president for public affairs, told the New York Times that MGM "had a contract with Perini that we would pay them to give us a certain kind of building type — in this case a luxury hotel." Mr. Feldman contends that Perini had not "kept up their part of the bargain." Perini has stated that the fault was due to the designers and did not comment to the Times. The claims of design and construction defects have left the building unfinished, with only twenty-six of the planned forty-nine floors constructed. Perini contends the building can still be repaired. MGM that its remediation plan is "to take the building down." Read the court decision
Read the full story...
Reprinted courtesy of

Appeals Court Affirms Carrier’s Duty to Pay Costs Taxed Against Insured in Construction Defect Suit

November 03, 2016 — Jesse Howard Witt – The Witt Law Firm
One of the key reasons for builders to maintain liability insurance is to cover the cost of hiring defense counsel and paying litigation costs in the event of a construction defect lawsuit. If a builder loses a lawsuit, it will typically be responsible for paying the plaintiff’s litigation costs. Today, the Colorado Court of Appeals clarified that the “supplementary payments” section of a standard Commercial General Liability (CGL) insurance policy covers such costs, even if the carrier has reserved the right to dispute whether it has a duty to indemnify the actual damages awarded. This may seem counter-intuitive, insofar as a carrier may owe costs even if it does not cover the underlying loss, but the court’s decision is consistent with the plain language of the CGL form that most carriers use. Reprinted courtesy of Jesse Howard Witt, The Witt Law Firm Mr. Witt may be contacted at his website www.witt.law Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

No Escape: California Court of Appeals Gives a Primary CGL Insurer’s “Other Insurance” Clause Two Thumbs Down

December 02, 2015 — Yas Omidi – California Construction Law Blog
“No Escape” is a 2015 action movie starring Pierce Brosnan and Owen Wilson (that’s right, Owen Wilson) and which the folks at rogerebert.com described as “a dreadful…would-be thriller” and “low-grade trash.” It’s also, in short, the California Court of Appeal’s answer to a primary insurer’s recent bid to escape its duty to defend pursuant to an “other insurance” clause in a CGL policy in Underwriters of Interest Subscribing to Policy No. A15274001 v. ProBuilders Specialty Ins. Co., Case No. D066615, California Court of Appeals for the Fourth District (October 23, 2015). Read the court decision
Read the full story...
Reprinted courtesy of Yas Omidi, California Construction Law Blog
Ms. Omidi may be contacted at yomidi@wendel.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES