SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

---

Ensuring Arbitration in Construction Defect Claims

February 04, 2013 — CDJ STAFF
Jared E. Berg and John W. Mill of Sherman & Howard note that developers and general contractors would prefer that construction defect claims against them go to arbitration, instead of ending up in front of a jury. They say “there is a way to do this.” For the developer and general contractor, arbitration is “typically less costly and time consuming than litigation.” On the other side, home owner associations “tend to prefer litigation because the up-front costs of arbitration are greater and they would rather have their cases tried to a jury than a panel of arbitrators in the belief juries offer greater potential for high damage awards. In order to avoid arbitration, “HOAs have taken advantage of their statutory rights to amend declarations by instructing their members to approve amendments removing arbitration clauses. However, in a recent Colorado case, the developer had taken a precaution of including in the arbitration clauses that “they could not be removed from the declarations by amendment with the developer’s and general contractor’s consent.” The homeowners association had voted to remove these clauses, but the judge found that they could not do so. Berg and Mill give the advice to “include in the declaration’s arbitration clause a provision making your consent required to amend or nullify the arbitration provision,” adding that “courts will enforce this kind of consent provision.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Dump Site Provider Has Valid Little Miller Act Claim

October 19, 2020 — Christopher G. Hill - Construction Law Musings
You may have thought that a Virginia “Little Miller Act” bond claim, like a mechanic’s lien, could only be brought by those that provide materials and labor incorporated into the construction project. If you did, you aren’t alone. In fact, Safeco Insurance Co. of America, a surety, made exactly the above argument in Yard Works LLC v. GroundDown Constructors LLC. In that case, a debris hauling company failed to pay Yard Works, the company that provided the dumping site for the debris. Yard Works sued pursuant to the Little Miller Act to get paid. In response, the surety sought to have the claim against the payment bond dismissed and argued that because Yard Works did not actually improve the property or provide improvements and that Yard Works only passively provided a dump site, Yard Works could not claim under the payment bond. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

My Construction Law Wish List

December 31, 2014 — Garret Murai – California Construction Law Blog
I’ve been good this year. Not great mind you, but good, and good is the standard, right? So, here’s my construction law wish list this holiday season: 1.More Transparency. So much uncertainty and resultant litigation exists for the simple reason that contractors and subs don’t know when a higher tiered contractor or owner (on a lender financed project) has been paid for their work. So how about a requirement that owners, contractors and subcontractors of all tiers be required to disclose when payment applications are submitted, when payments are made and in what amount, and what pay applications have been paid. And because I’m pretty sure I’m at least within the 20th percentile of “good” this year how about a requirement that this information be provided through an online database accessible by all persons working on projects valued at over a certain dollar amount, say $500,000. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

'There Was No Fighting This Fire,' California Survivor Says

September 14, 2020 — The Associated Press (Brian Melley & Terence Chea) - Bloomberg
Berry Creek, Calif. (AP) -- John Sykes built his life around his cabin in the dense woods of Northern California. He raised his two children there, expanded it and improved it over time and made it resilient to all kinds of disaster except fire. So when the winds started howling Tuesday and the skies became so dark from smoke that he had to turn on his lights at midday, he didn’t hesitate to leave it all behind in an instant before any evacuation order. With the disaster two years ago in nearby Paradise, in which 85 people perished in the deadliest and most destructive fire in modern state history, still fresh on his mind, Sykes got his wife and a friend into his car and left with only a change of clothes each. “All I could do is look in the rear view mirror and see orange sky and a mushroom cloud and that told me it was hot and to keep going,” Sykes said Friday. “It was a terrifying feeling.” Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

---

Colorado “occurrence”

January 06, 2012 — CDCoverage.com

In Greystone Construction, Inc. v. National Fire & Marine Insurance Co., No. 09-1412 (10th Cir. November 1, 2011), general contractors Greystone and Branan were each sued by purchases of homes built by each alleging defective construction performed by subcontractors. CGL insurer American Family Mutual Insurance Company defended both Greystone and Brannon while co-insurer National Fire & Marine Insurance Company denied a defense. Greystone, Branan, and American Family sued National Fire for contribution towards defense costs. The federal district trial court entered summary judgment for National Fire.

Read the full story…

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Chairman of the Senate Committee on Banking, Housing and Urban Affairs Calls for CFPB Investigation into Tenant Screening Businesses

December 13, 2021 — Brian H. Montgomery - Gravel2Gavel Construction & Real Estate Law Blog
Senator Sherrod Brown (D-OH), Chairman of the Senate Committee on Banking, Housing, and Urban Affairs, has written to newly confirmed Consumer Financial Protection Bureau (CFPB) Director Rohit Chopra, asking him to review companies in the tenant screening industry for possible Fair Credit Reporting Act violations and other violations of U.S. laws. The CFPB, for its part, has already published a bulletin alerting Consumer Reporting Agencies (CRAs) and other furnishers of consumer information that, as federal, state and local pandemic-related housing protections expire, the Bureau will be giving greater enforcement focus to these businesses’ compliance with accuracy and dispute obligations under the Fair Credit Reporting Act (FCRA) and Regulation V. While it is still unclear whether Director Chopra will direct the Bureau to investigate specific businesses flagged by Chairman Brown, the tenant screening industry will likely face increased scrutiny in the coming months, which may impact their service offerings and cause interruptions for landlords relying on these businesses and services. There are approximately 2,000 tenant screening companies across the United States. These companies are used by landlords to better identify and perform background checks on prospective tenants. These reports typically provide a prospective tenant’s rental and eviction histories, credit score, debt-to-income ratio, and outstanding credit obligations, among other financial metrics. The reports also usually include a criminal background check, including searches of sex offender registries and other public records searches. Many tenant screening companies then use this information to provide an estimate of the risk that each tenant presents, calculated through proprietary algorithmic formulas. These reports are usually available to landlords at a cost ranging from approximately $5 to $55 per report, usually passed through to the prospective tenant through application fees. Read the court decision
Read the full story...
Reprinted courtesy of Brian H. Montgomery, Pillsbury
Mr. Montgomery may be contacted at brian.montgomery@pillsburylaw.com

---

Latin America’s Biggest Corporate Crime Gets a Worthy Epic

January 04, 2021 — Mac Margolis - Bloomberg
As much as pouring cement and building towers, Brazilian construction dynasty Odebrecht was famed for its political panache. “I get down in the mud with the pigs but come out the other side clean in my white suit,” Norberto Odebrecht, founder of the legacy contractor, liked to boast back in the 1970s and 1980s. The catchphrase was shorthand for what became a patently Brazilian way of doing business – the art of buying influence and coming away unsoiled, or at least unincarcerated – among porcine politicians and bribe-truffling officials. In half a century and over three generations, the family firm from northeast Brazil grew into a multinational engineering colossus, hurling up grand public works from the Andes to Angola. Shady pacts with political grifters and bagmen were just part of the deal behind the build-up and seemingly nothing a little Brazilian bonhomie and contract skimming couldn’t tidy up. Until it didn’t. Read the court decision
Read the full story...
Reprinted courtesy of Mac Margolis, Bloomberg
Mr. Margolis may be contacted at mmargolis14@bloomberg.net

---