SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Turkey to Start Building 200,000 Homes in March, Erdogan Says

February 20, 2023 — Taylan Bilgic - Bloomberg
President Recep Tayyip Erdogan has announced that Turkey will begin constructing almost 200,000 homes as early as March in areas devastated by twin earthquakes that hit the southeast of the country two weeks ago. Erdogan emphasized the severity of the earthquake’s impact, drawing parallels to historical events that wreaked havoc in Anatolia, the heartland of modern Turkey. “With faith, courage and patience, we have resisted numerous political and social upheavals for centuries, such as the Crusades and the Mongol invasions,” he said. The construction of 199,739 new homes will begin in 11 provinces, including the hardest-hit Hatay and Kahramanmaras, Erdogan said. The death toll from the earthquakes has risen to 41,156 while over 114,000 people have been rescued from the rubble. Read the court decision
Read the full story...
Reprinted courtesy of Taylan Bilgic, Bloomberg

---

Terminating Contracts for Convenience — “Just Because”

June 28, 2021 — David Adelstein - Florida Construction Legal Updates
Termination for convenience provisions are important provisions to include in construction contracts. These are provisions that allow a party to terminate the contract for ANY REASON. No cause is needed to exercise the termination for convenience provision. In other words, the terminating party does not have to demonstrate the other party breached the contract. A termination for convenience can be exercised “just because.” Typically, the party providing the service should not get to terminate for convenience. However, the party receiving the service will want to be afforded this contractual right. For example, an owner (receiving a service) will want to include a termination for convenience provision with its prime contractor (providing a service). And, a general contractor (receiving a service) will want to include a termination for convenience provision in its subcontract with its subcontractor (providing a service). However, a general contractor providing a service for an owner, or a subcontractor providing a service to a general contractor, should not be able to terminate the contract for their convenience “just because” a better opportunity comes along. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

The Hidden Dangers of Construction Defect Litigation

March 28, 2012 — David M. McLain, Colorado Construction Litigation

David M. McLain, writing at Colorado Construction Litigation, has an interesting blog post republishing his article in Common Interests magazine, the monthly periodical of the Rocky Mountain Chapter of the Community Associations Institute. In his article, he touches on a number of pitfalls in construction defect litigation, including the potential conflicts of interests facing HOAs. He also considers the problems homeowners can face, including both “strong-arm tactics” taken by attorneys to compel homeowners to join the lawsuit, or situations in which the interests of the HOA do not match those of the homeowners. He writes:



There is also a conflict of interest with individual owners who attempt to opt out of the case. This can lead to shocking strong-arm tactics on the part of plaintiffs’ attorneys. In one instance, a plaintiffs’ attorney sent a letter to an individual homeowner that stated that as a 1/58th owner of the common elements, if he refused to go along with the suit, and there was ultimately a finding in favor of the HOA which was in any way limited by his refusal to participate, he would be personally liable for 1/58th of the HOA’s total damages. In another instance, a different plaintiffs’ attorney sent a letter to a homeowner who wanted the builder to perform warranty repairs, informing the owner that if he let the builder perform any repairs, the attorney would bill the HOA according to the fee agreement entered by the HOA board (without knowledge or consent of non-board members) and that the HOA would assess the homeowner for that expense. These are just two examples of conflicts which may arise between the HOA board and individual homeowners when the HOA pursues CD cases.



Another example of a conflict which will arise as a result of CD litigation occurs post-settlement. When an HOA settles for less than 100% of the amount necessary to fund all repairs outlined by its experts, plus attorneys’ fees and litigation costs, there will obviously be a shortfall in the amount necessary to fix the development. The HOA board must then choose to impose a special assessment to cover the shortfall or to make some, but not all, of the repairs outlined by its experts. In choosing the latter, the conflict arises with respect to which homes get fixed and which do not. In this situation, the HOA board has acted as the attorney-in-fact for the individual owners by bringing claims on their behalf, and has compromised those claims without their knowledge or consent.

Read the full story…



Reprinted courtesy of David M. McLain of Higgins, Hopkins, McClain & Roswell, LLC. Mr. McClain can be contacted at mclain@hhmrlaw.com.

Read the court decision
Read the full story...
Reprinted courtesy of

---

Reminder About the Upcoming Mechanic’s Lien Form Change

August 26, 2019 — Christopher G. Hill - Construction Law Musings
As July 1, 2019 approaches with its inevitable changes to the Virginia Code, I wanted to remind you once again that the statutory form for a Virginia mechanic’s lien will change as of that date. HB2409 passed both houses of the General Assembly and has been signed by the Governor. This bill reconciled the language found in Virginia Code Sec. 43-4 with the various forms for general contractor, subcontractor and sub-subcontractor/supplier forms found in later sections of the code. As you will see if you download the .pdf of the bill as signed, this involved some tweaks to 43-4 and some updates to the mechanic’s lien forms that are in the code. The recent Desai case from the Virginia Supreme Court made it clear that such action was necessary. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

MTA Implements Revised Contractors Debarment Regulations

July 06, 2020 — Steven M. Charney, Gregory H. Chertoff & Paul Monte - Peckar & Abramson, P.C.
On June 3, 2020, the Metropolitan Transit Authority (“MTA”) published and implemented revised regulations pertaining to the debarment of contractors. The revised regulations address many of the deep concerns raised by the contracting community. Under relevant administrative procedure, the MTA publication of the revised regulations starts a 45 day notice period before the regulations can be adopted as final. The prior regulations essentially required that debarment occur upon a purely formulaic calculation establishing that a contractor: 1) was more than 10% late, or 2) had submitted invalid claims that exceeded the adjusted contract price by a measure of 10%. The revised regulations represent improvements over the prior regulations. Critically, the revised regulations address the primary concern raised by the contracting community, that being the mandate of purely formulaic debarment. Instead, the revised regulations establish a process that includes greater flexibility and discretion before debarment may ensue. Reprinted courtesy of Peckar & Abramson, P.C. attorneys Steven M. Charney, Gregory H. Chertoff and Paul Monte Mr. Charney may be contacted at scharney@pecklaw.com Mr. Chertoff may be contacted at gchertoff@pecklaw.com Mr. Monte may be contacted at pmonte@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractor’s Charge Of Improvements To Real Property Not Required For Laborers To Have Lien Rights

June 13, 2018 — Matt T. Paxton - Ahlers Cressman & Sleight PLLC Blog
In Washington, persons furnishing labor, professional services, material, or equipment for improvements of real property are generally entitled to a lien on that property, but only if their labor is furnished at the direction of the owner or the owner’s “construction agent.”[1] Whether a lien attaches, therefore, can turn on whether the person directing work is the owner’s construction agent. Washington’s mechanic’s lien statute defines “construction agent” as “any registered or licensed contractor, registered or licensed subcontractor, architect, engineer, or other person having charge of any improvement to real property, who shall be deemed the agent of the owner for the limited purpose of establishing the lien created by this chapter.”[2] Read the court decision
Read the full story...
Reprinted courtesy of Matt T. Paxton, Ahlers Cressman & Sleight PLLC
Mr. Paxton may be contacted at matt.paxton@acslawyers.com

---

U.S. Firm Helps Thais to Pump Water From Cave to Save Boys

August 14, 2018 — Dan Murtaugh - Bloomberg
Like much of the world, Patrick Decker has been engrossed in the saga of 12 boys and their soccer coach who became trapped in a flooded cave in Thailand. Unlike most, Decker is in a position to do something about it. As chief executive officer of Xylem Inc., one of the world’s top water technology firms, Decker spent much of last week reaching out to Thai officials and mobilizing his company of 17,000 employees to help. Decker said he sent four engineers to the cave site, and they assisted rescuers by boosting pumping power 40 percent. Thai Navy SEALs and international cave diving experts extracted eight boys over Sunday and Monday. Read the court decision
Read the full story...
Reprinted courtesy of Dan Murtaugh, Bloomberg

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---