Seattle Washington Building Expert Directory

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Bremer Whyte’s Newport Beach Team Prevails on a Motion for Summary Judgment in a Wrongful Death Case!

September 02, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations on another win to Orange County Partners Jonathan Cothran and Rachel Mihai for prevailing on a Motion for Summary Judgment in a wrongful death case! Plaintiffs filed a wrongful death lawsuit alleging negligence and vicarious liability against BWB&O’s client, a licensed electrical contractor. BWB&O’s client installed a solar system at the Plaintiffs’ home in January 2018. In October 2018, an electrical fire broke out at the home in an upstairs bedroom. Tragically, the family’s father perished in the fire when he entered the home after the fire started. Plaintiffs alleged that BWB&O’s client was liable for the fire and Plaintiffs’ resulting injuries due to its electrical work on the solar system at the home. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

US Supreme Court Orders All Mountain Valley Gas Line Work to Proceed

August 14, 2023 — Debra K. Rubin - Engineering News-Record
In a ruling without explanation in response to an emergency appeal by the project developer, the U.S. Supreme Court on July 27 said work to complete the Mountain Valley gas pipeline can proceed. The decision follows an order earlier this month by the Richmond, Va., appeals court to halt restart of work on the much-litigated and delayed $6.6-billion, 303-mile natural gas pipeline in Virginia and West Virginia, after new lawsuits filed by opponent groups. Reprinted courtesy of Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Litigation Roundup: “Builder’s Risk Indeed”

October 24, 2023 — Daniel Lund III - Lexology
A contractor for a hotel in Seattle was tasked with constructing the hotel utilizing premanufactured modular hotel rooms. The modular unit portion of the project was the subject of a $15.8 million subcontract between the general contractor and the manufacturer. The manufacturer was also responsible to the GC for shipping and installing the modular units. Shipping was to be “DDP,” or “Delivery Duty Paid” – which, according to a New York federal court, “is an international shipping term meaning that the seller assumes all responsibilities and costs for delivering property to the named place of destination, including export and import clearance, fees, duties, and taxes.” Additionally, per the subcontract, the manufacturer was responsible for “ensur[ing] all modular units [were] covered, secured[,] and protected from damage during the shipping process….” The modular units were shipped from Poland to Seattle. In the shipping process, the units spent some time in the Port of Everett in Washington state, where the units sustained water damage while sitting in port. A related damage claim made by the subcontractor against the general contractor’s builder’s risk policy. On the face of the policy, the policy covered subcontractors as “additional insured” parties, covered all manner of materials and the like to be used on the project, and would provide that coverage in the process of transporting the materials insofar as “inland or coastal waters” were concerned. Yet, the builder’s risk insurer refused to cover the claim for the damages to the modular units which occurred while sitting in port in Everett. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

US Appeals Court Halts OSHA Vaccine Mandate, Unclear How Long

November 15, 2021 — Debra K. Rubin & Jeff Yoders - Engineering News-Record
The U.S. Court of Appeals in New Orleans on Nov. 6 stayed the Biden administration's requirement that workers at U.S. companies with at least 100 employees be vaccinated against COVID-19 or be tested weekly, citing potential "grave statutory and constitutional" issues raised by opponents of the US Occupational Safety and Health Administration's emergency temporary standard announced on Nov. 4. Reprinted courtesy of Debra K. Rubin, Engineering News-Record and Jeff Yoders, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Mr. Yoders may be contacted at yodersj@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

“Based On”… What Exactly? NJ Appellate Division Examines Phrase and Estops Insurer From Disclaiming Coverage for 20-Month Delay

August 20, 2019 — Anthony L. Miscioscia and Timothy A. Carroll - White and Williams LLP
On May 28, 2019, the New Jersey Superior Court, Appellate Division examined the phrase “based on” in an assault-and-battery exclusion, finding that the phrase means “to make, form, or serve as the foundation of any claim, demand or suit.” C.M.S. Investment Ventures, Inc. v. American European Insurance Company, No. A-2056-17T3, 2019 N.J. Super. Unpub. LEXIS 1215, at *8-9 (N.J. Super. Ct. App. Div. May 28, 2019) (CMS). The CMS case is also notable because the Appellate Division held that a 20-month delay in disclaiming coverage was unreasonable and therefore warranted estoppel. In CMS, the insured was allegedly warned by its tenant about a faulty ground-floor window that failed to lock properly. Afterward, an intruder broke into the tenant’s apartment and sexually assaulted the tenant, who sued the insured on a premises liability claim. Before she filed suit, the tenant sought payment from the insured’s CGL insurer directly. The insurer denied coverage based on the assault-and-battery exclusion and closed the file, but never informed the insured. Later, the tenant sued the insured, which sought a defense and indemnity from its insurer, which again denied coverage based on the exclusion. The insured then sought a declaration of coverage on grounds that the exclusion was ambiguous, and the insurer “was estopped from denying coverage, because it waited [20] months to inform CMS of its coverage decision.” The trial court ruled in the insured’s favor which led to the appeal in CMS. Reprinted courtesy of Timothy Carroll, White and Williams LLP and Anthony Miscioscia, White and Williams LLP Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Mr. Carroll may be contacted at carrollt@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Treble Damages Awarded After Insurer Denies Coverage for Collapse

July 03, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Fourth Circuit upheld the district court's decision that a collapse was covered, but reversed the denial of treble damages to the insured. DENC, LLC v. Phila. Indem. Ins. Co., 2022 U.S. App. LEXIS 10443 (4th Cir. April 18, 2022). The district court decision was summarized here. DENC owned The Crest, an apartment building leased to Elon University for student housing. Philadelphia Indemnity Company insured the property. In January 2018, students gathered on a second-floor breezeway for a party. Partygoers began jumping in the breezeway, which caused an abrupt collapse. Observers noticed that the breezeway was hanging down by more that a foot. DENC filed a claim with Philadelphia the next day. An adjuster was sent to inspect the breezeway. By that time, the city had condemned The Crest. The adjuster said that undiscovered "water damage which occurred over an extended period of time" caused the loss. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Following California Law, Federal Court Adopts Horizontal Allocation For Asbestos Coverage

May 19, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Following California law, the federal district court adopted horizontal allocation to settle a dispute among carriers for an insured sued for selling asbestos products. New England Fire Ins. Corp. v. Ferguson Enterprises, Inc., Civil No. 3:12cv948 (D. Conn. April 8, 2014) [ruling here] The insured was a California-based corporation that sold plumbing supply products that contained asbestos. The insured was named in numerous asbestos-related lawsuits that were filed largely in California. The insured had primary and excess coverage for bodily injury claims. New England Fire Insurance issued an excess policy to the insured. The policy provided the insurer would be liable for the ultimate new loss in excess of the insureds underlying limit, which was defined as the amount equal to the limits of the underlying insurance, plus the applicable limits of any other underlying insurance collectible by the insured. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES