Fairfield Connecticut Building Expert Directory

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

What are Section 8(f) Agreements?

July 02, 2018 — Wally Zimolong – Supplemental Conditions
Like many areas of federal labor law, there are different rules for construction industry employers. One major difference is in how employers become unionized. Typically, under Section 9(a) of the National Labor Relations Act, a union becomes a collective bargaining agent of employees only after a majority of employees show support for union representation. In other words, the employees chose whether to be represented by a particular union. However, under Section 8(f) of the NLRA, construction industry employers can choose to become union without any showing of majority support by employees. In fact, construction industry employers don’t need to have any employees at all to sign a “8(f) agreement.” Thus, these agreements have become known as pre-hire agreements. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

OSHA Announces Expansion of “Severe Violator Enforcement Program”

November 15, 2022 — Kip J. Adams & Steven G. Gatley - Lewis Brisbois
(October 28, 2022) - Employers beware! The Occupational Safety and Health Administration (OSHA) is significantly expanding its “Severe Violator Enforcement Program” (SVEP). Employers that are placed into the program by OSHA will be significantly scrutinized, with the potential for very damaging information about their failure to maintain a safe workplace being made public for customers, partners, and vendors to see. As the name suggests, the program is meant to identify, classify, and then stringently monitor employees deemed to be “severe violators” of the OSH Act. According to the OSHA website alert, to be deemed a “severe violator”, the agency must find that the employer has demonstrated “indifference” to the regulations by committing “willful, repeated, or failure-to-abate” violations. Reprinted courtesy of Kip J. Adams, Lewis Brisbois and Steven G. Gatley, Lewis Brisbois Mr. Adams may be contacted at Kip.Adams@lewisbrisbois.com Mr. Gatley may be contacted at Steven.Gatley@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Excess Carrier's Declaratory Judgment Action Stayed While Underlying Case Still Pending

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court determined the excess carrier's declaratory judgment action to establish it had no coverage obligations should be stayed while the underlying case was still pending. Scottsdale Ins. Co. v. Ortiz & Assocs., 2014 U.S. Dist. LEXIS 64286 (D. Ore. May 9, 2014). The subcontractor's employee was killed on the job site when struck by a dump truck owned by the general contractor, Inland Asphalt Co. Island was sued for wrongful death. Island was an additional insured under the subcontractor's primary policy and excess policy with Scottsdale. Inland put Scottsdale on notice of the underlying wrongful death lawsuit, but did not tender its defense to Scottsdale. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

It’s Not What You Were Thinking!

December 10, 2024 — Daniel Lund III - Lexology
At least it is not what the lower court was thinking… but the same result for a general contractor seeking to have its comprehensive general liability insurer pay the GC’s defense related to claims for physical damage on a construction project. In reviewing the Massachusetts federal district court’s ruling in favor of the insurer, the United States First Circuit Court of Appeals posited: “The principal question is whether a general contractor’s CGL insurance policy covers damage to a non-defective part of the contractor’s project resulting from a subcontractor’s defective work on a different part of that project.” The district court had held under Massachusetts law that the insurer had no duty to defend because the lawsuit “did not allege ‘property damage’ caused by an ‘ occurrence,’ as required for coverage” under the policy (a defense that was urged by the insurer). The Court of Appeals affirmed, “albeit for different reasons.” Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Florida’s Supreme Court Resolves Conflicting Appellate Court Decisions on Concurrent Causation

December 21, 2016 — Afua S. Akoto – Saxe Doernberger & Vita, P.C.
The Supreme Court of Florida kicked off December with an opinion that determined which theory of recovery applies when multiple perils combine to create a loss, and at least one of those perils is excluded by the terms of a policy. In Sebo v. American Home Assurance Company, Inc.,1 the court resolved the conflict between the Florida Appellate Courts for the Second District and the Third District and declared the concurrent cause doctrine (CCD) as the more applicable theory of recovery over the efficient proximate cause doctrine (EPC). The underlying dispute concerned damage to a home Sebo purchased in Naples, Florida in April 2005. The American Home Assurance Company (AHAC) insured the home under a manuscript policy specifically created for the property with limits of over eight million dollars. In May 2005, Sebo discovered major water leaks in the main foyer, master bathroom, exercise room, piano room, and living room of the home. In August, paint fell off the walls after it rained, and it became clear that the house suffered from major design and construction defects. When Hurricane Wilma struck in October, the house was further damaged by rain water and high winds, and was eventually demolished. Read the court decision
Read the full story...
Reprinted courtesy of Afua S. Akoto, Saxe Doernberger & Vita, P.C.
Ms. Akoto may be contacted at asa@sdvlaw.com

Primer Debuts on Life-Cycle Assessments of Embodied Carbon in Buildings

August 20, 2018 — Engineering News-Record
A recently released primer for the use of a life-cycle assessment approach to analyze the environmental impacts of buildings is considered a small but necessary step toward the ambitious goal of getting to net-zero embodied carbon and operational greenhouse gas emissions in the construction, operation and decommissioning of buildings. The LCA guide comes after the release of the first-of-its-kind benchmarking database of embodied carbon in existing buildings. And another first—a tool to calculate embodied carbon in construction—is on the horizon. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

BWB&O Senior Associate Kyle Riddles and Associate Alexandria Heins Obtain a Trial Victory in a Multi-Million Dollar Case!

May 01, 2023 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is excited to share that Newport Beach Senior Associate Kyle Riddles and Associate Alexandria Heins obtained a significant trial victory on behalf of their client in a multi-million dollar dispute stemming from the construction of a commercial expansion project at a beachfront resort. The owner of the resort alleged that the general contractor was responsible for a significant delay to the completion of the expansion project. The general contractor filed a cross-complaint against BWB&O’s client in an attempt to pass through the delay claims to BWB&O’s client. The general contractor’s delay expert alleged a total 441 days of delay to the completion of the project. A significant portion of the delay was apportioned to BWB&O’s client, for which it faced substantial contractual damages. Senior Associate Kyle Riddles expertly crossed key witnesses and obtained testimony that was extremely favorable to its client. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES