Duty to Defend Construction Defect Case Triggered by Complaint's Allegations
August 20, 2014 —
Tred R. Eyerly – Insurance Law HawaiiThe subcontractor's insurer could not escape contributing to defense costs of its insured when coverage was possible based upon the underlying complaint's allegations. Seneca Ins. Co. v. James River Ins. Co., 2014 U.S. Dist. LEXIS 97156 (D. Ore. July 17, 2014).
The underlying action alleged construction defects in a 60-unit complex located in Seaside, Oregon. S.D. Deacon Corp. was the general contractor and contracted with the owners association to reconstruct portions of the building, including the curtain wall. Deacon subcontracted with Superwall Design, LLP for work on the curtain wall renovation.
At some point not specified in the underlying complaint, the Association notified Deacon of construction defects in the curtain wall renovation. Deacon investigated and concluded that the alleged property damage was the result of inadequate usage of materials, violations of state and local building codes, and violations of relevant industry standards relating to the work performed by Superwall. Deacon contended that the problems were caused by Superwall's faulty workmanship.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
LA’s $1.2 Billion Graffiti Towers Put on Sale After Bankruptcy
June 04, 2024 —
John Gittelsohn - BloombergFor sale: Steel skeletons of three towers in downtown Los Angeles, erected by a Chinese developer that spent $1.2 billion before running into financial troubles.
The site, called Oceanwide Plaza, became famous this year when graffiti artists covered the 49-floor-tall structures. Now, the property is going on the market, with lenders and other creditors needing about $400 million to recoup their money.
The brokerage Colliers and advisory firm Hilco Real Estate have been hired to market and handle a sale of the property, subject to bankruptcy court approval, according to a statement.
“We are determined to run a disciplined and orderly process to identify the right developer to finish the project in time for the 2028 Summer Olympics,” said Mark Tarczynski, an executive vice president at Colliers.
Read the court decisionRead the full story...Reprinted courtesy of
John Gittelsohn, Bloomberg
Georgia Local Government Drainage Liability: Nuisance and Trespass
November 29, 2021 —
David R. Cook Jr. - Autry, Hall & Cook, LLPA long-running dispute between a landowner and a municipality has escalated to the Georgia Court of Appeals and in the federal court for the Northern District of Georgia.[1] The municipality maintained a stormwater system that discharged on property uphill from the landowner’s property. The uphill property was used as an illegal dump, and debris washed downhill from the dump to the landowner’s property. The debris clogged the landowner’s surface water drainage system, which caused flooding of the property and a building.
State Case
The landowner sued for trespass, nuisance, takings, and inverse condemnation. While the other claims were barred by the four-year statute of limitations, the court addressed the plaintiff-landowner’s claim for continuing nuisance.
Municipalities may be liable when they negligently construct or maintain a sewer or drainage system that causes repeated flooding of property, such that it results in a continuing, abatable nuisance.[2] For a municipality to be liable for maintenance of a nuisance:
the municipality must be chargeable with performing a continuous or regularly repetitious act, or creating a continuous or regularly repetitious condition, which causes the hurt, inconvenience or injury; the municipality must have knowledge or be chargeable with notice of the dangerous condition; and, if the municipality did not perform an act creating the dangerous condition, . . . the failure of the municipality to rectify the dangerous condition must be in violation of a duty to act.[3]
Read the court decisionRead the full story...Reprinted courtesy of
David R. Cook Jr., Autry, Hall & Cook, LLPMr. Cook may be contacted at
cook@ahclaw.com
Incorporation, Indemnity and Statutes of Limitations, Oh My!
January 19, 2017 —
Christopher G. Hill – Construction Law MusingsWe all know that the contract is king in Virginia. We also know that Virginia will allow for a so called “incorporation” clause that will allow for “flow down” of certain prime contract provisions in a way that will make those provisions applicable to subcontractors. We also know that a claim for breach of contract or other contractual claim does not last forever due to certain statutes of limitation found in the Code of Virginia. What happens when all of these elements crash together in one place leading to litigation? Well, a relatively recent case from the Virginia Supreme Court gives at least a partial answer.
In Hensel Phelps Construction Company v Thompson Masonry Contractor, Inc, the Virginia Supreme Court considered a claim that arose from construction at Virginia Tech by Hensel Phelps. The construction concluded in 1998 (remember that date). The Prime Contract included language concerning a one year “Guarantee of Work” as well as fairly typical Warranty of Workmanship” language. However the Prime Contract also stated that the one year guaranty term did nothing to affect any other limitations period for any other action pursuant to the Prime Contract (this is important as well because Virginia Tech was not subject to any statute of limitations due to its status as an agency of the Commonwealth of Virginia). Final payment was made to Hensel Phelps and subsequently to the subcontractors in 1999.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment
December 16, 2019 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government).
Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
So You Want to Arbitrate? Better Make Sure Your Contract Covers All Bases
August 16, 2021 —
Stephanie Nolan Deviney - ConsensusDocsAs a General Contractor, you may prefer to arbitrate any contractual disputes rather than engage in protracted litigation. Many Courts favor arbitration clauses and will enforce them if there is a sufficient reason to do so. However, there are several issues that a General Contractor should consider when including an arbitration clause in its construction agreement with its client. When an arbitration clause is not properly crafted, questions can arise as to who must arbitrate? Who decides whether to arbitrate? Who selects the arbitrator? What will the subject matter of the arbitration be? A look at a recent case in Pennsylvania highlights the need for properly crafted arbitration clauses.
A Recent Case Highlights The Importance Of Arbitration Clauses
In TEC Construction, LLC v. Greg Rich and Lora Rich filed in the Court of Common Pleas, Allegheny County, Pennsylvania, TEC Construction, LLC (“TEC”) and Greg and Lora Rich (the “Riches”), entered into a Construction Agreement with an arbitration clause. Specifically, the parties to the Construction Agreement, TEC and the Riches, agreed to arbitrate any disputes with the American Arbitration Association. Five subcontractors completed the work under the Construction Agreement but none of the subcontractors agreed to arbitrate.
Read the court decisionRead the full story...Reprinted courtesy of
Stephanie Nolan Deviney, Fox Rothschild LLP (ConsensusDocs)Ms. Deviney may be contacted at
sdeviney@foxrothschild.com
Get Construction Defects in Writing
December 11, 2013 —
CDJ STAFFSometimes, even if a developer is willing to make a repair, sometimes the repair doesn’t get to the actual problem, according to Nicholas D. Cowie of Cowie & Mott, writing on his blog. He notes that “getting it ‘right’ the first time is important and written documentation is key.” He gives the example of “when a developer agrees to informally repair a window or roof leak, the ‘repair,’ as far as the developer is concerned, may consist merely of sending out a worker with a caulk gun to seal gaps that should have been protected with a solid flashing material during the original installation.”
As a better course, he says that homeowner associations should “request a written description of the proposed repair” in order that it can be evaluated. This also allows follow-up to determine if the agreed-upon repair was done properly. And, although some homeowners associations would rather not have the original subcontractor repair their own work, here warranties often come into play.
Read the court decisionRead the full story...Reprinted courtesy of
Providing Your Insurer Prompt Notice
May 20, 2024 —
David Adelstein - Florida Construction Legal UpdatesSometimes, when it comes to insurance, you may hear the argument that you breached your insurance policy by failing to provide your insurer with prompt notice as the insurance policy requires. Well, this is not such an absolute issue. With that said, you should absolutely provide your insurer with prompt notice of a claim or loss. No legitimate reason not to. But, if you don’t, it is not an absolute get out of jail free card for your insurer, but it does give them a good argument, which you don’t really want to deal with.
In Gulfpoint Construction Co., Inc. v. Westfield Ins. Co., 2024 WL 1759228 (11th Cir. 2024), an insured appealed a trial court’s ruling that found it did not provide prompt notice to its property insurer as the policy required. In this case, notice was provided two years after a loss from a hurricane. The insurer denied coverage and, in doing so, relied on the insured’s failure to provide prompt notice. Although the trial court agreed, the appellate court found this was a genuine issue of material fact.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com