Fairfield Connecticut Building Expert Directory

Behavioral Science Meets Construction: Insights from Whistle Rewards

September 09, 2024 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business Podcast, Aarni Heiskanen hosts Drew Carter, CEO of Whistle Rewards, and Dr. Laurel Newman, a behavioral scientist, to discuss instant rewards for driving behavioral change in construction. Laurel shares her psychology background and academic career, studying how the environment influences behavior. Drew introduces himself as a data scientist, focusing on predictive modeling. Tune in to learn how they collaborate to create motivating environments in the construction industry. Whistle Rewards is a platform specializing in rewards, recognition, and incentives in the AEC industry. It is designed to enhance employee engagement, safety compliance, performance, and technology adoption in construction companies. The Guests Drew Carter, CEO and Co-Founder at Whistle Systems, Inc. Drew is improving employee retention using data science and behavioral science. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Fourth Circuit Questions EPA 2020 Clean Water Act 401 Certification Rule Tolling Prohibition

August 10, 2021 — Karen C. Bennett - Lewis Brisbois
Last week, in North Carolina Department of Environmental Quality v. Federal Energy Regulatory Commission, the Fourth Circuit Court of Appeals suggested that Congress did not intend for the states, or tribes, to take final action on Clean Water Act (CWA) Section 401 applications within a year of filing. The opinion conflicts with the Environmental Protection Agency's (EPA) 2020 final rule that sought to limit state and tribal certifying authorities’ ability to delay federal projects through various tolling schemes. 85 Fed. Reg. 42210 (Jul. 13, 2020). EPA’s rule, codified in existing regulations, states that the CWA imposes a strict one-year deadline for certification decisions, otherwise certification is waived. However, the Fourth Circuit’s view suggests that this waiver is not triggered in cases where the certifying authority has acted on the application, even if it takes longer than a year to make a final certification decision. The court ultimately decided the case on other grounds, leaving a resolution on the statutory interpretation question for another day. Read the court decision
Read the full story...
Reprinted courtesy of Karen C. Bennett, Lewis Brisbois
Ms. Bennett may be contacted at Karen.Bennett@lewisbrisbois.com

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Massachusetts Clarifies When the Statute of Repose is Triggered For a Multi-Phase or Multi-Building Project

December 07, 2020 — Jeffrey J. Vita & Anna M. Perry - Saxe Doernberger & Vita, P.C.
Lennar Hingham Holdings, LLC (“Lennar”) built a twenty-eight-building, 150-unit condominium project containing twenty-four discrete phases over a seven-year span. The condominium association subsequently brought an action against Lennar and others alleging design and construction defects to four main components of the common elements: “decks and columns,” “roofing/flashing,” “exterior walls/flashing/building envelope,” and “irrigation system.” In response, the defendants argued that the plaintiff’s claims with respect to six of the twenty- eight buildings were barred by Massachusetts’s six-year statute of repose, G. L. c. 206 § 2B. The United States District Court for the District of Massachusetts previously held that all twenty-eight of the condominium’s buildings should be treated as a single improvement for purposes of application of the statute of repose. Subsequently, the court certified the following question to the Massachusetts Supreme Judicial Court: Where the factual record supports the conclusion that a builder or developer was engaged in the continuous construction of a single condominium development comprising multiple buildings or phases, when does the six-year period for an action of tort relating to the construction of the condominium’s common or limited common elements start running? Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and Anna M. Perry, Saxe Doernberger & Vita, P.C. Mr. Vita may be contacted at JVita@sdvlaw.com Ms. Perry may be contacted at APerry@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Arbitration—No Opportunity for Appeal

October 22, 2014 — Craig Martin – Construction Contractor Advisor
Last week I presented to the Great Plains Chapter of the American Society of Professional Estimators on arbitration and litigation. Some of the questions related to the difficulty of appealing an arbitrator’s decision. A Florida appellate court recently confirmed this difficulty. In Village at Dolphin Commerce Center, LLC v. Construction Service Solutions, LLC, a contractor filed an arbitration claim against the owner to get paid for its work. The owner claimed that the contractor could not maintain the claim to get paid because the contractor was not licensed. Apparently, there is a law in Florida that a contractor unlicensed at the time of the contract cannot maintain an action in Florida for unpaid work. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

ASHRAE Seeks Comments by May 26 on Draft of Pathogen Mitigation Standard

May 22, 2023 — James Leggate - Engineering News-Record
ASHRAE, the professional group focused on research and standards development for heating, ventilation, air conditioning and air conditioning systems, is seeking comments on the first draft of a standard for pathogen mitigation, it announced May 15. ASHRAE will accept comments on the public review draft, via osr.ashrae.org, through May 26. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Sixth Circuit Finds No Coverage for Property Damage Caused by Faulty Workmanship

October 21, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Sixth Circuit affirmed the lower court's order granting summary judgment to the insurer who denied a defense for a construction defect claim. Steel Supply & Eng'g Co. v. Illinois Nat'. Ins. Co., 2015 U.S. App. LEXIS 14363 (6th Cir. Aug. 13, 2015). Steel Supply contracted with the Carmel Redevelopment Corporation to fabricate and erect steel for a construction project in Carmel, Indiana. After the steel was erected, an iron worker at the site discovered defects in the steel. Subsequent investigations revealed additional defects. Carmel filed suit against Steel Supply for breach of contract. The complaint alleged that a critical connection that Steel Supply designed was inadequate to handle the forces coming onto it. Carmel claimed that the immediate need to remediate the steel damaged Carmel directly, and that other contractors sought damages from Carmel for harm caused by the delays. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Homeowners Sue Over Sinkholes, Use Cash for Other Things

January 06, 2012 — CDJ STAFF

Quoting one homeowner as saying that his house “can fall in the ground for all I care, I made my money,” the Tampa Bay Times looks at the issue of sinkhole claims in Florida. Homeowners “have paid off mortgages, put in pools, replaced roofs, or otherwise used money from sinkhole claims to do something besides fix sinkhole damage.

It’s been tough for insurance companies. Citizens Property Insurance took in $32 million in premiums for sinkhole coverage in 2010, but paid out $245 million in sinkhole claims. The Tampa Bay Times notes that some of those claims come from settling problems caused by their repairs, including one settlement of $350,000 for repairs to a house worth $39,000.

One couple, after receiving $217,000 from Citizens, sold the house to a company that bought unrepaired sinkhole homes for $190,000. The home has been sold since and remains unrepaired.

Sometimes the preferred solution by the insurance company isn’t the cheapest either. One couple was informed that Citizens was going to spend $150,000 to have the hole filled with grout. After they settled with the insurance company, they fixed the problem by installing steel piers, at a cost of about $45,000.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES