Cambridge Massachusetts Building Expert Directory

Anatomy of a Data Center

October 28, 2024 — Robert A. James & Matt Olhausen - Gravel2Gavel Construction & Real Estate Law Blog
Traditional and social media are thick with reports and predictions of the remarkable increase in size, power consumption and significance of data centers. Not only technology companies but real estate and energy developers, investment funds, lenders, and professionals of all stripes are in or determined to enter this sector. Our inboxes are full—it’s data center this, data center that. But what exactly is a data center? What infrastructure, technology and human resources come together to create and sustain one of these localized points of computation? By understanding their components, we can glean some understanding of the business, public policy and (our focus) legal issues that arise before and during their operation. In this article, we cite key characteristics of a reference Blackacre Data Center, with occasional glances at other (real) structures that offer variations on themes. Blackacre is a composite of several centers we have encountered in our law practice. These facilities differ widely in size, location and functions, so your mileage will vary. Reprinted courtesy of Robert A. James, Pillsbury and Matt Olhausen, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Olhausen may be contacted at matt.olhausen@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Recognized as 2022 Illinois Super Lawyers® and Rising Stars

February 21, 2022 — Traub Lieberman
Traub Lieberman is pleased to announce that two Partners from the Chicago, IL office have been selected to the 2022 Illinois Super Lawyers list. In addition, three Partners have been named to the 2022 Super Lawyers Rising Stars list. 2022 Illinois Super Lawyers

Brian Bassett – Insurance Coverage
Dana Rice – Insurance Coverage

2022 Super Lawyers Rising Stars

Brandt Allen – Insurance Coverage
Jessica Kull – Civil Litigation: Defense
Jeremy Macklin – Insurance Coverage

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Don’t Fall in Trap of Buying the Cheapest Insurance Policy as it May be Bad for Your Business Risks and Needs

March 25, 2024 — David Adelstein - Florida Construction Legal Updates
Don’t fall in the trap of buying the cheapest insurance policy. It will come and bite you in the butt big time! Consult with an insurance broker that understands construction and, importantly, your specific industry, to provide you coverage within your industry. Otherwise, you’ll be paying for a policy that may (i) not be a good policy, and (ii) may provide you minimal to no value for your industry’s RISKS and NEEDS when factoring in exclusions. When procuring insurance, think of the old adage “penny wise and pound foolish,” and don’t make decisions that fit within this adage! The recent decision in Nautilus Ins. Co. v. Pinnacle Engineering & Development, Inc., 2024 WL 940527 (S.D. Fla. 2024) serves as an example. Here, a subcontractor was hired by a general contractor to perform underground utility work for a townhome development which consisted of 57 townhome units included in 18 detached structures. The subcontractor’s underground work was defective which caused damage to the property’s water line, sewer system, plumbing lines, pavers, etc. The general contractor was liable to the owner for this defective work. Although the general contractor was an additional insured under the subcontractor’s commercial general liability (CGL) policy, the subcontractor’s CGL carrier denied the duty to defend and initiated an insurance coverage lawsuit. Motions for summary judgment were filed. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Poor Pleading Leads to Loss of Claim for Trespass Due to Relation-Back Doctrine, Statute of Limitations

April 13, 2017 — Brett G. Moore & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
In Scholes v. Lambirth Trucking Co. (No. C070770, Filed 4/6/2017), the California Court of Appeal for the Third Appellate District held that the relation-back doctrine could not save a property owner’s trespass claim against an adjacent neighbor where the property owner’s original complaint was factually devoid and was later amended to include the trespass claim after the statute of limitations had run. The relation-back doctrine is a well-settled legal principle which allows a plaintiff to amend a complaint to add a cause of action which would otherwise be barred by the statute of limitations. As long as the factual allegations “relate back” to the those alleged in the original complaint, an additional cause of action will not be subject to the applicable statute of limitations. The policy behind statutes of limitation is to put a defendant on notice of the need to defend against a claim in time to prepare an adequate defense. On May 21, 2007, a fire broke out at defendant Lambirth Trucking Company’s (“Lambirth”) soil enhancement facility adjacent to plaintiff Vincent Scholes’ (“Scholes”) property. Scholes had previously notified Lambirth that wood chips and rice hulls were accumulating on his property as a result of Lambirth’s operations. Local authorities also warned Lambirth of the hazards presented by storage of those materials. Reprinted courtesy of Brett G. Moore, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Mr. Moore may be contacted at bmoore@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Blackstone to Buy Chicago’s Willis Tower for $1.3 Billion

March 19, 2015 — Hui-yong Yu – Bloomberg
(Bloomberg) -- Blackstone Group LP agreed to buy Chicago’s Willis Tower, the second-tallest building in the U.S., and plans to upgrade the retail and observatory space in a bet on growth in the city. The price was $1.3 billion, a record for a Chicago office building, according to Blackstone executives. The sellers of the 110-story skyscraper, formerly known as Sears Tower, are a group including New York-based investors Joseph Chetrit and Joseph Moinian, and American Landmark Properties Ltd. Read the court decision
Read the full story...
Reprinted courtesy of Hui-yong Yu, Bloomberg
Ms. Yu may be contacted at hyu@bloomberg.net

Appellate Team Secures Victory in North Carolina Governmental Immunity Personal Injury Matter

January 23, 2023 — Sam Friedman & Christopher Meeks - Lewis Brisbois
Atlanta, Ga. (January 12, 2023) - Atlanta Appellate Partners Seth M. Friedman and Christopher Meeks obtained a significant appellate win on behalf of a city in North Carolina when the North Carolina Court of Appeals reversed the trial court’s denial of the city’s motion for summary judgment. In the underlying case, Lewis Brisbois’ client was sued for injuries that occurred during the construction of a dog park. The city moved for summary judgment on the grounds that it was immune from suit under the doctrine of governmental immunity. The trial court denied the motion and held that the city waived its governmental immunity through the purchase of a liability insurance policy. Lewis Brisbois was subsequently retained to handle the appeal. Before the North Carolina Court of Appeals, Lewis Brisbois argued, on behalf of its client, that well-established North Carolina law, along with a particular provision in the city’s insurance policy, rendered the city immune from the plaintiff’s claims. The appellate court agreed, holding that the city was immune from all liability and entitled to summary judgment on all of the plaintiff’s claims. The court's full opinion can be read here. Reprinted courtesy of Sam Friedman, Lewis Brisbois and Christopher Meeks, Lewis Brisbois Mr. Friedman may be contacted at Seth.Friedman@lewisbrisbois.com Mr. Meeks may be contacted at Christopher.Meeks@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

New-Home Sales in U.S. Unexpectedly Fall to Four-Month Low

January 07, 2015 — Victoria Stilwell – Bloomberg
Purchases of new U.S. homes unexpectedly declined in November to a four-month low, underscoring a lack of momentum this year in residential real estate. Sales dropped 1.6 percent to a 438,000 annualized pace last month following a 445,000 rate in October that was weaker than previously estimated, Commerce Department figures showed today in Washington. The median estimate of 73 economists surveyed by Bloomberg called for a 460,000 pace in November. Read the court decision
Read the full story...
Reprinted courtesy of Victoria Stilwell, Bloomberg
Ms. Stilwell may be contacted at vstilwell1@bloomberg.net

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES