Seattle Washington Building Expert Directory

"My Bad, I Thought It Was in Good Faith" is Not Good Enough - Contractor Ordered to Pay Prompt Payment Penalties

February 23, 2016 — David A. Harris & Jesse M. Sullivan – Haight Brown & Bonesteel LLP
Retention clauses are almost always included in California construction contracts and permit an Owner to withhold a portion of what is owed to the General Contractor as security to ensure the proper completion of the work. General Contractors pass the withholding of retention down to the subcontractors. Thus, if the subcontractor fails to complete its work, or fails to correct deficiencies, the Owner/General Contractor can use the retention to pay the costs of completing or correcting the subcontractor’s work. The contractor must release any retention it receives from the owner within ten days unless a “good faith dispute exists between the direct contractor and the subcontractor.” (Civil Code section 8814.) Where there is a good faith dispute, the contractor “may withhold from the retention to the subcontractor an amount not in excess of 150 percent of the estimated value of the disputed amount.” (Civil Code section 8814(c).) If the contractor wrongfully withholds retention, it must not only pay the retention but must also pay the subcontractor “a penalty of 2 percent per month on the amount wrongfully withheld.” The contractor must also pay the subcontractor’s costs and reasonable attorney’s fees incurred in collecting the retention. (Civil Code section 8818.) Reprinted courtesy of David A. Harris, Haight Brown & Bonesteel LLP and Jesse M. Sullivan, Haight Brown & Bonesteel LLP Mr. Harris may be contacted at dharris@hbblaw.com Mr. Sullivan may be contacted at jsullivan@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Texas School System Goes to Court over Construction Defect

December 30, 2013 — CDJ STAFF
The Zapata County Independent School District filed a lawsuit against Satterfield and Pontikes, claiming construction defect in two schools and two gyms that the company built for the district, according to the Laredo Morning Times. The company built two elementary schools, Zapata South and Fidel & Andrea Villarreal, and the gyms were built at Zapata North and Arturo L. Benavides. The case is scheduled to reach the courtroom in January, 2014. Read the court decision
Read the full story...
Reprinted courtesy of

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

Reservation of Rights Letter Merely Citing Policy Provisions Inadequate

February 14, 2023 — Tred R. Eyerly - Insurance Law Hawaii
In an unpublished opinion, the Fourth Circuit affirmed the district court's finding that the insurers' reservation of rights letters did not provide a basis for denial of coverage. Stoneiedge At Lake Keowee Owners Ass'n Inc. v. Cincinnati Ins. Co., 2022 US. App. LEXIS 34292 (4th Dist. Dec. 13, 2022). The Stoneledge AOAO sued the general contractor Marlick Home Builders, LLC and other defendants after construction of 37 units. The complaint alleged construction defects that resulted in water intrusion and other physical damage. Marlick notified its insurers, Cincinnati Insurance Company and Builders Mutual. Various reservation of rights letter were sent by the insurers. In the underlying case, a judgment was entered against Marlick totalling approximately $1.6 million. As a judgment creditor of Marlickm, Stoneledge sued Cincinnati and Builders Mutual. The district court granted Stonelege's motion for summary judgment, primarily on the ground that the insurers failed to reserve the right to contest coverage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Motion to Dismiss COVID Claim Granted in Part, Denied in Part

February 06, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion to dismiss the insured's claim for business losses due to COVID-19 was granted in part, denied in part. SRL v Zurich Am. Ins Co., 2022 U.S. Dist. LEXIS 210058 (N.D. Ill. Nov. 21, 2022). Excelsior owned and managed the Westin Excelsior Rome, a luxury hotel in Rome. The hotel suffered business income losses with the onset of the pandemic.While the hotel was not forced to close, its bookings decreased to virtually nothing. The Excelsior's complaint alleged that the COVID-19 virus was present in and around the hotel as multiple guests and at least six employees tested positive for COVID-19. It further alleged that the virus attached to interior property and was in the air. Excelsior was insured under a commercial property policy issued by Zurich. The court agreed there was no direct physical loss because no structure suffered damage. Among the coverages under the policy, however, was a "Cancellation of Bookings" provision. Zurich agreed there was coverage under this provision, but argued that Excelsior had already reached its annual limit for Cancellation of Bookings claims. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Miller Wagers Gundlach’s Bearish Housing Position Loses

May 19, 2014 — Alexis Leondis – Bloomberg
Bill Miller said investor Jeffrey Gundlach and real estate billionaire Sam Zell are wrong about housing. Gundlach, the chief executive officer of DoubleLine Capital LP, and Zell, chairman of landlord Equity Residential, predict fewer young people will buy homes, further driving down the U.S. ownership rate. Miller, the stock picker who beat the Standard & Poor’s 500 Index for a record 15 years, said he’s so confident lending and housing will rebound that he’s betting on mortgage insurers, homebuilders and subprime servicers. “Anytime there’s a cataclysm, people always say it’s never going to come back,” said Miller, 64, sitting outdoors at a table overlooking Baltimore’s harbor. “I don’t believe there’s been a secular change in demand for housing. People may just rent longer than they otherwise would have before eventually buying.” Read the court decision
Read the full story...
Reprinted courtesy of Alexis Leondis, Bloomberg
Ms. Leondis may be contacted at aleondis@bloomberg.net

General Contractor/Developer May Not Rely on the Homeowner Protection Act to Avoid a Waiver of Consequential Damages in an AIA Contract

August 04, 2011 — Higgins, Hopkins, McLain & Roswell, LLC

Recently, in Caribou Ridge Homes, LLC v. Zero Energy, LLC, et al., Case No. 10CV1094, Boulder County District Court Judge Ingrid S. Bakke entered a ruling and order on the Plaintiff’s Motion for Determination of Question of Law Pursuant to C.R.C.P. 56(h) on Issue of Damages. The Order found that the Plaintiff was not a homeowner intended to be protected by the Homeowner Protection Act (the “HPA”) and thus could not pursue its claims for consequential damages against Defendant.

By way of background, on June 18, 2008, Plaintiff Caribou Ridge Homes, LLC (“Caribou”) entered into a Standard Form Agreement Between Owner and Contractor AIA Document A114-2001 (the “Contract”) with Defendant Zero Energy, LLC (“Zero Energy”). Plaintiff hired Zero Energy to serve as a general contractor for the construction of a single-family home in the Caribou Ridge subdivision in Nederland, Colorado. A provision in the contract contained a mutual waiver of consequential damages (“Waiver”).

Read the full story…

Reprinted courtesy Higgins, Hopkins, McLain & Roswell, LLC

Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Recognized in the 2022 Edition of The Best Lawyers in America®

September 13, 2021 — Traub Lieberman
Traub Lieberman is pleased to announce that three Partners have been selected by their peers for inclusion in the 2022 edition of The Best Lawyers in America®. In addition, five attorneys have been included in the 2022 Best Lawyers®: Ones to Watch list. These recognitions include attorneys from the firm’s Chicago, IL; Palm Beach Gardens, FL; and St. Petersburg, FL offices. 2022 Best Lawyers®

Brian C. Bassett – Insurance Law

Rina Clemens – Personal Injury Litigation – Defendants

Scot E. Samis – Appellate Practice

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES