Fairfield Connecticut Building Expert Directory

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

Professional Services Exclusion in CGL Policies

December 05, 2022 — David Adelstein - Florida Construction Legal Updates
A professional services exclusion in a commercial general liability policy means something. It’s an exclusion an insurer will rely on to avoid insurance coverage based on “professional services” performed or rendered by the insured. Don’t take it from me. Take it from the recent opinion in Colony Insurance Company v. Coastal Construction Management, LLC, 2022 WL 16636697 (M.D.Fla. 2022) where the trial court granted a commercial general liability insurer’s motion for judgment on the pleadings based on the professional services exclusion. Here, an owner sued, among other parties, an entity performing only construction management services based on construction defects at its project. The construction manager did not perform any design or physical construction. It was hired to make site inspections of the construction, review construction quality and finish standards, ensure workmanship quality, coordinate the punchlist process, and supervise management and administration of the project. The construction manager’s commercial general liability insurer sued for declaratory relief claiming it owed no duty to defend or indemnify based on the professional services exclusion. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Release Language Extended To Successor Entity But Only Covered “Known” Claims

August 06, 2019 — David Adelstein - Florida Construction Legal Updates
A recent case contains valuable analysis that has impact on whether a “successor” entity will be bound by a settlement agreement it was not a direct party to. This case contains arguments for contractors that can be raised in a number of different contexts if it is sued by a successor or related entity. The same case discusses the difference between releasing a party for “known” claims without releasing the same party for “unknown” claims. This is an important distinction because unknown claims refer to latent defects so a release that only releases a party for known claims is not releasing that party for latent defects. In MBlock Investors, LLC v. Bovis Lend Lease, Inc., 44 Fla. L. Weekly D1432d (Fla. 3d DCA 2019), an owner hired a contractor to construct a project. At completion, the owner transferred the project to an affiliated entity (collectively, the “Owner”). The contractor sued the Owner for unpaid work, the Owner claimed construction defects with the work, and a settlement was entered into that released the contractor for KNOWN claims. Thereafter, the Owner defaulted on the construction loan and agreed to convey the property through a deed in lieu of foreclosure to an entity created by the lender (the “Lender Entity”). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer's Summary Judgment Motion on Business Risk Exclusions Fails

November 15, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The insurer unsuccessfully moved for summary judgment on the CGL policy's business risk exclusions. Scottsdale Ins. Co. v. TL Spreader, LLC, (W.D. La. Oct. 20, 2017). Helena Chemical Company contracted with its customer Wild Farms to sell and apply certain herbicides and pesticides to Wild Farms' 123 acre rice filed. Helena subcontracted the TL Spreader, LLC (TLS) to apply the chemicals to Wild Farm's rice field. The TLS employee failed to properly neutralize a chemical being used in the spray. TLS finished its work on May 6, 2014, completing all its work for Helena's contract with Wild Farms. Three days after completion of the spraying, the rice crop first began to exhibit physical damage in the form of abnormal stunting, lesions, yellowing and death. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Subsequent Purchaser Can Assert Claims for Construction Defects

October 17, 2022 — David Adelstein - Florida Construction Legal Updates
Can a subsequent purchaser pursue construction defect claims relating to the original construction of the property? This was the threshold issue on a motion for summary judgment by a drywall manufacturer against a subsequent purchaser of a home in Karpel v. Knauf Gips KG, 2022 WL 4366946 (S.D. Fla. 2022). This matter deals with the defective Chinese drywall that was installed in homes years ago. The plaintiffs, which were subsequent purchasers of a home, sued the manufacturer of the defective drywall for various theories including negligence, negligence per se, strict liability, breach of express and/or implied warranty, private nuisance, unjust enrichment, and Florida’s Deceptive and Unfair Trade Practices Act. The trial court noted, from the onset, that Florida does NOT have a subsequent purchaser rule that prohibits subsequent purchasers from asserting construction defect claims. With this consideration in mind, the trial court went through the claims the plaintiff, as a subsequent purchaser, asserted against the manufacturer to determine whether they were viable claims as a matter of law. Negligence Claim The trial court found that a subsequent purchaser could sue in negligence. “Florida courts have long allowed subsequent purchasers to sue for negligence including in construction defect litigation.” Karpel, supra, at *2. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

California Mediation Confidentiality May Apply to Third Party “Participants” Retained to Provide Analysis

November 02, 2017 — Tony Carucci - Snell & Wilmer Real Estate Litigation Blog
California Evidence Code section 1119 governs the general admissibility of oral and written communications generated during the mediation process. Section 1119(a) provides that “[n]o evidence of anything said or any admission made for the purpose of, in the course of, or pursuant to, a mediation . . . is admissible or subject to discovery, and disclosure of the evidence shall not be compelled, in any . . . civil action . . . .” Cal. Evid. Code § 1119(a) (emphasis added). Similarly, section 1119(b) bars discovery or admission in evidence of any “writing . . . prepared for the purpose of, in the course of, or pursuant to, a mediation . . . .” Cal. Evid. Code § 1119(b) (emphasis added). Finally, section 1119(c) provides that “[a]ll communications, negotiations, or settlement discussions by and between participants in the course of a mediation . . . shall remain confidential.” Cal. Evid. Code § 1119(c) (emphasis added). Read the court decision
Read the full story...
Reprinted courtesy of Tony Carucci, Snell & Wilmer
Mr. Carucci may be contacted at acarucci@swlaw.com

Presidential Memorandum Promotes Reliable Supply and Delivery of Water in the West

November 14, 2018 — Anthony B. Cavender - Gravel2Gavel
In a Memorandum dated October 19, 2018 and entitled Promoting the Reliable Supply and Delivery of Water in the West, the President has directed the Secretaries of the Interior and Commerce to work together to minimize “unnecessary regulatory burdens and foster more efficient decision-making” so that major federal water projects are constructed and operated in a manner that delivers water and power in an “efficient, cost-effective way.” More specifically, they will take steps to streamline the western water infrastructure regulatory processes and remove unnecessary burdens in accordance with the timetables set forth in the Memorandum. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Certificates as Evidence of Additional Insured Coverage Are All the Rage, But You Deserve Better

August 30, 2021 — Joseph L. Cohen, W. Mason & Sean Milani-nia - ConsensusDocs
Consider the following scenario: the construction project is ready to proceed. The deal is done. The agreements have all been carefully crafted, with detailed provisions on insurance dedicated to reducing risk. Those provisions require the downstream trade contractors to furnish certificates of insurance listing the owner and prime contractor as additional insureds on the downstream contractor’s policies of insurance. A provision in the prime contract further requires the prime contractor to provide the owner with a certificate of insurance showing the owner as an additional insured on the prime contractor’s policies. At the ceremonial ground-breaking and right before work commences, the downstream contractors deliver their insurance certificates to the prime contractor and the prime contractor delivers its certificate plus the downstream certificates to the owner. From there, each insurance certificate will begin its final destination to the project file (either electronic or physical) where, with any luck, it will serve the regular stint before being discarded after the project’s successful conclusion. Otherwise, it will be retrieved under much stress and heavy scrutiny. The acceptance of insurance certificates is often viewed as standard industry practice, but should it be? The answer is a resounding “no.” There are many form development and construction agreements in circulation that deem insurance certificates to be acceptable evidence of insurance. But, a certificate of insurance should not be relied upon because it does not mean that insurance has been placed. You deserve real evidence that the requisite additional insured coverage is in place (in the form of a policy endorsement), and here is why. Reprinted courtesy of Joseph L. Cohen, Fox Rothschild, W. Mason, Fox Rothschild and Sean Milani-nia, Fox Rothschild Mr. Cohen may be contacted at jlcohen@foxrothschild.com Mr. Mason may be contacted at wmason@foxrothschild.com Mr. Milani-nia may be contacted at smilani@foxrothschild.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES