Triple Points to the English Court of Appeal for Clarifying the Law on LDs
July 01, 2019 —
Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2GavelCan an employer recover liquidated damages (LDs) from a contractor if the contract terminates before the contractor completes the work?
Surprisingly, heretofore, English law provided no clear answer to this seemingly straightforward question, and inconsistent case law over the past century has left a trail of confusion. Given the widespread use of English law in international construction contracts, this uncertainty had gone on far too long.
The good news is that drafters of construction contracts throughout the world can now have a well-deserved good night’s sleep courtesy of the English Court of Appeal’s March 2019 decision in Triple Point Technology, Inc. v PTT Public Company Ltd [2019] EWCA Civ 230.
The Triple Point case concerned the delayed supply by Triple Point (the “Contractor”) of a new software system to employer PTT. The contract provided for payments upon achievement of milestones, however order forms incorporated into the contract set out the calendar dates on which fixed amounts were payable by PTT, resulting in an apparently contradictory requirements on when payment was due. Triple Point achieved completion (149 days late) of a portion of the work milestones, and were paid for that work. Triple Point then sought payment for the work which was not yet completed, relying on the calendar dates in the order forms rather than achievement of milestone payments. Things got progressively worse as PTT refused payment, Triple Point suspended the work for PTT’s failure to pay, PTT terminated the contract and then appointed a new contractor to complete the work.
Reprinted courtesy of
Vincent C. Zabielski, Pillsbury and
Julia Kalinina Belcher, Pillsbury
Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com
Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Wisconsin Supreme Court Abandons "Integrated Systems Analysis" for Determining Property Damage
September 12, 2023 —
Tred R. Eyerly - Insurance Law HawaiiThe Wisconsin Supreme Court departed from its previous mechanism for determining property damage under the "integrated systems analysis" and found the insurers were not entitled to summary judgment as determined by the trial court. 5 Walworth, LLC v. Engerman Contracting, Inc., 2023 Wis. LEXIS 152 (Wis. June 20, 2023).
5 Walworth LLC hired Engerman as general contractor to construct a swimming pool complex. Engerman subcontracted with Downes Swimming Pool Co., Inc. to construct the pool complex. Otto Jacobs supplied Downes with a ready-mixed concrete called shotcrete, commonly used in swimming poll construction.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Self-Storage Magnates Cash In on the Surge in Real Estate
August 06, 2014 —
Hui-yong Yu – BloombergKelsey Smith is a single mother who works as a waitress in Midvale, Utah, and lives with a roommate in a small apartment in the Sugar House neighborhood of Salt Lake City. Smith, 26, pays $500 a month for daycare for her 3-year-old, which makes it hard to get by on a waitress’s pay. She says she’s had to move to cheaper lodgings six or seven times.
Rather than drag all her belongings with her, Smith rents a 10-foot-by-15-foot (3-meter-by-5-meter) self-storage unit, for which she pays $80 a month -- as much as two shifts’ worth of wages and tips. The unit contains furniture and other items she’s accumulated over the years -- “just the things you’d need if you had a home,” she says. “People don’t want to let go.”
Millions of Americans are like Kelsey Smith, Bloomberg Markets magazine will report in its September issue. They’ve got furniture and old photos, children’s toys and bric-a-brac that they’re loath to give up, yet they can’t find a place for it in their homes, garages or apartments.
Read the court decisionRead the full story...Reprinted courtesy of
Hui-yong Yu, BloombergHui-yong Yu may be contacted at
hyu@bloomberg.net
Newmeyer Dillion Attorneys Named to 2022 Super Lawyers and Rising Stars Lists
July 11, 2022 —
Newmeyer DillionNEWPORT BEACH, Calif. – July 6, 2022 – Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that partner James Ficenec has been selected to the 2022 Norther California Super Lawyers list. Additionally, partner Tara Dudum and associates Brandon Clouse and Jacqueline McCalla have been selected to the 2022 Northern California Rising Stars list by Super Lawyers. Each year, no more than 5 percent and 2.5 percent, respectively, of the lawyers in the state are selected to receive this honor. The attorneys will be recognized in the July 2022 issues of Northern California Super Lawyers Magazine, San Francisco Magazine and Sactown Magazine.
James Ficenec is a partner in the Walnut Creek office. With incredible business acumen, Jim has counseled and defended clients across a variety of industries by advocating for their rights and legal protections as both a transactional attorney and business litigator.
Tara Dudum is a partner in the Walnut Creek Office. Tara's practice focuses primarily on business and employment law and her clients span across industries, including retail, e-commerce, real estate, manufacturing, hospitality, and beyond. She often acts as outside counsel for clients, providing day-to-day legal advice to owners, executives, supervisors, and human resource professionals.
Brandon Clouse is an associate in the Walnut Creek Office. As a part of the firm's construction and real estate litigation group, Brandon litigates disputes on behalf of clients concerning construction and real estate matters.
Jacqueline McCalla is an associate in the Walnut Creek Office. Jacqueline takes pride in assisting local businesses and entrepreneurs as well as Fortune 500 companies with all aspects of litigation, from inception through trial. Jacqueline's practice ranges across business, construction defect, employment and insurance disputes.
Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The patented selection process evaluates candidates on 12 indicators of peer recognition and professional achievement, resulting in a comprehensive, credible and diverse listing of exceptional attorneys. The Rising Stars list is developed using the same selection process except candidates must be either 40 years old or younger, or have been in practice for 10 years or less.
About Newmeyer Dillion
For over 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 60 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's operations, growth, and profits. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
The Clock is Ticking: Construction Delays and Liquidated Damages
September 18, 2023 —
Tiffany Harrod - ConsensusDocsWith the on-going shortage of construction workers in the industry and other factors ranging from weather to procurement problems, the threat of project delay is real. When a contract contains a liquidated damages clause for assessing project delays, real financial consequences for contractors can result. Courts have long allowed parties to apportion contractual risks as they deem appropriate especially in the commercial context where the parties are considered to be sophisticated even if their bargaining power is not equal. Liquidated damage provisions such as those for delay that are found in construction contracts are not unusual but they must be crafted in such a way as to be enforceable and not violate public policy.
A liquidated damage clause in a construction contract is a customary way for the parties to deal with the possibility of delay in the completion of a project and the potential losses flowing from the delay.[
1] In their most basic form, the party in breach, which is more often than not the contractor, is obligated to pay the non-breaching party, usually the project owner, some fixed sum of money for the period that exceeds the designated completion date that was agreed upon in advance and memorialized in the contract. (It is after all no secret that these provisions are primarily for the owner’s benefit.) The non-breaching party is then compensated for losses associated with the delay without the time and expense of having to prove in either a civil suit or an arbitration proceeding what the actual damages are. This option is particularly attractive to project owners because the liquidated damages assessment can simply be withheld from payments owed to the contractor once the agreed-upon completion date has been passed.
Read the court decisionRead the full story...Reprinted courtesy of
Tiffany Harrod, Peckar & AbramsonMs. Harrod may be contacted at
tharrod@pecklaw.com
San Francisco Half-Built Apartment Complex Destroyed by Fire
March 12, 2014 —
Beverley BevenFlorez-CDJ STAFFAccording to San Jose Mercury News, a 250 million dollar apartment complex being built in San Francisco, California received “catastrophic damage” from a fire on March 11th. The complex was being developed by BRE Properties, Inc., and “was slated to open sometime later this year.”
Initial reports blamed high winds for the start of the blaze, however, San Jose Mercury news reported that “downtown San Francisco experienced wind speeds of no more than 10 mph Tuesday, and that heavy winds were not expected Tuesday night” according to the National Weather Service.
“Representatives for [BRE Properties, Inc.] were not available for comment,” as reported by San Jose Mercury News.
Read the court decisionRead the full story...Reprinted courtesy of
Contractor Manslaughter? Safety Shortcuts Are Not Worth It
August 11, 2011 —
Douglas Reiser, Builders Council BlogIt’s been a while since I discussed the importance of safety. But, a recent article on ENR.com compelled this brief article. Don’t shortcut safety — you could be facing serious criminal repercussions.
A New York crane company owner and one of his employees are each facing a second-degree manslaughter charge for the death of two construction workers.  The charges stem from the collapse of a crane in New York City. The district attorney determined that the crane owner cut a few corners to reduce its operation costs, significantly sacrificing safety.
Another example was the 2010 trial of another New York crane operator who was charged with manslaughter. In that case, the criminal charges failed to stick, but an administrative judge found that the contractor used a damaged sling to support the steel collar binding the tower-crane mast to the 18th floor of a high-rise building being constructed. The company also used four slings instead of the eight, as specified by the crane manufacturer; improperly attached the slings and failed to pad or soften them.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Read the court decisionRead the full story...Reprinted courtesy of
Additional Insured Status Survives Summary Judgment Stage
August 26, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe court determined that the insurer was not entitled to summary judgment in seeking a determination that a hotel was not the additional insured under its elevator repair company's policy. Aspen Spec. Ins. Co. v. Ironshore Indem. Inc., 2015 N.Y. Misc. LEXIS 2413 (N.Y. Sup. Ct. July 7, 2015).
Michael Patalano was an elevator repairman employed by Transel Elevator Inc. Transel had a contract to maintain the elevators at Alphonse Hotel. The contract required Transel to name Alphonse as an additional insured on Transel's CGL policy.
Patalano was injured while working at the hotel. He sued Alphonse, alleging that while performing work for the hotel, the stairs he was on which he was descending collapsed, causing him to fall and sustain injuries. Alphonse tendered to Ironshore, Transel's CGL carrier.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
