How Does Your Construction Contract Treat Float
November 08, 2017 —
David Adelstein - Florida Construction Legal UpdatesAlthough there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Texas Supreme Court Cements Exception to “Eight-Corners” Rule Through Two Recent Rulings
March 06, 2022 —
Jeremy S. Macklin - Traub Lieberman Insurance Law BlogThe Texas “eight corners” rule precludes insurers from disclaiming a defense obligation based on facts not alleged in the underlying pleadings. Texas federal and appellate courts have been issuing rulings addressing exceptions to the eight corners rule and recently sought guidance from the Texas Supreme Court on whether Texas law recognizes such exceptions to the “eight corners” rule. The Texas Supreme Court has now spoken on the issue.
Monroe Guar. Ins. Co. v. BITCO Gen. Ins. Corp., 65 Tex. Sup. Ct. J. 440 (2022).
In Monroe, David Jones contracted with 5D Drilling & Pump Services in the summer of 2014 to drill a 3,600-foot commercial irrigation well on his farmland. In 2016, Jones sued 5D for breach of contract and negligence relating to 5D’s drilling operations on Jones’s property. Jones’s pleading was silent as to when the damage flowing from 5D’s alleged acts of misconduct occurred. BITCO and Monroe stipulated that 5D’s drill struck a bore hole during 5D’s drilling operations in or around November 2014.
Read the court decisionRead the full story...Reprinted courtesy of
Jeremy S. Macklin, Traub LiebermanMr. Macklin may be contacted at
jmacklin@tlsslaw.com
Texas Supreme Court Holds that Invoking Appraisal Provision and Paying Appraisal Amount Does Not Insulate an Insurer from Damages Under the Texas Prompt Payment of Claims Act
September 16, 2019 —
John C. Eichman & Grayson L. Linyard - Hunton Insurance Recovery BlogIn two cases decided June 28, 2019, the Texas Supreme Court held that an insurer’s invocation of a contractual appraisal provision after denying a claim does not as a matter of law insulate it from liability under the Texas Prompt Payment of Claims Act (“TPPCA”). But, on the other hand, the court also held that the insurer’s payment of the appraisal award does not as a matter of law establish its liability under the policy for purposes of TPPCA damages.
In Barbara Techs. Corp. v. State Farm Lloyds, No. 17-0640, 2019 WL 2666484, at *1 (Tex. June 28, 2019), State Farm Lloyds issued property insurance to Barbara Technologies Corporation for a commercial property. A wind and hail storm damaged the property, and Barbara Tech filed a claim under the policy. State Farm denied the claim, asserting that damages were less than the $5,000 deductible.
Barbara Tech filed suit against State Farm, including for violation of the TPPCA. Six months later, State Farm invoked the appraisal provision of the policy. More than a year after the suit was filed, appraisers agreed to a value of $195,345.63. State Farm then paid that amount, minus depreciation and the deductible. Barbara Tech amended its petition to include only TPPCA claims.
Reprinted courtesy of
John C. Eichman, Hunton Andrews Kurth and
Grayson L. Linyard, Hunton Andrews Kurth
Mr. Eichman may be contacted at jeichman@HuntonAK.com
Mr. Linyard may be contacted at glinyard@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Traub Lieberman Attorneys Recognized in the 2022 Edition of The Best Lawyers in America®
September 13, 2021 —
Traub LiebermanTraub Lieberman is pleased to announce that three Partners have been selected by their peers for inclusion in the 2022 edition of The Best Lawyers in America®. In addition, five attorneys have been included in the 2022 Best Lawyers®: Ones to Watch list. These recognitions include attorneys from the firm’s Chicago, IL; Palm Beach Gardens, FL; and St. Petersburg, FL offices.
2022 Best Lawyers®
Chicago, IL
- Brian C. Bassett – Insurance Law
Palm Beach Gardens, FL
- Rina Clemens – Personal Injury Litigation – Defendants
St. Petersburg, FL
- Scot E. Samis – Appellate Practice
Read the court decisionRead the full story...Reprinted courtesy of
Traub Lieberman
Construction Warranties: Have You Seen Me Lately?
February 07, 2022 —
Christopher D. Cazenave - ConsensusDocsA construction contract typically contains many different types of warranties. Owners expect contractors to explicitly warrant their workmanship, contractor-provided materials and equipment, and in many instances to assume other warranty risks that may obligate the contractor years after the project is completed.
No contractor wants to be surprised years after a project is completed by the existence of warranty obligations that were not considered or negotiated at the outset of the project. To help avoid this situation, warranties should be treated similar to other critical risk-sharing provisions in the contract in concert with other bargained-for provisions, including for example price and schedule.
This article provides a brief overview of warranty obligations found in typical construction contracts followed by a few practical considerations for contractors to consider when negotiating warranty obligations.
Reprinted courtesy of
Christopher D. Cazenave, Jones Walker, LLP (ConsensusDocs)
Mr. Cazenave may be contacted at ccazenave@joneswalker.com
Read the court decisionRead the full story...Reprinted courtesy of
Taylor Morrison v. Terracon and the Homeowner Protection Act of 2007
June 11, 2014 —
Buck Mann – Colorado Construction LitigationOn January 30, 2014, the Colorado Court of Appeals decided the case of Taylor Morrison of Colorado, Inc. v. Bemas Construction, Inc. and Terracon Consultants, Inc. 2014WL323490. The case addressed a substantial issue of Colorado constitutional law, as well as a variety of procedural issues of potential importance to construction litigation attorneys. Of particular interest is the question of whether the provisions of the 2007 Homeowner Protection Act (“HPA”) are limited in application to contracts between residential homeowners and construction professionals, or whether they have broader application between commercial construction professional parties as well. As discussed below, the Court of Appeals stated that it would not answer the question, and then, separately, implied that the statute might only apply to homeowner transactions – with the resulting exclusion of commercial transactions. However, after its analysis, it left the actual decision of that issue to a future court in a later case.
The factual background for the case involved claims of breach of a contract for soils engineering by Terracon Consultants, Inc. (“Terracon”) and negligent excavation work by Bemas Construction, Inc. (“Bemas”). Plaintiff was Taylor Morrison of Colorado (“Taylor Morrison”), the developer and general contractor for a residential subdivision called Homestead Hills. After it constructed many homes, Taylor Morrison began to receive complaints of cracking drywall resulting from foundation movement and it made repairs at significant expense. Taylor Morrison then filed suit against Terracon and Bemas in connection with their respective roles in the original construction.
Read the court decisionRead the full story...Reprinted courtesy of
Buck Mann, Higgins, Hopkins, McLain & Roswell, LLCMr. Mann may be contacted at
mann@hhmrlaw.com
Anti-Concurrent, Anti-Sequential Causation Clause Precludes Coverage
February 26, 2015 —
Tred R. Eyerly – Insurance Law HawaiiWhere the building was damaged by both a covered cause and a non-covered cause, the policy's anti-concurrent/anti-sequential causation clause barred coverage for a collapsed building. Ashrit Realty LLC v. Tower Nat'l Ins. Co., 2015 N.J. Super. Unpub. LEXIS 107 (N.J. Super. Ct. App. Div. Jan. 20, 2015).
The property sustained moderate damage during a storm on August 14, 2011. More extensive damage was caused by Hurricane Irene two weeks later. After the hurricane, a large hole formed due to the collapse of a pipe which ran underneath the property. Once the pipe collapsed, leaking water caused substantial soil erosion, which led to the collapse of the rear portion of the building.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Changes in the Law on Lien Waivers
November 16, 2020 —
Alan Paulk - Autry, Hall & Cook, LLPAmong many things to look forward to in 2021, we can add a new lien law to the list. Effective January 1, 2021, Georgia’s Lien Statute will be modified so that lien waivers and releases are limited to “waivers and releases of lien and labor or material bond rights and shall not be deemed to affect any other rights or remedies of the claimant.” O.C.G.A. 44-14-366(a). This would mean that lien waivers only waive lien or bond rights and do not waive contractual rights to collect payment.
The new law is in reaction to a decision from the Georgia Court of Appeals in ALA Constr. Servs., LLC v. Controlled Access, Inc., 351 Ga. App. 841 (2019). In that case, a contractor signed an interim lien waiver at the time it submitted an invoice. The contractor did not receive payment, and it failed to timely record an affidavit of non-payment or a claim of lien. Subsequently, the contractor filed suit for breach of contract. The Georgia Court of Appeals held that the statutory form lien waiver was binding against the parties “for all purposes” and not just the purpose of preserving the right to file a lien. By such sweeping logic, the contractor’s breach of contract claim was denied.
Read the court decisionRead the full story...Reprinted courtesy of
Alan Paulk, Autry, Hall & Cook, LLPMr. Paulk may be contacted at
paulk@ahclaw.com