California Expands on Scope of Coverage for Soft Cost Claims
February 14, 2023 —
Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage.
The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project.
As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.Ms. Rabiyan may be contacted at
CRabiyan@sdvlaw.com
Apartment Boom in Denver a Shortcut Around Condo Construction Defect Suits?
September 24, 2013 —
CDJ STAFFFor every condo currently being built in Denver, there are 40 apartment units. And there are some who think that this is being done to evade construction defect lawsuits. At issue is the statute of limitations for construction defects. Under Colorado law, condominium buyers have six years after the completion of constrution to sue for construction defects, unless the defect isn’t discovered until the fifth or six year, in which case they are given until the eighth year. But what if someone built an apartment building, rented out the units for six years, and then converted the whole thing to condominiums?
Some think that the construction defect clock would be reset. Amie Mayhew, the CEO of the Colorado Association of Home Builders noted that if this is the case, “you’d be back at square one.” But Doug Benson, a construction defect attorney, thinks that if a builder did this, and didn’t make any further construction, no one would be able to sue for construction defects, even if the condo owners found them. Mr. Benson, who represents homeowners, said that “they’re apartment homes and that’s just to avoid liability.”
Mike Gifford, the president of the Associated General Contractors of Colorado, noted that insurance companies were already wary of apartment complexes, fearing that they would be turned into condos. Whatever the cause, Denver seems to have a shortage of condos. But, they’re going to have a lot of apartments available.
Read the court decisionRead the full story...Reprinted courtesy of
#10 CDJ Topic: Carithers v. Mid-Continent Casualty Company
December 30, 2015 —
Beverley BevenFlorez-CDJ STAFFCraig Martin of
Lamson Dugan and Murray, LLP on his
Construction Contractor Advisor blog used the Carithers case to demonstrate how “[w]hen you are involved in construction litigation, you have battles on several fronts, including those against subcontractors, owners, insurers and the court. Shoring up your defenses on each of these fronts is imperative, or you may lose the battle or, worse yet, the war.” Martin discusses the various “battle fronts” including the “Claim Against Contractor,” “Where Are You Litigating,” “Claim Against Insurance Company,” and “Damages.”
Read the full story...
In the article, “Duty to Defend Construction Defect Case Affirmed, Duty to Indemnify Reversed In Part,” attorney
Tred R. Eyerly also covered the Carithers case. Eyerly explained, “Determining whether there was coverage for the damages awarded required the court to decide which trigger applied. Examining the policy language, the court determined that property damage occurred when the damage happened, not when the damage was discovered or discoverable. Therefore, the district court did not err in applying the injury in fact trigger.”
Read the full story...
Read the court decisionRead the full story...Reprinted courtesy of
Excess Insurer On The Hook For Cleanup Costs At Seven Industrial Sites
August 28, 2018 —
Lorelie S. Masters & Geoffrey B. Fehling - Hunton Insurance Recovery BlogA New York district court has held that an insurer must provide coverage under three excess insurance policies issued in 1970 for defense and cleanup costs incurred by Olin Corporation in remediating environmental contamination at seven sites in Connecticut, Washington, Maryland, Illinois, New York, and Washington. Seven of the remaining sites at issue presented questions of fact for trial, with only one site being dismissed due to lack of coverage.
Reprinted courtesy of
Lorelie S. Masters, Hunton Andrews Kurth and
Geoffrey B. Fehling, Hunton Andrews Kurth
Ms. Masters may be contacted at lmasters@HuntonAK.com
Mr. Fehling may be contacted at gfehling@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Must Defend Where Possible Continuing Property Damage Occurred
January 13, 2017 —
Tred R. Eyerly - Insurance Law HawaiiThe California Court of Appeal overturned the trial court's issuance of summary judgment based upon the possibility of continuing property damage during the insurer's policy period. Tidwell Enters. v. Fin. Pac. Ins. Co., 2016 Cal. App. LEXIS 1038 (Cal. Ct. App. Nov. 29, 2016).
Financial Pacific insured Greg Tidwell, Tidwell Enterprises, Inc. and Tidwell Enterprises Fireplace Division (Tidwell) under CGL policies issued between March 2003 and March 2010. In 2006 or 2007, Tidwell installed a fireplace in a home. On November 11, 2011, 20 months after the end of the last policy period of Financial Pacific's coverage, the home owned by Kendall Fox, was damaged by fire. Fox was insured by State Farm. State Farm's attorney advised Tidwell of the fire, and Tidwell forwarded the information to Financial Pacific.
State Farm hired an investigator who reported that the fire was caused by the installation of an "unlisted shroud at the top of the chimney chase". This prevented the fireplace from drafting properly, resulting in overheating of the fireplace and heat transfer to the surround wood framing members. This resulted in the ignition of the framing members at the sides, top and bottom of the fireplace. State Farm sent the report to Financial Pacific.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Microsoft Said to Weigh Multibillion-Dollar Headquarters Revamp
September 17, 2015 —
Dina Bass & Hui-Yong Yu - BloombergMicrosoft Corp. is considering a multibillion-dollar revamp of its headquarters campus in suburban Seattle, seeking to foster more collaboration among employees and attract young engineers, according to people with knowledge of the plans.
The software giant has hired architecture firm Skidmore, Owings & Merrill LLP as part of the effort at its Redmond, Washington, offices, said the people, who asked not to be named because the plans aren’t public. Skidmore Owings designed Dubai’s Burj Khalifa, the world’s tallest building, and is helping Microsoft with a makeover of its much smaller campus in Mountain View, California.
Microsoft hasn’t yet decided whether to move forward with the Redmond overhaul, said one of the people familiar with the matter.
Reprinted courtesy of
Dina Bass, Bloomberg and
Hui-Yong Yu, Bloomberg
Read the court decisionRead the full story...Reprinted courtesy of
Connecticut Supreme Court Further Refines Meaning of "Collapse"
January 13, 2020 —
Tred R. Eyerly - Insurance Law HawaiiConnecticut courts have been inundated with collapse cases the past couple of years due to insureds' living in homes that were constructed with defective concrete manufactured by J.J. Mottes Concrete Company. In a duo of cases, the Connecticut Supreme Court responded to a certified question from the U.S. District Court, holding that collapse required that the building be in imminent danger of falling down. Vera v. Liberty Mut. Fire Ins. Co., 2019 Conn. LEXIS 339 (Conn. Nov. 12, 2019).
Plaintiffs had resided in their home since 2009. The home was built in 1993. In August 2015, after learning about the problem of crumbling basement walls affecting homes in their community due to cement manufactured by Mottes, they retained a structural engineer to evaluate their basement walls. The engineer found spider web cracking approximately 1/16 of an inch wide in the basement walls and three small vertical cracks. There were no visible signs of bowing. The engineer did not find that the walls were in imminent danger of falling down, but recommended that the basement walls be replaced.
Plaintiffs submitted a claim under their homeowners policy to Liberty Mutual. The claim was denied. The policy did not define collapse, but stated that collapse did not include "settling, cracking, shrinking, bulging or expansion."
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Strategy for Enforcement of Dispute Resolution Rights
May 30, 2018 —
Whitney Judson - Smith CurrieArbitration and litigation each offer their own benefits and drawbacks to litigants looking to resolve a construction dispute. A careful analysis of these benefits and drawbacks may be helpful in determining whether to avoid or pursue either dispute resolution process. Arbitration is oftentimes regarded as the more economically feasible dispute resolution option and is therefore attractive to many construction dispute litigants. Although arbitration may prove to be less expensive than litigation in the long run, some litigants may prefer to file a case in court because the upfront filing fees in litigation are less expensive than the filing fees of arbitration.
Litigants may also prefer the decision makers of one process for dispute resolution over another. Arbitrators in a construction dispute oftentimes have a background in the construction industry, whereas a judge or jury may not. Strategy may dictate whether the preferable decision maker should have experience within the construction industry or be free of any construction industry knowledge and possible biases. The finality of decisions may also be a reason to strategically choose one dispute resolution process over another. Arbitration decisions are overturned only under very narrow and specific circumstances. The losing party in litigation however, has a right to appeal decisions to a higher court and has more options for recourse when the findings of the court are not supported by the evidence or the law.
Read the court decisionRead the full story...Reprinted courtesy of
Whitney Judson, Smith CurrieMs. Judson may be contacted at
wtjudson@smithcurrie.com