Fairfield Connecticut Building Expert Directory

Tall and Sustainable Is Not an Easy Fix

June 01, 2020 — Christopher G. Hill - Construction Law Musings
Way back in 2009, I discussed the interaction between taller and taller buildings and sustainable (“green”) building. Back then, the reference was to the construction of skyscrapers in the Middle East and Europe. The initially referenced ENR article was written in the context of an urban retrofit of some of Chicago’s taller buildings to make them more sustainable. Just this week, ENR published another article relating to sustainability and super tall buildings. The gist of the article is that while many see taller (rather than wider) as the trend to meld an urban population explosion with more sustainable building practices, this goal is not an easy one to meet. For one, according to the article, energy performance metrics are hard to obtain, both due to the relative newness of these buildings and the seeming reluctance of certain owners to provide the data. Bob Pratt, a managing director in the Shanghai office of developer Tishman Speyer Properties, is quoted in the article, stating

Once we have measuring sticks about performance, we will know what to do” to make buildings sustainable.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrissghill@constructionlawva.com

Congratulations to Associate Madeline Arcellana on Her Selection as a Top Rank Attorney in Southern Nevada!

July 18, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Senior Associate Madeline Arcellana was selected by Nevada Business Magazine as a Top Rank Attorney in Southern Nevada for her work in Civil Litigation, General Liability, and Personal Injury! The lawyers selected to Nevada Business Magazine, Top Rank Attorneys list are at the top of their field and each nomination is put through an extensive verification process, resulting in the top attorneys in Nevada who are chosen by their peers. To view Nevada’s 2022 Top Rank Attorneys, please click here. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

The Clock is Ticking: Construction Delays and Liquidated Damages

September 18, 2023 — Tiffany Harrod - ConsensusDocs
With the on-going shortage of construction workers in the industry and other factors ranging from weather to procurement problems, the threat of project delay is real. When a contract contains a liquidated damages clause for assessing project delays, real financial consequences for contractors can result. Courts have long allowed parties to apportion contractual risks as they deem appropriate especially in the commercial context where the parties are considered to be sophisticated even if their bargaining power is not equal. Liquidated damage provisions such as those for delay that are found in construction contracts are not unusual but they must be crafted in such a way as to be enforceable and not violate public policy. A liquidated damage clause in a construction contract is a customary way for the parties to deal with the possibility of delay in the completion of a project and the potential losses flowing from the delay.[1] In their most basic form, the party in breach, which is more often than not the contractor, is obligated to pay the non-breaching party, usually the project owner, some fixed sum of money for the period that exceeds the designated completion date that was agreed upon in advance and memorialized in the contract. (It is after all no secret that these provisions are primarily for the owner’s benefit.) The non-breaching party is then compensated for losses associated with the delay without the time and expense of having to prove in either a civil suit or an arbitration proceeding what the actual damages are. This option is particularly attractive to project owners because the liquidated damages assessment can simply be withheld from payments owed to the contractor once the agreed-upon completion date has been passed. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Harrod, Peckar & Abramson
Ms. Harrod may be contacted at tharrod@pecklaw.com

Newmeyer & Dillion Attorney Casey Quinn Selected to the 2017 Mountain States Super Lawyers Rising Stars List

June 15, 2017 — Newmeyer & Dillion LLP
LAS VEGAS, Nev. – JUNE 14, 2017 – Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that litigation attorney Casey Quinn has been selected to the 2017 Mountain States Super Lawyers Rising Stars list. Each year, no more than 2.5 percent of lawyers are selected to receive this honor. Quinn will be recognized in the July 2017 issue of Mountain States Super Lawyers Magazine. Quinn, an associate in the Las Vegas office of Newmeyer & Dillion, focuses his practice in complex commercial and construction litigation. He represents a variety of business entities in commercial disputes, including contract claims, business torts, privacy lawsuits, defamation, and fraud. Quinn is the immediate-past chair of the Construction Law section of the State Bar of Nevada and has successfully argued before the Supreme Court of Nevada, as well as settled disputes through various forms of conflict resolution including mediation and arbitration. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high-degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations and peer evaluations. About Newmeyer & Dillion For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit http://www.newmeyeranddillion.com/. Read the court decision
Read the full story...
Reprinted courtesy of

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Contingent Business Interruption Claim Denied

April 08, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The insured's claim for contingent business interruption ("CBI") coverage was denied in Millennium Inorganic Chemicals Ltd. v. Nat. Union Fire Ins. Co. of Pittsburgh Pa., 2014 U.S. App. LEXIS 3096 (4th Cir. Feb. 20, 2014). Millenium processed titanium dioxide, a compound used for its white pigmentation, at its plant in Western Australia. Millennium purchased natural gas to process the titanium dioxide from Alinta Sales Pty Ltd., a natural gas supplier. Alinta purchased gas from Apache Corporation. Once Apache processed the natural gas, it was injected into a pipeline. The gas from Apache's facility was commingled with that obtained from other producers, resulting in a mix of gas in a single pipeline. Alinta had sole ownership of the gas once it entered the pipeline. Under Alinta's contract with Millennium, title to the gas passed to Millenium only at the time of delivery, i.e., when the gas left the pipeline and was delivered to Millennium's facility through a separate delivery line. Millennium had no contract or business relationship with Apache, and the contract it had with Alinta made no reference to Apache. An explosion occurred at Apache's facility causing its natural gas production to cease. As a result, Millennium's gas supply was curtailed, and it was force to shut down its operations for a number of months. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Real Estate & Construction News Roundup (5/8/24) – Hotel Labor Disputes, a Congressional Real Estate Caucus and Freddie Mac’s New Policies

June 04, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, nonresidential construction increases, Redfin settles lawsuits, overseas real estate becomes more lucrative than domestic real estate, and more!

High inflation and a disappointing report on economic growth — followed by a sudden drop in stocks late last month — show similar signs to the 1970s when the housing market stagnated, and the decade itself became synonymous with stagflation. (Gabriella Cruz-Martinez, Yahoo)
American investors have figured out that buying property overseas can be both affordable and lucrative, with some countries offering “golden visas” to foreign investors who make large real estate investments in their country. (Jordan Rosenfeld, Yahoo)
Nonresidential construction spending ticked up 0.2% in March to a seasonally adjusted annual rate of $1.19 trillion. (Sebastian Obando, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Ohio Supreme Court Rules That Wrongful Death Claims Are Subject to the Four-Year Statute of Repose for Medical Claims

January 16, 2024 — Lewis Brisbois Newsroom
Cleveland, Ohio (January 2, 2024) - In a landmark 4-3 ruling, the Supreme Court of Ohio ruled on December 28 that wrongful death claims are subject to the four-year statute of repose contained in O.R.C. 2305.113(C) (“Medical Claim Statute of Repose”). Everhart v. Coshocton County Memorial Hospital, Slip No. 2023-Ohio-4670. Statutes of repose create an absolute bar to filing a lawsuit. When applicable, they bar plaintiffs from filing claims outside a specified time frame. The Medical Claim Statute of Repose creates a four-year window for commencing medical claims, which begins to run from “the occurrence of the act or omission constituting the alleged basis of the medical…claim.” O.R.C. 2305.113(C)(1). Medical claims commenced after the four-year period are barred. The primary question before the Court was whether a wrongful death claim, which is separate and distinct from a medical negligence claim, can qualify as a “medical claim” within the context of the Medical Claim Statute of Repose. The Court answered in the affirmative. A wrongful death claim can qualify as a medical claim if the wrongful death claim “…arises out the medical diagnosis, care, or treatment, of any person.” O.R.C. 2305.113(E)(3). According to the majority, a wrongful death claim can fall within the broad definition of “medical claim” and, if it does, is subject to the Medical Claim Statute of Repose. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES