Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor
September 09, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project.
In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Don’t Be Lazy with Your Tenders
October 24, 2022 —
Rick Erickson - Snell & Wilmer Real Estate Litigation BlogOur clients probably spend significant time, money and effort refining and updating their contract provisions covering indemnification and the duty to defend claims arising on their projects. But they should also consider spending an appropriate and adequate amount of time, money and effort when sending notices, or “tenders,” to enforce those critical provisions. Tenders demanding defense and indemnity are strictly interpreted based on what the contract documents require. Getting tenders wrong can result in losing one of the most significant risk-shifting tools in the contract. It can also be a monumental mistake if insurance coverage for indemnification damages and defense costs are lost because of an inadequate tender.
The legal definition of “tender” is simple; it is “[a]n unconditional offer of money or performance to satisfy a debt or obligation.” Black’s Law Dictionary 1479-80 (7th ed. 1999). Whereas “tender of defense” for insurance is “the act in which one party places its defense and all costs associated with said defense with another due to a contract or other agreement … [which] transfers the obligation of the defense and possible indemnification to the party to which the tender was made.” Int’l Risk Mgmt. Inst., Glossary. Thus, when claims arise on your projects, notice by tenders of defense and indemnity will often determine dispute resolution and available insurance proceeds.
Read the court decisionRead the full story...Reprinted courtesy of
Rick Erickson, Snell & WilmerMr. Erickson may be contacted at
rerickson@swlaw.com
Connecticut Supreme Court Finds Faulty Work By Subcontractor Constitutes "Occurrence"
July 31, 2013 —
Tred Eyerly, Insurance Law HawaiiThe U.S. District Court in Alabama certified a question to the Connecticut Supreme Court: Is damage to a project caused by faulty workmanship "property damage" resulting from an "occurrence"? With some qualification, the Connecticut Supreme Court answered in the affirmative. Capstone Building Corp. v. Am. Motorists Ins. Co., SC 18886 (Conn. June 11, 2013).
Captsone Development agreed to coordinate and supervise construction on a building at the University of Conneticut. Capstone Building was the general contractor. UConn secured an OCIP policy from American Motorist Insurance Company ("AMICO"). More than three years after completion, UConn notified the insureds of alleged defects in the project, including elevated levels of carbon monoxide. The source of the leak was the individual hot water heaters in residential units and insufficient draft of exhaust from the heater.Other defects were found during an investigation.
The insureds tendered to AMICO. Coverage was denied because the liability arose out of the insureds' own work.The insureds settled with UConn, paying $1 million each. The insureds then sued AMICO in Alabama and the question was certified to the Connecticut Supreme Court.
Read the court decisionRead the full story...Reprinted courtesy of
Tred EyerlyTred Eyerly can be contacted at
te@hawaiilawyer.com
Reasonableness of Denial of Requests for Admission Based Upon Expert’s Opinions Depends On Factors Within Party’s Understanding
February 27, 2019 —
Stephen M. Tye & Lawrence S. Zucker II - Haight Brown & Bonesteel LLPIn Orange County Water District v. The Arnold Engineering Company (D070763), the Fourth Appellate District examined the criteria for evaluating the reasonableness of a parties’ denial of requests for admission (RFA’s) based upon their expert’s opinions and the proof required to recover costs for unreasonable denials.
In Orange County Water District, the Orange County Water District (the District) sued several current and former owners and operators of industrial sites, including The Arnold Engineering Company (Arnold), to recover expenses associated with groundwater cleanup efforts intended to address groundwater contamination caused by volatile organic compounds (VOC’s) and other chemicals. Over six years, the parties conducted extensive discovery, including document productions, depositions, and soil sampling and monitoring.
Reprinted courtesy of
Stephen M. Tye, Haight Brown & Bonesteel LLP and
Lawrence S. Zucker II, Haight Brown & Bonesteel LLP
Mr. Tye may be contacted at stye@hbblaw.com
Mr. Zucker may be contacted at lzucker@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Language California Construction Direct Contractors Must Add to Subcontracts Beginning on January 1, 2022, Per Senate Bill 727
December 20, 2021 —
William L. Porter - Porter Law GroupSenate Bill No. 727, Imposing Liability on Contractors for Wage Claims of Subcontractor Employees:
California Senate Bill 727 was approved by the Governor on September 27, 2021. The new Act amended Labor Code Section 218.7 and added a new section 218.8 to the Labor Code. Both Labor Code sections impose on “direct contractors” in the construction industry (defined by Civil Code 8018 as “a contractor that has a direct contractual relationship with an owner”) liability for the wage violations of their subcontractors and sub-subcontractors at any tier when working on California private construction projects.
Specifically, new Section 218.8 expands the liability of direct contractors for wage claims of the employees of subordinate subcontractors on projects for contracts executed beginning on January 1, 2022. The liability of the direct contractor under Labor Code 218.8 will include “any debt owed to a wage claimant or third party on the wage claimant’s behalf, incurred by a subcontractor at any tier acting under, by, or for the direct contractor.” Specifically included as listed liabilities of the direct contractor are: “any unpaid wage, fringe or other benefit payment or contribution, penalties or liquidated damages, and interest owed by the subcontractor on account of the performance of the labor.”
Read the court decisionRead the full story...Reprinted courtesy of
William L. Porter, Porter Law GroupMr. Porter may be contacted at
bporter@porterlaw.com
Real Estate & Construction News Round-Up 05/04/22
May 23, 2022 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogConstruction payment apps are on the rise, the European Union proposes to block Russians from buying European real estate, warehouse vacancy rates hit a 27-year low, and more.
- The Metaverse Group has made itself one of the most prominent virtual land owners, having invested more than $10 million into digital real estate purchases. (Katie Canales, Business Insider)
- The European Union proposed to block Russians from buying European real estate in its six package of sanctions following Russia’s invasion of Ukraine. (Jorge Valero and Alberto Nardelli, Bloomberg)
- Although smart office buildings are able to easily identify viruses, they are susceptible to hacks, raising privacy and cybersecurity concerns in the market. (Konrad Putzier, The Wall Street Journal)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
CGL Insurer’s Duty To Defend Broader Than Duty To Indemnify And Based On Allegations In Underlying Complaint
April 10, 2019 —
David Adelstein - Florida Construction Legal UpdatesThe duty to defend an insured with respect to a third-party claim is broader than the duty to indemnify the insured for that claim. The duty to defend is triggered by allegations in the underlying complaint. However, an insurer is only required to indemnify its insured for damages covered under the policy. A recent case example demonstrating the duty to defend is broader than the duty to indemnify can be found in Southern Owners Ins. Co. v. Gallo Building Services, Inc., 2018 WL 6619987 (M.D.Fla. 2019).
In this case, a homebuilder built a 270-unit condominium project where the units were included in 51-buildings. Upon turnover of the condominium association to the unit owners, the condominium association served a Florida Statutes Chapter 558 Notice of Construction Defects letter. There was numerous nonconforming work spread out among various subcontractor trades including nonconforming stucco work. The homebuilder incurred significant costs to repair defective work and resulting property damage, and relocated unit owners during repairs. The homebuilder then filed a lawsuit against implicated subcontractors. One of the implicated subcontractors was the stucco subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Newmeyer Dillion Named 2023 Best Law Firm in Multiple Practice Areas By U.S. News-Best Lawyers
November 07, 2022 —
Newmeyer DillionNEWPORT BEACH, Calif. – November 3, 2022 – Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that U.S. News-Best Lawyers® has recognized the firm in its 2023 "Best Law Firms" rankings, in seven practice areas earning the highest ranking possible - Tier 1 in the Orange County Metro area. The practices recognized include:
Commercial Litigation
Construction Law
Insurance Law
Litigation - Construction
Litigation - Insurance
Litigation - Real Estate
Real Estate Law
Additionally, the firm has been recognized as Tier 2 in Employment Law - Management and Tier 3 in Litigation - Labor & Employment.
"Newmeyer Dillion prides itself on genuinely partnering with our clients to offer business-oriented solutions for their legal issues," said Managing Partner Paul Tetzloff. "Receiving this honor shows that our clients appreciate the quality of our work and our team's dedication to their organization's success."
Firms included in the 2023 "Best Law Firms" list have been recognized by their clients and peers for their professional excellence. Firms achieving a Tier 1 ranking have consistently demonstrated a unique combination of quality law practice and breadth of legal expertise.
To be eligible for the "Best Law Firms" ranking, a firm must have at least one attorney recognized in the current edition of The Best Lawyers in America for a specific practice area. Best Lawyers recognizes the top 4 percent of practicing attorneys in the U.S., selected through exhaustive peer-review surveys in which leading lawyers confidentially evaluate their professional peers.
About Newmeyer Dillion
For over 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 60 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's operations, growth, and profits. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
