Cambridge Massachusetts Building Expert Directory

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Massachusetts Roofer Killed in Nine-story Fall

January 08, 2019 — Johanna Knapschaefer - Engineering News-Record
A 41-year-old roofer from Haverhill, Mass. fell through a roof hole nine stories to his death on Dec. 18 while working on an apartment building project in Haverhill, a city north of Boston. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Production of Pre-Denial Claim File Compelled

November 30, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The appellate court found that the claims file that existed before the insurer's denial was discoverable. Cascade Builders Corp. v. Rugar, 2017 N.Y. App. Div. LEXIS 7357 (N.Y. App. Div.. Oct. 19, 2017). Cascade Builders was the general contractor for the homeowners. In May 2011, Cascade subcontracted with John Rugar to perform certain exterior power washing on the residence. The contract between Cascade and Rugar required Rugar to indemnify and hold Cascade harmless for any work performed by Rugar and to obtain coverage naming Cascade as an additional insured. Rugar procured the required CGL policy from Utica First Insurance Company. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Federal Court Asks South Dakota Supreme Court to Decide Whether Injunction Costs Are “Damages,” Adopts Restatement’s Position on Providing “Inadequate” Defense

August 13, 2019 — Anthony L. Miscioscia & Timothy A. Carroll - White and Williams LLP
Do costs associated with complying with an injunction constitute covered “damages?” The U.S. District Court for the District of South Dakota recently certified that question to the South Dakota Supreme Court, in Sapienza v. Liberty Mutual Fire Insurance Company, No. 3:18-CV-03015-RAL, 2019 U.S. Dist. LEXIS 84973 (D.S.D. May 17, 2019). If the South Dakota Supreme Court takes on the question, it will become one of the few highest state courts to do so.[1] The Sapienza case is also notable because the court adopted § 12 of the Restatement of the Law of Liability Insurance (Restatement) regarding an insurer’s potential liability for providing an “inadequate” defense. In doing so, the Sapienza court joins a growing list of courts to rely upon or cite to the Restatement. The Sapienza case arose out of an underlying dispute between residential neighbors over the size and location of the Sapienzas’ new house they built in a historic district in Sioux Falls, SD. The newly-built house allegedly prevented the neighbors from using their fireplace, blocked natural light the neighbors previously enjoyed, and decreased the value of the neighbors’ house. The neighbors sought a permanent injunction requiring the Sapienzas to modify or relocate the house. The Sapienzas’ homeowners’ insurer provided them with defense counsel, but the insurer instructed the Sapienzas that it would not cover any costs associated with an injunction as such costs did not constitute covered “damages.” Reprinted courtesy of Timothy Carroll, White and Williams LLP and Anthony Miscioscia, White and Williams LLP Mr. Schulman may be contacted at carrollt@whiteandwilliams.com Mr. Anderson may be contacted at misciosciaa@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Safety Accusations Fly in Dispute Between New York Developer and Contractor

July 01, 2019 — Richard Korman - Engineering News-Record
The developer of a New York City high rise and the project's former prime contractor are trading unusually nasty safety related accusations in a dispute over the contractor's exit from the project. The contractor, New York City-based Pizzarotti, claims the settlement of the structure in soft soils creates hazards in future work that could send building components crashing to the streets. In reply, developer Fortis Property Group says the contractor’s uneven pace of work is to blame for what it sees as only slab misalignments that don’t compromise safety in any way. Read the court decision
Read the full story...
Reprinted courtesy of Richard Korman, ENR
Mr. Korman may be contacted at kormanr@enr.com

After Breaching its Duty to Defend, Insurer Must Indemnify

August 11, 2011 — Tred R. Eyerly - Insurance Law Hawaii

In a brief decision analyzing Oregon law, the Ninth Circuit determined that once an insurer breaches its duty to defend, it must indemnify.Â See Desrosiers v. Hudson Speciality Ins. Co., 2011 U.S. App. LEXIS 12591 (9th CIr. June 21, 2011).

The victim secured a judgment against the insured after he was beaten by another patron outside the insured's bar. Hudson Speciality Insurance refused to defend the insured, claiming the injury arose from an assault and battery, which excluded coverage.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

How to Remove a Mechanics Lien from Your Property

March 21, 2022 — Hannah Kreuser - Porter Law Group
It sometimes happens that a contractor or material supplier records a mechanics lien on your property that becomes expired. Other times, the mechanics lien may be wrong, invalid and unenforceable for some reason, serving no legitimate purpose. The contractor or material supplier may be reasonable and release the mechanics lien once these issues are brought to its attention, but the contractor or material supplier may very well refuse to release the mechanics lien when requested. When this happens, what are your options? In California, there are various ways to bring this type of mechanics lien to a court’s attention in the hopes that the court will cause it to be released. Three of the more common methods are: (1) a petition under California Civil Code (“CCC”) § 8480; (2) a petition under California Code of Civil Procedure (“CCP”) § 765.010; or (3) a Lambert motion. This article will briefly discuss each of these methods. Read the court decision
Read the full story...
Reprinted courtesy of Hannah Kreuser, Porter Law Group
Ms. Kreuser may be contacted at hkreuser@porterlaw.com

New Home Permits Surge in Wisconsin

October 10, 2013 — CDJ STAFF
September saw a 42% increase in the number of permits issued to build new homes in the metro areas of Wisconsin. MTD Marketing Services of Wisconsin described it as “another good month as starts continue to increase across the state.” In September 2012, 266 permits were issued, while September 2013 saw that increase to 378. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES