FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Maryland Legislation Prohibits Condominium Developers from Shortening Statute of Limitations to Defeat Unit Owner Construction Defect Claims

May 16, 2018 — Nicholas D. Cowie - Maryland Condo Construction Defect Law Blog
New Maryland legislation prevents developers from shortening the time period within which condominium associations and their unit owner members can assert claims for hidden construction defects in newly constructed condominium communities. The legislation known as HB 77 and SB 258 passed both houses of the Maryland General Assembly and was signed into law by Governor Lawrence J. Hogan on April 24, 2018 (see photo above). Nicholas D. Cowie, Esq. is the author of the legislation, which will be codified as Section 11-134.1 of the Maryland Condominium Act, effective October 1, 2018. This article discusses how this new legislation ends the practice by which some condominium developers attempted to use condominium documents to shorten the normal statute of limitations in order to prevent condominium associations and their unit owner members from having a fair opportunity to assert their warranty and other legal claims for latent construction defects. Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Esq., Cowie & Mott
Mr. Cowie may be contacted at ndc@cowiemott.com

---

Alabama “occurrence” and subcontractor work exception to the “your completed work” exclusion

November 18, 2011 — CDCoverage.com

In Town & Country Property, LLC v. Amerisure Ins. Co., No. 1100009 (Ala. Oct. 21, 2010), property owner Town & Country contracted with insured general contractor Jones-Williams for the construction of a car dealership. All of the construction work was performed by Jones-Williams subcontractors. After completion, Town & Country sued Jones-Williams for defective construction. Jones-Williams’ CGL insurer Amerisure defended. The case was tried and a judgment was entered against Jones-Williams in favor of Town & Country. After Amerisure denied any obligation to pay the judgment, Town & Country sued Amerisure in a statutory direct action.

Read the full story…

Reprinted courtesy of CDCoverage.com.

Read the court decision
Read the full story...
Reprinted courtesy of

---

Effects of Amendment to Florida's Statute of Repose on the Products Completed Operations Hazard

November 06, 2018 — Richard W. Brown & Grace V. Hebbel - Saxe Doernberger & Vita, P.C.
Recent amendments to Florida’s Statute of Repose have resulted in concerns as to the scope of risk Florida homebuilders face as a result, and the availability of insurance coverage for such exposures. Previously, the statute provided for a strict, yet straightforward 10-year limitation for latent construction defect claims. Under that language, issues arose when suits were filed near expiration of the statute, because parties seeking to defend claims were given little time to effectively assert related claims. The amendment to the statute serves to lengthen the statute of repose to 11 years for certain cross-claims, compulsory counterclaims, and third-party claims, and in limited circumstances, potentially even longer. Most policies in the Florida marketplace serve to limit coverage under the products-completed operations hazard (“PCO”) to 10 years, and thus, in very limited circumstances, an insured contractor may be exposed to third-party claims under the revised statute. It is important to note, however, that coverage under most CGL policies is occurrence-based, meaning that the policy is triggered by property damage that occurs during the policy period, and therefore, any subsequent claims permitted under the amended statute will necessarily relate to the original property damage that occurred during the 10-year period, and thus, would be covered under the standard 10-year PCO extension. This paper will analyze the anticipated effect of the amendments upon coverage under a 10-year PCO extension. Reprinted courtesy of Richard W. Brown, Saxe Doernberger & Vita P.C. and Grace V. Hebbel, Saxe Doernberger & Vita P.C. Mr. Brown may be contacted at rwb@sdvlaw.com Ms. Hebbel may be contacted at gvh@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

No Coverage for Property Damage That is Limited to Work Completed by Subcontractor

April 25, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The issue before the 11th Circuit was whether, under Florida law, a general contractor had coverage for a property damage claim limited to the defective work performed by a subcontractor, and not affecting any other portion of the project. The court found no coverage in Amerisure Mut. Ins. Co. v. Auchter Co., 2012 U.S. App. LEXIS 5412 (11th Cir. March 15, 2012).



Amelia Island Company contracted with Auchter Company, a general contractor, for construction of an inn and conference room. Auchter subcontracted with Register Contracting Company to install the Inn’s roof. Pursuant to the Florida Building Code, installation of the roof required that it be able to withstand 110 m.p.h. winds.



Register completed installing the roof tiles in January 1998. Beginning in 2002, the tiles began dislodging from the roof. During the 2004 hurricane season, three hurricanes caused more tiles to come off the roof. Some of these tiles hit other tiles, cracking them.



In 2006, the parties went to arbitration over the costs of repairs for the roof.



Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

Hundreds of Snakes Discovered in Santa Ana Home

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
404 Snakes—more than half dead—were discovered after a “nearly daylong search” in a home in Santa Ana, California, reported the Los Angeles Times. “Over the past few months, neighbors called authorities about the foul odor,” claimed the Orange County Register. “They thought it was trash. Then Jehovah’s Witnesses knocked on the door.” Concerned that someone might have died, they called the police. William Buchman, the homeowner, “identified as a snake breeder, was arrested on suspicion of animal cruelty, a felony,” according to the Los Angeles Times. Police wore gas masks and “clutched Tasers” as they entered the home. “Rats scampered over furniture and scores of clear plastic boxes holding the snakes lined the walls.” The Orange County Register claimed that up until recently Bachman was a “regular joe.” A neighbor said, “Let me tell you, Bill was a nice guy, outspoken, knowledgeable. He talked to my grandkids about school.” According to the Los Angeles Times, Buchman’s mother died in 2011, which appeared to “have affected him profoundly.” Read the full story at The Los Angeles Times... Read the full story at The Orange County Register... Read the court decision
Read the full story...
Reprinted courtesy of

---

Skanska Will Work With Florida on Barge-Caused Damage to Pensacola Bay Bridge

October 19, 2020 — Jim Parsons - Engineering News-Record
Florida Dept. of Transportation investigators continue to assess damage to the Pensacola Bay Bridge, which sustained multiple impacts from two construction barges unmoored by Hurricane Sally’s storm-driven waves on Sept. 15. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Patrick Haggerty Promoted to Counsel

May 24, 2021 — Patrick Haggerty - White and Williams LLP
White and Williams is pleased to announce the promotion of Patrick Haggerty to the position of Counsel. Pat is a member of the Real Estate and Finance groups and practices in the Philadelphia office. Pat focuses his practice on a wide range of commercial real estate transactions and financings. He represents real estate developers, owners, and investors, international and domestic banks, private equity firms, hedge funds, and insurance companies in the financing, acquisition, development, repositioning and disposition of commercial real estate assets. “Pat’s unique skillset and impressive experience enhances the services which we can provide to our real estate and finance clients. We are proud to promote such a talented lawyer,” said Tim Davis, Chair of the Business Department. “We look forward to his continued success.” Read the court decision
Read the full story...
Reprinted courtesy of Patrick Haggerty, White and Williams LLP
Mr. Haggerty may be contacted at haggertyp@whiteandwilliams.com

---