Cambridge Massachusetts Building Expert Directory

Seven Key Issues for Construction Professionals to Consider When Dealing With COVID-19

April 13, 2020 — Jason Adams - Linked In
By now every construction professional has been inundated with articles regarding the impacts of COVID-19 on the construction industry. The sheer volume of information is overwhelming and changes by the hour. This article is intended to summarize key issues affecting construction professionals and serve as a general road map for navigating the crisis. 1. Determine Project Status The first consideration is whether the construction projects at issue are allowed to proceed given “shelter in place” and related orders. Generally speaking, Governor Newsom has deemed construction to be essential and, therefore, exempt from California’s “Safer at Home” order. There is some debate as to whether the governor’s order takes priority over contradictory local (City and County) orders. For example, some Northern California counties and the City of Berkeley have issued orders expressly providing that their local orders legally supersede the State order because the local orders are more restrictive. If a local ordinance, public entity representative, or the project owner orders the project to shut down, the parties will need to make a fact specific determination regarding how to proceed at that time. If the project proceeds, employee safety is paramount. In the City of Los Angeles employers are required to develop a “comprehensive COVID-19 exposure control plan” that includes a laundry list of safety requirements. Regardless of the jurisdiction, the parties must err on the side of caution and comply with social distancing (six feet), refrain from holding meetings, and close the project to the public. Anyone who can work remotely should be encouraged to do so. Read the court decision
Read the full story...
Reprinted courtesy of Jason Adams, Gibbs Giden
Mr. Adams may be contacted at jadams@gibbsgiden.com

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

One World Trade Center Tallest Building in US

November 13, 2013 — CDJ STAFF
It’s official! The tallest building in the United States is in New York. For forty years, the tallest building in the United States has been the Willis Tower in Chicago (better known by its former name, the Sears Tower). Now, the Council on Tall Buildings and Urban Habitat has decreed that One World Trade Center edges it out with its 1,776 feet of height, surpassing the Willis by 325 feet. There is a caveat. The antennas on the top of the Willis building aren’t counted in. The mast on the top of One World Trade Center is, and it adds 441 feet to the height of the building. If the mast weren’t counted, One World Trade Center would be 116 feet shorter than the building in Chicago. Read the court decision
Read the full story...
Reprinted courtesy of

Domingo Tan Receives Prestigious Ollie Award: Excellence in Construction Defect Community

May 28, 2024 — Wood Smith Henning & Berman
(Anaheim, CA.) - Wood Smith Henning & Berman is thrilled to announce that Domingo Tan, a partner in the Los Angeles office, has been awarded the prestigious Jerrold S. Oliver Award of Excellence. Fondly known as the "Ollie", this esteemed accolade is presented annually to a standout professional in the construction defect community who has demonstrated exceptional contributions and unwavering dedication to the field. The exciting announcement of Tan's victory took place during the 30th Anniversary of the West Coast Casualty Construction Defect Seminar in Anaheim. Widely recognized as the nation's largest conference for professionals handling construction defect matters, the event drew a remarkable gathering of general counsel, risk managers, claim professionals, and attorneys who actively participated in the nomination and voting process. The Ollie award pays tribute to the late Judge Jerrold S. Oliver, a highly respected legal professional renowned for his groundbreaking work in alternate dispute resolution methods for construction defect disputes. It celebrates individuals who embody the values of loyalty, commitment, and trust within the industry. Read the court decision
Read the full story...
Reprinted courtesy of Wood Smith Henning & Berman

Manhattan Site for Supertall Condo Finds New Owner at Auction

December 15, 2016 — Oshrat Carmiel – Bloomberg
A development site slated for an almost 1,000-foot condo tower on Manhattan’s far east side found a new owner through a bankruptcy auction Tuesday, removing a hurdle for construction after about a year of delays. Gamma Real Estate, the lender to the project, won the auction with a credit bid of $86 million and is poised to take control of the site, pending approval from the bankruptcy court, said David Schechtman, a broker with Meridian Investment Sales, which handled the auction with another brokerage. Read the court decision
Read the full story...
Reprinted courtesy of Oshrat Carmiel, Bloomberg
Mr. Carmiel can be followed on Twitter @OshratCarmiel

California Court of Appeals Says, “We Like Eich(leay)!”

March 30, 2016 — Garret Murai – California Construction Law Blog
Time is money. And nowhere can than be best observed than on a construction project. Project delays can mean lost profits for owners, liquidated damages for general contractors, and increased material, labor, field overhead, and home office overhead costs for general contractors and subcontractors alike. Pricing the impact of delays, however, can be thorny. Particularly, for home office overhead. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Red Tape Is Holding Up a Greener Future

March 13, 2023 — The Editors - Bloomberg
Seven months on, Democrats are still celebrating the Inflation Reduction Act, even though a crucial determinant of its success — permitting reform for energy projects — remains undone. Recent data shows just how imperative it is for them to stop dragging their feet. What’s now called the IRA had little to do with inflation. It was a climate bill, and a big one: It provided $370 billion to improve energy efficiency, reduce emissions and smooth the path to a clean-power economy. It came on top of a 70% surge in private investment since 2017. But the biggest impediment to the US energy transition isn’t financing: It’s building. A decade ago, between 25% and 30% of proposed wind and solar projects moved from the drawing boards to completion. But as new projects and new funding have soared, utilities have been unable to keep up, leading to an immense backlog. A recent report by BloombergNEF found that over just six years, global clean-energy investment has gone from half the level of fossil-fuel investment to near parity, an extraordinary leap that reflects the market’s appetite for clean power. Yet America’s dysfunctional regulation is preventing many needed projects from even breaking ground. Read the court decision
Read the full story...
Reprinted courtesy of The Editors, Bloomberg

Housing Gains Not Leading to Hiring

October 25, 2013 — CDJ STAFF
Although construction spending has been rising steadily, the Labor Department noted that most of the 20,000 jobs added by the construction industry in September were for nonresidential construction. In a year that saw an 18% gain in residential construction spending, there was only an increase of 4.8% in employment. The lack of hiring seems to indicate a lingering lack of confidence in the homebuilding market. Employers are having workers do overtime, rather than employ additional people. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES