Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment
February 24, 2020 —
David Adelstein - Florida Construction Legal UpdatesIs the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial.
In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision):
The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Appellate Team Secures Victory in North Carolina Governmental Immunity Personal Injury Matter
January 23, 2023 —
Sam Friedman & Christopher Meeks - Lewis BrisboisAtlanta, Ga. (January 12, 2023) - Atlanta Appellate Partners Seth M. Friedman and Christopher Meeks obtained a significant appellate win on behalf of a city in North Carolina when the North Carolina Court of Appeals reversed the trial court’s denial of the city’s motion for summary judgment.
In the underlying case, Lewis Brisbois’ client was sued for injuries that occurred during the construction of a dog park. The city moved for summary judgment on the grounds that it was immune from suit under the doctrine of governmental immunity. The trial court denied the motion and held that the city waived its governmental immunity through the purchase of a liability insurance policy. Lewis Brisbois was subsequently retained to handle the appeal.
Before the North Carolina Court of Appeals, Lewis Brisbois argued, on behalf of its client, that well-established North Carolina law, along with a particular provision in the city’s insurance policy, rendered the city immune from the plaintiff’s claims. The appellate court agreed, holding that the city was immune from all liability and entitled to summary judgment on all of the plaintiff’s claims. The court's full opinion can be read
here.
Reprinted courtesy of
Sam Friedman, Lewis Brisbois and
Christopher Meeks, Lewis Brisbois
Mr. Friedman may be contacted at Seth.Friedman@lewisbrisbois.com
Mr. Meeks may be contacted at Christopher.Meeks@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of
Beyond the Disneyland Resort: World Class Shopping Experiences
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFIf you don’t want to venture far from the Disneyland Resort, consider heading to
the Outlets at Orange. Formerly known as the Block of Orange, this open air shopping center features outlet stores such as Neiman Marcus Last Call, Nordstrom Rack, and Sax Fifth Avenue’s Off Fifth, as well as an AMC movie theater, restaurants, Lucky Strike Bowling Alley, and Dave and Buster’s.
For another local option, head to
the Brea Mall, where you can find department stores such as Macy’s and Nordstrom’s and a host of other stores like Apple, Guess, and Tommy Bahama.
For a more exclusive shopping experience, travel to south Orange County's
Fashion Island of Newport Beach. Their department stores include Bloomingdale’s, Macy’s, Neiman Marcus’s, and Nordstroms, and the shopping center also contains many boutique shops and eateries.
Read the court decisionRead the full story...Reprinted courtesy of
Motions to Dismiss, Limitations of Liability, and More
January 23, 2023 —
Christopher G. Hill - Construction Law MusingsRemember BAE Sys. Ordnance Sys. V. Fluor Fed. Sols? I examined that case on two occasions previously here at Construction Law Musings. Previously the discussions were about the
mix (or lack thereof) between fraud and contract and about how
careful contract drafting is key.
In the
most recent opinion in this ongoing litigation from March of 2022, the Court examined various motions to dismiss the Complaint and Counterclaim in the matter. As a reminder, the basic facts are as follows.
The US Army Joint Munitions Command (“Army”) contracted with BAE Systems OrdnanceSystems, Inc. (“BAE”) to operate and maintain the Radford Army Ammunition Plant (“RFAAP”)under a basic ordering agreement (“BOA”). Under BOA Task Order 002, BAE contracted to replace the legacy NC facility at the RFAAP with a newer one (the “NC Project”). Initially, BAE subcontracted the NC Project to Lauren Engineers & Constructors (“Lauren”), but later terminated Lauren. Despite terminating Lauren, BAE’s timeline to complete the NC Project remained unchanged and BAE was required to use Lauren’s design for the NC Project. BAE gave interested bidders access to the Lauren design and other related documents and required the selected subcontractor to perform in accordance with the 85% complete Lauren design, that the Lauren design could be relied on for accuracy, and the selected subcontractor only had to complete the unfinished parts. Fluor Federal Solutions, LLC (“Fluor”) submitted a request for information (“RFI”) asking BAE about the standards referenced in the SOW. Fluor was unable to determine the completeness of the Lauren design but relied on BAE’s assertion that the design was 85% complete. BAE rejected Fluor’s initial bid as being too high given what BAE had already paid Lauren for its design and told Fluor to lower its bid because the design was close to complete. Fluor lowered its price and submitted another bid proposal that outlined a firm-fixed-price design/build that forecasted 32 months to complete the NC Project. BAE awarded Fluor an Undefinitized Contract Action (“UCA”) in the amount of $9 million dollars, later increased to $32 million. Under the UCA, Fluor began procuring materials and physical construction before a formal subcontract was agreed upon. On December 17, 2015, BAE and Fluor agreed to a fixed-price design and build subcontract (the “Subcontract”) in which Fluor agreed to design, construct, and partially commission the NC Project for $245,690,422.00, which included money spent already in the UCA. When this litigation began, Fluor was scheduled to complete its work by December 2020, 2.5 years beyond the originally agreed-upon completion date.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Construction Venture Sues LAX for Nonpayment
February 05, 2014 —
Beverley BevenFlorez-CDJ STAFFConstruction joint venture Walsh/Austin filed suit against the Los Angeles International Airport, claiming that “the airport failed to properly pay more than $2.4 million to an electrical subcontractor,” according to The Daily Breeze. Furthermore, SASCO, the electrical firm, alleged that they were “given inaccurate design documents that made it impossible for the company to carry out the work at the agreed-upon rate.”
The complaint, as reported by The Daily Breeze, cited “other lawsuits brought by an Orange County plastering firm and a Buena Park door company” and suggested that “eventually, all the litigation tied to nonpayment at LAX will end up in the same courtroom.”
Nancy Castles, a spokeswoman for Los Angeles World Airports, told The Daily Breeze that “the agency does not comment on pending litigation.”
Read the court decisionRead the full story...Reprinted courtesy of
New Case Law Update: Mountain Valleys, Chevron Deference and a Long-Awaited Resolution on the Sacketts’ Small Lot
June 12, 2023 —
Anthony B. Cavender - Gravel2GavelThis is a brief roundup of recent federal court environmental and regulatory law decisions from the federal courts over the past few months, including the much anticipated ruling in Sackett, et ux., v, Environmental Protection Agency.
THE U.S. SUPREME COURT
Sackett, et ux., v, Environmental Protection Agency
Last year, the Supreme Court issued a significant decision curtailing some of the EPA’s regulatory powers in the Clean Air Act in West Virginia v. Environmental Protection Agency. On May 25, 2023, the Court limited EPA’s—and the U.S. Army Corps of Engineers’ authority—under the Clean Water Act. This, too, is a major environmental ruling. The Court held that the EPA could not classify the wetlands located on the Idaho property of Michael and Chantell Sackett as “Waters of the United States” on the basis of the “significant nexus” test devised by Justice Kennedy in his separate opinion in the 2005 case of Rapanos v. United States. Accordingly, the Court unanimously held that their property was not subject to the EPA’s or the U.S. Army Corps of Engineers’ permitting and enforcement power. In 2004, the Sacketts purchased a small lot near Priest Lake in Bonner County, Idaho, on which to build a home. As related by Justice Alito, once they began to fill in their property with dirt and rocks, they were notified by EPA that their backfilling operation violated the Clean Water Act (CWA) because they were affecting protected wetlands. The Sacketts challenged this action, thus beginning a long legal battle with EPA and the federal government. In 2021, the U.S. Court of Appeals for the Ninth Circuit upheld the federal government’s regulatory authority over these wetlands, holding that the CWA covers “adjacent” wetlands having a significant nexus to traditional navigable waters. The Supreme Court decided that this case was suitable for determining whether the Sackett’s wetlands are “waters of the United States” and thus subject to the permitting and regulatory enforcement powers of the EPA and the Corps of Engineers.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Arizona Supreme Court Holds a Credit Bid at a Trustee’s Sale Should Not be Credited to a Title Insurer Under a Standard Lender’s Title Policy To the Extent the Bid Exceeds the Collateral’s Fair Market Value
March 01, 2017 —
Richard H. Herold - Snell & Wilmer Real Estate Litigation BlogThe Arizona Supreme Court recently addressed what impact, if any, a lender’s credit bid at an Arizona trustee’s sale has on an insurer’s liability under Sections 2, 7 and 9 of the standard’s lender’s title policy (“Policy”), holding in Equity Income Partners, LP v. Chicago Title Insurance Company, 241 Ariz. 334, 387 P.3d 1263 (February 7, 2017) as follows:
1. Section 2 of the Policy, entitled “Continuation of Insurance,” not Section 9, entitled “Reduction of Insurance; Reduction or Termination of Liability,” applies when a lender acquires property at a trustee sale by “either a full- or partial-credit bid” since Section 2 directly addresses the existence and amount of coverage in such circumstances. Id. at 1267.
Read the court decisionRead the full story...Reprinted courtesy of
Richard H. Herold, Snell & WilmerMr. Herold may be contacted at
rherold@swlaw.com
Inside New York’s Newest Architectural Masterpiece for the Mega-Rich
May 20, 2015 —
Oshrat Carmiel – BloombergThe newest condominium tower in midtown Manhattan's billionaires district is ready to open its doors to buyers. It took almost a decade to get there.
The skyscraper at 53 W. 53rd St., designed by French architect Jean Nouvel and rising next to the Museum of Modern Art, will start marketing its 139 apartments next week, with prices starting at $3 million. Planned since 2006, the project endured the real estate bust and a global financial crisis that decimated demand for luxury homes. Now it's emerging when buyers can't seem to get enough of them.
"We're very eager to begin,'' said David Penick, the New York-based managing director for developer Hines, which is building the project with Goldman Sachs Group and Singapore-based Pontiac Land Group. "We're confident in what we have to sell in the market we're in, and we'll see how it goes.''
Read the court decisionRead the full story...Reprinted courtesy of
Oshrat Carmiel, Bloomberg
