Seattle Washington Building Expert Directory

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

Failure to Comply with Sprinkler Endorsement Bars Coverage for Fire Damage

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
Despite its application stating otherwise, the insured's failure to install a sprinkler system in its building barred coverage for extensive damage caused by fire.American Way Cellular, Inc. v. Travelers Prop. Cas. Co. of Am., 2013 Cal. App. LEXIS 425 (Cal. Ct. App. May 30, 2013). American Way contacted a broker, A&J, regarding liability and property coverage. A&J sent American Way an application for a policy with Travelers. The application indicated American Way had a sprinkler system and fire detectors in its building. Travelers issued a policy with a Protective Safeguards Endorsement For Sprinkler Locations and Restaurants. The endorsement stated that as a condition of the insurance, the insured was required to maintain a sprinkler system. An exclusions section said the insurer would not pay for loss caused by fire if there was no sprinkler system. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Settlement Payment May Preclude Finding of Policy Exhaustion: Scottsdale v. National Union

December 11, 2013 — Heather Anderson — Higgins, Hopkins, McLain & Roswell, LLC.
In the last year, the U.S. District Court for the District of Colorado found that a settlement payment from an excess insurance carrier to another primary insurance carrier precluded a finding of vertical exhaustion sufficient to trigger the primary carrier’s duty to indemnify. See Scottsdale Ins. Co. v. National Union Fire Ins. Co. of Pittsburgh, 2012 WL 6004087 (D. Colo. 2012). The Scottsdale case arose out of the construction of a 507-unit apartment complex in Arapahoe County, Colorado in which a number of defects became apparent during construction. As a result, the owner of the project sued the general contractor and/or the construction manager, seeking to recover more than $22 million for various construction deficiencies. Id. at *1. The general contractor was insured under policies issued by several carriers. Scottsdale Insurance Co. (“Scottsdale”) and National Union Fire Ins. Co. (“National Union) provided umbrella coverage, and CNA and American Zurich Ins. Co. (“Zurich”) provided primary insurance under commercial general liability policies. About five years later, the construction defect case settled for $8.5 million dollars. Read the court decision
Read the full story...
Reprinted courtesy of Heather Anderson
Heather Anderson can be contacted at anderson@hhmrlaw.com

Contractor Entitled to Continued Defense Against Allegations of Faulty Construction

November 01, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The U.S. District Court found that the contractor was entitled to a defense in the underlying state court action. Pa. Nat'l Mut. Cas. Ins. Co. v. Zonko Builders, 2021 U.S. Dist. LEXIS 168855 (D. Del. Sept. 7, 2021). Zonko was the general contractor for building the Salt Meadows Townhomes Condominium. This included supervising subcontractors in the installation of siding, house wrap, and flashing in five buildings between 2005 and 2007. In 2016, Salt Meadows and its individual members ("Association") found property damage in the condominiums. The Association sued Zonko in state court, alleged that resulting damages included drywall damage in ceilings or walls, flooring and carpet, water damage around window trim, rot on window frames, incorrect flashing around roofs and windows, possible ridge vent leaks, and possible foundation issues. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Demand Unsteady, Gains in Some Regions

June 29, 2011 — CDJ STAFF

The Associated General Contractors of America reported Tuesday, June 28 that construction employment increased in 120 of the 337 metropolitan areas surveyed between May 2010 and May 2011.

‘While construction employment has stopped plunging, any sign of a recovery remains spotty at best,” said Ken Simonson, the association’s chief economist. ‘The close to even split between areas adding and losing jobs is a reminder that for every market doing well, there is another market that is still hurting.”

The largest number of jobs created was in the Dallas, Texas region, with 5,600 new jobs, a five percent increase. The northern Massachusetts/southern New Hampshire region near Haverhill saw the greatest percentage increase, although that twenty-two percent increase represents only 800 new jobs. The Chicago, Illiinois area added 4,600 jobs, a four percent increase.

Other regions were not so lucky. The Atlanta, Georgia area saw a loss of 7,400 jobs, an eight percent loss. Las Vegas also lost 7,400 jobs, which there represented a sixteen percent decline. The New York City area lost 6,700 jobs, a six percent reduction. The Riverside, California area lost 5,300 jobs, a nine percent loss.

Stephen E. Sandherr, the association’s chief executive officer, blamed a combination of regulation and budget squeezes. "Some in Washington never met a regulation they didn’t like and others never found a penny they didn’t want to pinch. Together that makes for a bad way to boost employment and a great way to stifle the private sector and neglect critical economic infrastructure.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

WSDOT Seeks Retraction of Waiver Excluding Non-Minority Woman-Owned Businesses from Participation Goals

September 28, 2017 — Lindsay K. Taft - Ahlers & Cressman PLLC
If you are a regular reader of our blog, you will likely recognize that our firm has been actively involved and concerned with the results of Washington State Department of Transportation’s (“WSDOT”) Disparity Study, which impacts both Disadvantaged Business Enterprises (“DBE”) and general contractors who bid on federally-funded projects with DBE goals. On June 1, 2017, WSDOT implemented a “waiver”, which excluded Caucasian women-owned firms (“WBEs”) from qualifying for Condition of Award DBE Goals on federally-funded projects. This drastic action was the result of WSDOT’s highly criticized 2012 Disparity Study conducted by BBC Research & Consulting of Denver, Colorado, which concluded non-minority women-owned firms do not face “substantial disparities” in the federally-funded transportation contracting market. BBC’s study was criticized for a number of reasons, but most concerning was BBC’s flawed and unreliable statistical methodology that did not accurately represent true marketplace conditions. See Ahlers & Cressman letter of January 9, 2014 and Associated General Contractors of Washington article. For example, BBC’s results showed both decreasing WBE availability and availability vastly out of range with other states (e.g., the availability of women-owned construction firms in Washington was just 1.5% compared to 11.96% in Oregon). Nevertheless, based on this flawed BBC study and BBC’s assertion that women-owned firms did not face disparities, WSDOT sought and on June 1, 2017 was granted a waiver precluding general contractors from counting WBE firms towards their DBE goals on federally funded public works projects. Read the court decision
Read the full story...
Reprinted courtesy of Lindsay Taft, Ahlers & Cressman PLLC
Ms. Taft may be contacted at ltaft@ac-lawyers.com

New Survey Reveals Present-Day Risks of Asbestos Exposure in America - 38% in High-Risk Jobs, 47% Vulnerable through Second-Hand Exposure

April 08, 2024 — The Law Offices of Justinian C. Lane, Esq. - PLLC
AUSTIN, April 04, 2024 (GLOBE NEWSWIRE) -- A recent nationwide survey conducted on the risks of asbestos in America revealed that 38% of respondents have worked in high-risk industries where asbestos was present, while 47% have experienced indirect exposure through family members employed in these high-risk environments. The survey results reflect the fact that, despite the EPA's recent ban on ongoing uses of chrysotile asbestos, the threat of exposure still looms large in the US, underscoring the urgent need for continued vigilance and action to safeguard public health. Compounding the concern is the revelation that only 8% of Americans undergo regular testing. These findings, released today, underscore the urgent necessity for Asbestos Cancer Risk Awareness and routine testing. They emphasize the crucial importance of proactive measures to mitigate the pervasive risks associated with asbestos exposure in the United States. The study was conducted by Researchscape on behalf of The Law Offices of Justinian C. Lane, Esq. - PLLC, a leading firm advocating for testing and compensation for individuals exposed to asbestos on the job and their families who are at risk due to second-hand exposure. According to the survey, 86% of respondents have never undergone any testing for asbestos exposure, while a mere 8% are tested regularly. The lack of testing is particularly concerning among the Gen X demographic who could be at risk due to secondhand exposure from a family member who worked with asbestos when it was still prevalent, with 92% reporting no testing, highlighting the potential risks associated with secondhand exposure. Read the court decision
Read the full story...
Reprinted courtesy of

The Legal Landscape

June 17, 2024 — David McMillin - Construction Executive
The construction industry continues to change as new technologies reshape jobsites and new generations of leaders rethink the way companies should operate. But one piece of the puzzle remains very much the same: Everyone needs a good lawyer. According to the most recent edition of the Arcadis Construction Disputes Report, the average value of a dispute in the industry has soared to $42.8 million—a 42% year-over-year increase between 2021 and 2022. And based on how busy the attorneys at Construction Executive’s 2024 Top 50 Construction Law Firmshave been this year, there is no sign of legal issues becoming less important to builders and contractors. Every construction leader wants to spend more time and energy doing what they do best—building projects safely, efficiently and profitably—and less time thinking about the things that might land them in court. How can you best avoid big disputes bound for mediation, arbitration or litigation? What emerging rules and regulations should be on your radar as you develop strategies for success? While legal issues will never disappear, listening to what some of the best construction lawyers in the country—all members of 2024 Top 50 Construction Law Firms—are thinking about offers a helpful perspective on future-proofing your business against risk, liability and worse. Reprinted courtesy of David McMillin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES