Cambridge Massachusetts Building Expert Directory

Constructive Changes – A Primer

October 02, 2018 — Jonathan R. Mayo - Smith Currie
A “constructive change” occurs when an owner action or omission not formally acknowledged by the owner to be a change in the contact’s scope of work forces the contractor to perform additional work. Constructive changes are not formal change orders, but informal changes that could have been ordered under a contract’s changes clause if the change had been recognized by the owner. The constructive change doctrine recognizes that being informally required to do extra work is similar to a formal change order and should be governed by similar principles. Thus, if it is found that a constructive change order did occur, the contractor may be entitled to payment for additional costs incurred, and an extension to the contract performance period. Constructive changes most often arise where there is a dispute regarding contract interpretation, defective plans and specifications, acceleration or suspension of work, interference or failure to cooperate with the contractor, misrepresentation or nondisclosure of superior knowledge or technical information, over inspection, or a delay in providing requested information crucial to the contractor’s ability to continue work. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan R. Mayo, Smith Currie
Mr. Mayo may be contacted at jrmayo@smithcurrie.com

Construction Defect Claim Must Be Defended Under Florida Law

February 15, 2018 — Tred R. Eyerly – Insurance Law Hawaii

The Eleventh Circuit found that the insured caused property damage to areas beyond its own work, obligating the insurer to defend. Addison Ins. Co. v. 4000 Island Blvd. Condo. Ass'n, 2017 U.S. App. LEXIS 26870 (11th Cir. Dec. 28, 2017).

The condominium association contracted with Poma Construction Corp. to replace the building's aging concrete balcony railings with new aluminum and glass railings. Poma subcontracted with Windsor Metal Specialties, Inc. to paint the new railings. Work was completed on February 24, 2012. Poma issued a 10-year warranty covering its installation of the railings. Windsor issued a 20-year limited warranty covering the paint job.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

COVID-19 Damages and Time Recovery: Contract Checklist and Analysis

April 27, 2020 — Patrick J. Greene, Jr. - Peckar & Abramson
This Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist. Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool. Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present: a) complete or partial suspension of work, b) additional work or requirements, c) added cost, d) delay, and e) disruption. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Greene, Jr., Peckar & Abramson
Mr. Greene may be contacted at pgreene@pecklaw.com

You’ve Been Suspended – Were You Ready?

April 20, 2020 — Curtis W. Martin, Patrick J. Greene, Jr. & Levi W. Barrett - Peckar & Abramson
“Effective tomorrow … the City is suspending all regular activity at construction sites in Boston.” This was just one of the surprises that greeted contractors last week. Contractors and owners with projects across the country are scrambling to comply with mandated governmental suspensions. Project participants should begin contingency planning for possible project shutdowns. Reacting to Suspension Your legal rights and remedies will be largely determined by your contract and the laws applicable to it. But some basic principles will be applicable depending on the source of the suspension. Suspension by the Owner: An owner work suspension suggests review of the contract’s suspension of work clause. Federal contractors would look to the FAR Suspension of Work clause, FAR 52.242-14, but that is applicable if the suspension is by the Contracting Officer; the US would argue that a systemic suspension was a sovereign act and outside the FAR clause. Contractors for private work and state or municipal work may have contractual suspension of work clauses. At least some suspension clauses provide relief for time and money. Reprinted courtesy of Peckar & Abramson attorneys Curtis W. Martin, Patrick J. Greene and Levi W. Barrett Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Greene may be contacted at pgreene@pecklaw.com Mr. Barrett may be contacted at lbarrett@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Bond Principal Necessary on a Mechanic’s Lien Claim

October 23, 2018 — Christopher G. Hill - Construction Law Musings
As anyone that reads this construction law blog knows, mechanic’s liens are a big part of the Virginia landscape for a construction attorney like me. One option for dealing with a mechanic’s lien here in Virginia that we have not discussed but so often is the ability to “bond off” a lien. In short, the Virginia statute allows a party to essentially substitute a bond valued at a court set multiple of the principal amount of the mechanic’s lien for the memorandum. In exchange, the lien is released of record. Any enforcement action can still proceed with security for the claimant and the property owner feeling better about things because there will be no lien on the title to the land. In many ways this process provides an easier path to resolution for both owner and claimant. First of all, the claimant does not have to deal with a bank or other interest holders in the property (though a recent case discussed below reminds us that certain other parties are necessary). Second of all, the owner does not have the cloud on the title of a mechanic’s lien that may have been filed by a subcontractor over which he has no control. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Three Reasons Lean Construction Principles Are Still Valid

February 27, 2019 — Kevin Clary - Construction Executive
When lean principles were first introduced to the construction industry five years ago, project managers raced to implement the production method. The internet was rife with content about how to easily overhaul a jobsite and transform it into the picture of efficiency. However, the number of lean construction critics have multiplied significantly in recent months. They claim concepts are near impossible to implement or, even worse, automation eliminates the need for deliberate human processes. These ideas are misleading. Lean principles are still valid for a few key reasons. 1. Lean involves seeing things from the customer’s point of view One of the defining principles of lean construction is understanding value from the customer’s point of view. The concept encourages stakeholders, including the owner, contractor and supplier, to come together during the early planning stage of the project. The significant level of trust created from this exercise can’t be replicated by machinery. It involves compassion, collaboration and a sense of creativity that artificial intelligence is yet to possess. Moreover, the rapport gained through this service-oriented exercise is worth the time investment. Reprinted courtesy of Kevin Clary, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Condo Board Goes after Insurer for Construction Defect Settlement

February 07, 2013 — CDJ STAFF
The City Bella on Lyndale homeowners association settled with the high rise's developer and builder for $1.9 million over construction defects. The defects included structural deterioration in the project's pool area, extensive air and water leaks in the windows, and structural problems in the project's underground parking garage. City Bella consists of a 15-story tower and a four-story building on Lyndale Avenue in Minneapolis. They settled the lawsuit in 2011, but the homeowners association is still looking to the insurers to pay up. With legal fees and interest, the total rises to $2.82 million that Travelers could be paying the association. Read the court decision
Read the full story...
Reprinted courtesy of

Do You Have A Florida’s Deceptive And Unfair Trade Practices Act Claim

April 27, 2020 — David Adelstein - Florida Construction Legal Updates
In previous articles, I discussed Florida’s Deceptive and Unfair Trade Practices Act referred to as “FDUTPA”…but, it has been awhile. (For more information on FDUTPA, check here and here.) Now is as good of a time as any to discuss it again because FDUTPA provides a private cause of action and, perhaps, there may be a consideration as to whether such claim can be (or is) properly asserted in the context of your circumstances. FDUTPA is a statutory scheme designed, “To protect the consuming public and legitimate business enterprises from those who engage in unfair methods of competition, or unconscionable, deceptive or unfair acts or practices in the conduct of any trade or commerce.” Fla. Stat. s. 501.201(2). In doing so, FDUTPA authorizes three avenues of legal recourse against an offending party: “(1) declaratory relief; (2) injunctive relief; and (3) [monetary] damages.” Webber v. Bactes Imaging Solutions, Inc., 45 Fla. L. Weekly D125a (Fla. 2d DCA 2020);Fla. Stat. s. 501.211. “An unfair practice is ‘one that “offends established public policy” and one that is ‘immoral, unethical, oppressive, unscrupulous or substantially injurious to consumers.’” Webber, supra, (citation omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES