CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Duty To Defend Construction Defect Case Affirmed, Duty to Indemnify Reversed In Part

May 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Eleventh Circuit affirmed the district court's finding of a duty to defend, but reversed, in part, the insurer's duty to indemnify. Carithers v. Mid-Continent Cas. Co., 2015 U.S. App. LEXIS 5540 (11th Cir. April 7, 2015). After discovering a number of defects in their home, the Carithers sued their homebuilder, Cronk Duch Miller & Associates. Cronk Duch's insurer, Mid-Continent Casualty Company, refused to defend.The parties entered into a consent judgment for $90,000 in favor of the Carithers. Cronk Duch then assigned to the Carithers the right to collect the judgment from Mid-Continent. The Carithers then sued Mid-Continent. Florida law applied. Mid-Continent has issued four policies to Cronk Duch from March 2005 to October 2008. The parties filed cross-motions for summary judgment on the duty to defend issue. The underlying complaint alleged that the defects could not have been discovered until 2010, after the last policy period. The district court rejected Mid-Continent's argument that property damage occurred when it was discovered or when it reasonably could have been discovered. Therefore, summary judgment on the duty to defend was granted to the Carithers. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Glendale City Council Approves Tohono O’odham Nation Casino

August 13, 2014 — Beverley BevenFlorez-CDJ STAFF
With a 4-3 vote, the Glendale, Arizona city council “approved an agreement with the Tohono O’odham Nation to build a casino adjacent to the city,” according to the Arizona Public Media. The tribe, under the agreement, “will commit more than $25 million over the next 20 years to the city.” The agreement also stipulates that Glendale “will try to convince state and federal officials to end their opposition to the casino plans.” City Councilman Gary Sherwood stated that he “he doesn't believe the tribe has firm plans for construction yet, but he said he wouldn't be surprised if there was gaming on the site by next fall.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract

May 10, 2022 — Ted Senet & Christopher Trembley - Gibbs Giden
California local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount. In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor. As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:

Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.

Reprinted courtesy of Ted Senet, Gibbs Giden and Christopher Trembley, Gibbs Giden Mr. Senet may be contacted at tsenet@gibbsgiden.com Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Toll Brothers Climbs After Builder Reports Higher Sales

February 26, 2015 — John Gittelsohn – Bloomberg
(Bloomberg) -- Toll Brothers Inc., the largest U.S. luxury-home builder, rose the most in a year after the company reported a higher-than-expected quarterly profit and said it sold more properties at higher prices. Net income for the three months through January was $81.3 million, or 44 cents a share, compared with $45.6 million, or 25 cents, a year earlier, the Horsham, Pennsylvania-based builder said in a statement Tuesday. The average of 14 estimates was for 28 cents a share, according to data compiled by Bloomberg. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

---

Public Contract Code Section 1104 Does Not Apply to Claims of Implied Breach of Warranty of Correctness of Plans and Specifications

October 30, 2023 — Garret Murai - California Construction Law Blog
It’s the classic tale of two cities. One city is occupied by architects and engineers. The other, by contractors. And while the cities typically co-exist relatively peacefully together, at times, they do not, such as when a defect arises that can either be a design or construction defect. Sometimes, project owners are pulled into these fights as well. There is a common law rule that when contracting with a contractor the owner impliedly warrants to the contractor that the plans and specifications are sufficiently accurate and correct. And, if you work on local public works projects, you may be familiar with Public Contract Code section 1104 which provides that, with the exception of design-build projects, local public entities cannot require a bidder to assume responsibility for the completeness and accuracy of architectural or engineering plans and specifications. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Elizabeth Lofts Condo Owners Settle with Plumbing Supplier

January 28, 2014 — Beverley BevenFlorez-CDJ STAFF
The owners of the Elizabeth Lofts condominiums in the Pearl District, Portland, Oregon have settled with Victaulic Co., the plumbing supplier who allegedly “sold failing parts,” reported The Oregonian. The case had been scheduled to go to trial this month. “Lawsuits filed by owners at the Avenue Lofts, the Benson Tower and The Edge Lofts are moving forward in federal courts.” The Elizabeth Lofts owners alleged “parts used in the buildings’ plumbing systems were disintegrating and causing water damage,” according to The Oregonian. The owners association had sought over three million in damages, though Phillip E. Joseph, Elizabeth Lofts owners’ attorney, said “he couldn’t disclose the terms” of the settlement. Victaulic’s attorney “declined to comment.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Colorado Construction-Defects Reform Law Attempt Expected in 2015

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
According to the Denver Post, another attempt to change Colorado’s construction defect laws to spur condo development is likely this term. Reform supporters are encouraged by the city of Lakewood’s ordinance, Denver Post reported: “"A patchwork around the state on this issue is not the way to go," Rep. Brian DelGrosso, R-Loveland, said. "Hopefully, the Lakewood measure will spur the conversation this year." Lakewood’s “measure gives builders a ‘right to repair’ faulty work before facing legal action and requires that a majority of home owners approve legal action before it is taken.” However, “Nancy Stockton, president of the homeowners association at the Vallagio at Inverness in Arapahoe County, said following Lakewood's example statewide would only make it that much harder to hold builders accountable for the quality of their work.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Righting Past Wrongs Through Equitable Development

January 17, 2022 — Bruce Buckley & Pam Radtke Russell - Engineering News-Record
Standing on a dead-end street in Spartanburg, S.C., Harold Mitchell can plainly see the history of injustice in his community. On one side lies the remains of his childhood home. On the other, a shuttered fertilizer plant that was operational when Mitchell was growing up. He distinctly recalls smells of ammonia and sulfur emanating through the neighborhood that “were so pervasive, you didn’t even think about it.” He remembers his father regularly cleaning white dust off their cars, and workers emerging from the plant gates “looking like the Pillsbury Doughboy” covered in fertilizer dust from head to toe. Sometimes, he’d walk with the plant’s night watchman, strolling alongside neon green sewage lagoons located not far from his bedroom window. Reprinted courtesy of Bruce Buckley, Engineering News-Record and Pam Radtke Russell, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---