Seattle Washington Building Expert Directory

Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing

January 22, 2024 — David Adelstein - Florida Construction Legal Updates
A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt. The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ASCE Releases New Report on Benefits and Burdens of Infrastructure Investment in Disadvantaged Communities

February 05, 2024 — The American Society of Civil Engineers
Washington — The American Society of Civil Engineers today released a new paper, Measuring the Benefits and Burdens of Infrastructure in Disadvantaged Communities. The report looks at how several communities across the country consider equity when investing infrastructure funds, and the impact of those projects on lower-income communities. "Civil engineers are focused on improving quality of life by building systems that improve the public's health, safety, and well-being," said Marsia Geldert-Murphey, P.E., 2024 President, ASCE. "However, the decisions on how and where infrastructure is built can affect communities for decades after a project is complete. By looking at the benefits and burdens of past projects, infrastructure owners and developers can find better ways to consider the impact of infrastructure projects being designed now." Some of the recommendations in the paper include encouraging government and other infrastructure stakeholders to use community engagement and transparent metrics when making decisions about proposed infrastructure investments. It also encourages post-project assessments and the use of existing resources to evaluate the positive and unexpected consequences of past infrastructure projects. Measuring the Benefits and Burdens of Infrastructure in Disadvantaged Communities is available here. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

No Global MDL for COVID Business Interruption Claims, but Panel Will Consider Separate Consolidated Proceedings for Lloyds, Cincinnati, Hartford, Society

August 24, 2020 — Eric B. Hermanson & Konrad R. Krebs - White and Williams
In a widely anticipated ruling, the Judicial Panel on Multidistrict Litigation has denied two motions to centralize pretrial proceedings in hundreds of federal cases seeking coverage for business interruption losses caused by the COVID-19 pandemic. However, the Panel has ordered expedited briefing on whether four separate consolidated proceedings should be set up for four insurers – Cincinnati, Society, Hartford, and Lloyds – who appear to be named in the largest number of claims. In seeking a single, industry-wide MDL proceeding, some plaintiffs had argued that common questions predominated across the hundreds of pending federal suits: namely, [1] the question of what constituted ‘physical loss or damage’ to property, under the allegedly standardized terms of various insurers’ policies; [2] the question whether various government closure orders should trigger coverage under those policies, and [3] the question whether any exclusions, particularly virus exclusions, applied. Reprinted courtesy of Eric B. Hermanson, White and Williams and Konrad R. Krebs, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Krebs may be contacted at krebsk@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Presidential Executive Order 14008: The Climate Crisis Order

August 16, 2021 — Anthony B. Cavender - Gravel2Gavel
Presidential Executive Order 14008, “Tackling the Climate Crisis,” a long and unusually detailed Executive Order published in the Federal Register on February 1, 2021 (see 86 FR 7619), has generated considerable discussion and commentary. Below, I briefly outline its provisions. This EO describes the “climate crisis” in existential terms:

“There is little time left to avoid setting the world on a dangerous, potentially catastrophic climate trajectory.” Confronting and combating climate change will be an important component of American foreign policy and national security, and domestically, the federal government’s resources will be mobilized to deploy a “govern-wide approach to the climate crisis.”

Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Significant Increase in Colorado Tort Damages Caps Now in Effect Under Recent Legislation

January 28, 2025 — Gordon Rees Scully Mansukhani, LLP
Colorado’s recently enacted legislation (HB 24-1472), which significantly increases damages caps for tort actions, is now in effect. Given the legislation’s January 1, 2025, effective date, an early-2025 increase in new filings is anticipated for cases that otherwise could have been filed in 2024. The increases include:

For noneconomic damages in tort actions (other than against medical professionals), more than double the previous cap to $1.5 million (with future inflation adjustment).[1]
In wrongful death actions (other than against medical professionals), a greater than threefold increase from the previous limit to $2.125 million (with future inflation adjustment).[2]
In medical professional actions for wrongful death, a 50% increase from the previous overall cap to $1.575 million in 2029 (with future inflation adjustment). For injury claims, more than double the previous cap for noneconomic damages to $875,000 in 2029 (with future inflation adjustment).[3]

Read the court decision
Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani, LLP

Surfside Condo Collapse Investigators Have Nearly Finished Technical Work

March 11, 2024 — James Leggate - Engineering News-Record
Newly analyzed evidence in the investigation into the June 2021 partial collapse of Champlain Towers South that killed 98 people in Surfside, Fla., shows that the pool deck collapsed more than four minutes before the tower itself. But investigators are still working to determine the initiating event, and aim to finish their technical work this summer. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Bidding for Success

May 22, 2023 — The Hartford Staff - The Hartford Insights
When construction companies develop a history of successful projects, they often consider bidding on larger projects. However, larger projects can carry greater risks. If your company has successfully completed numerous $10 million projects and is considering a bid on a $100 million project, there are several factors to consider before submitting a proposal. That is because bidding on the wrong project could potentially put you out of business. “When a contractor bids a larger project, there is a greater financial risk,” says Tim Holicky, a senior executive underwriter at The Hartford. There are more subcontractors to manage and additional materials to purchase, which all leads to greater financial risk. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

New Proposed Regulations Expand CFIUS Jurisdiction Regarding Real Estate

January 20, 2020 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
On September 17, 2019, the U.S. Department of Treasury issued two new proposed rules for the Committee on Foreign Investment in the United States (CFIUS) implementing the Foreign Investment Risk Review Modernization Act (FIRRMA). Of particular interest to readers of this blog was the second of the proposed rules, which addressed FIRRMA’s real estate-related expansion of CFIUS jurisdiction. Pillsbury's Construction & Real Estate Law Team Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES