Seattle Washington Building Expert Directory

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

A Look Back at the Ollies

May 03, 2018 — Beverley BevenFlorez-CDJ STAFF
The Jerrold S. Oliver Award of Excellence, also known as the “Ollie” award, is presented to “an individual who is outstanding or has contributed to the betterment of the construction defect community.” West Coast Casualty asks members of the construction defect community to nominate those they feel are deserving of the award, and then members vote for one of four nominees. The award is presented at the West Coast Casualty Seminar. Those recognized receive a plaque and a donation in the winner’s name to Habitat for Humanity as well as a local California and Nevada charity. Jerrold S. Oliver was a “’founding father’ in the alternate resolution process in construction defect claims and litigation. His loyalty and commitment to this community were beyond mere words as he was a true believer in the process of resolution.” Past Award Winners: 1996 - Awarded to Ross R. Hart, Esq. (Mediator - American Arbitration Assoc.) 1997 - Awarded to Merv Thompson, Esq. (Mediator in private practice) 1999 - Awarded to Tom Craigo, (Adjuster - C.N.A. Insurance Company) 2000 - Awarded to Kristi Cole, (Adjuster - Safeco Insurance Company) 2001 - Awarded to Karen Rice, (Claims Manager - ACE / USA) 2002 - Awarded to Stephen Henning, Esq. (Wood, Smith, Henning and Berman, LLP) 2003 - Awarded to Ross Feinberg, Esq. (Feldscott, Lee, Feinberg, Grant and Mayfield LLP) 2004 - Awarded to Janet Shipes (Adjuster – C.N.A. Insurance Company) 2005 - Awarded to Edward Martinet (Expert – MC Consultants) 2006 - Awarded to Hon. Victoria V. Chaney (Judge – Los Angeles Superior Court) 2007 - Awarded to Bruce Edwards, Esq. (Mediator) JAMS 2008 - Awarded to Gerald Kurland, Esq. (Mediator) JAMS 2009 - Awarded to Keith Koeller, Esq. (Koeller, Nebecker, Carlson and Haluck, LLP) 2010 - Awarded to Terry Wolcott – (Construction Defect Manager – Travelers Ins. Co.) 2011 - Awarded to George Calkins, Esq. (Mediator) JAMS 2012 - Awarded to Joyia Greenfield, Esq. (Lorber, Greenfield and Polito, LLP) 2013 - Awarded to Margee Luper (Claim Manager – XL Insurance Group) 2014 - Awarded to Matt Liedle, Esq. (Liedle, Lounsbery, Larson & Lidl, LLP) 2015 - Awarded to Robert A. Bellagamba, Esq. (Special Master/Mediator, Castle & Dekker) 2016 - Awarded to Lisa Unger, (Senior Claims Examiner, Global Management Liability Markel) 2017 - Awarded to Caryn Siebert, (Vice President, Claims, Knight Insurance Group) Read the court decision
Read the full story...
Reprinted courtesy of

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Bad Faith in the First Party Insurance Context

December 15, 2016 — David Adelstein – Florida Construction Legal Updates
In a previous article I discussed bad faith when it comes to an insurance claim. Recently, in Barton v. Capitol Preferred Insurance Co., Inc., 41 Fla. L. Weekly D2736b (Fla. 5th DCA 2016), the court discussed bad faith in the first-party insurance context (i.e., a property / homeowners insurance policy). In this case, homeowners, as the insured, sued their homeowners insurance carrier for sinkhole coverage. The homeowner filed a Civil Remedy Notice of Insurer Violation (also known as a Civil Remedy Notice) against their insurer with the Florida Department of Insurance in accordance with Florida Statute s. 624.155. This Civil Remedy Notice is a prerequisite to initiating such a bad faith claim; the notice specifies the statutory violations committed by the insurer and gives the insurer 60 days to cure the violation. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dma@katzbarron.com

Production of Pre-Denial Claim File Compelled

November 30, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The appellate court found that the claims file that existed before the insurer's denial was discoverable. Cascade Builders Corp. v. Rugar, 2017 N.Y. App. Div. LEXIS 7357 (N.Y. App. Div.. Oct. 19, 2017). Cascade Builders was the general contractor for the homeowners. In May 2011, Cascade subcontracted with John Rugar to perform certain exterior power washing on the residence. The contract between Cascade and Rugar required Rugar to indemnify and hold Cascade harmless for any work performed by Rugar and to obtain coverage naming Cascade as an additional insured. Rugar procured the required CGL policy from Utica First Insurance Company. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

McCarthy Workers Test Fall-Protection Harnesses Designed to Better Fit Women

November 09, 2020 — Corinne Grinapol - Engineering News-Record
At project sites in Dallas, Houston and Atlanta, 27 McCarthy Building Co. women employees are testing a harness better suited to fit a diversity of body types than the more ubiquitous harnesses generally available at construction sites. Reprinted courtesy of Corinne Grinapol, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Limited Number of Insurance-Related Bills Passed by 2014 Hawaii Legislature

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Very few insurance-related bills survived the 2014 Hawaii Legislative session, with several consumer-friendly bills failing to make it out of committee. Here is a summary of the bills that passed: SB2365: Limits reimbursement of prescription medications in order to prevent drug prices from becoming an unreasonable cost driver of health care in workers' compensation and motor vehicle insurance claims. SB2470: Appropriates general funds to provide for the sustainability of the Hawaii Health Connector, but provides for greater transparency, stakeholder engagement, and legislative involvement in the activities of the Hawaii Health Connector. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Three Key Takeaways from Recent Hotel Website ADA Litigation

April 26, 2021 — Shane Singh & Grace Mehta - Lewis Brisbois
Despite the COVID-19 pandemic and its chill on the hospitality industry, ADA-related digital lawsuits increased by approximately 23% in 2020. Many of these lawsuits are filed against hotels. The complaints allege that a hotel’s online reservation system failed to provide enough detail for individuals with disabilities to decide if the hotel meets their accessibility needs. These plaintiffs will often claim that it is insufficient to describe an aspect of a hotel or room as “accessible” because the term is an opinion or conclusion. Plaintiffs argue that a hotel’s reservation system must report specific information, such as the dimensions of space under accessible desks and sinks, the slopes of surfaces, doorway clearance, and numerous other technical requirements under the ADA. Many hotels are fighting back, arguing that the detail provided is sufficient and in compliance with the ADA. So far this year, in February 2021, two judges in the U.S. District Court for the Central District of California, Judge Percy Anderson and Judge Cormac Carney, agreed with the defendants, dismissing three cases with prejudice. Reprinted courtesy of Shane Singh, Lewis Brisbois and Grace Mehta, Lewis Brisbois Mr. Singh may be contacted at Shane.Singh@lewisbrisbois.com Ms. Mehta may be contacted at Grace.Mehta@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES