Seattle Washington Building Expert Directory

Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages

February 14, 2022 — David Adelstein - Florida Construction Legal Updates
A recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration. In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Labor Under the Miller Act And Estoppel of Statute of Limitations

May 08, 2023 — David Adelstein - Florida Construction Legal Updates
If you want a case that goes into history of the federal Miller Act, check out the Fourth Circuit Court of Appeal’s opinion in U.S. ex rel. Dickson v. Fidelity and Deposit Company of Maryland, 2023 WL 3083440 (4th Cir. 2023). While I am not going to delve into this history, it’s a worthwhile read. It is also a worthwhile read for two other points. First, it discusses what constitutes “labor” under the Miller Act. Second, it discusses doctrine of estoppel to prevent a surety from raising the statute of limitations to bar a Miller Act payment bond claim, which is a doctrine you do NOT want to rely on, as this case reinforces. Both of these points applicable to Miller Act claims are discussed below. This case dealt with a prime contractor renovating staircases that was terminated by the federal government. The prime contractor hired a professional engineer as its subcontractor to serve as its project manager and supervise labor on the project. The engineer/subcontractor also had “logistical and clerical duties, taking various field measurements, cleaning the worksite, moving tools and materials, and sometimes even watering the concrete himself.” Dickson, supra, at *1. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Open & Known Hazards Under the Kinsman Exception to Privette

February 15, 2018 — Frances Ma & Lawrence S. Zucker II – Haight Brown & Bonesteel LLP Publications & Insights
Gonzalez v. Mathis, 2018 WL 718528 confirms the difficulties a defendant will face when trying to overcome the Kinsman exception to the Privette doctrine on a dispositive motion when dealing with an open and obvious hazard. There, a professional window washer fell off a roof while walking along a parapet wall constructed by the owner of a home. The window washer filed suit against the homeowner and alleged three dangerous conditions on the roof: (1) the parapet wall forced those who needed to access a skylight to walk along an exposed two-foot ledge that lacked a safety railing; (2) dilapidated and slippery roof shingles; and (3) the lack of tie off points that would allow maintenance workers to secure themselves with ropes or harnesses. The homeowner filed a motion for summary judgment under Privette v. Superior Court (1993) 5 Cal.4th 689 and its progeny which prohibits an independent contractor from suing his or her hirer for workplace injuries (“Privette doctrine”). There are two exceptions to the Privette doctrine. First, a hirer cannot avoid liability when he or she exercises control over the manner and means in which a contractor does his or her work and that control contributes to the injuries sustained – known as the “Hooker exception” (premised on the holding of Hooker v. Department of Transportation (2002) 27 Cal.4th 198). Second, a hirer may be found liable if he or she fails to warn the contractor of a concealed hazard on the premises – known as the “Kinsman exception” (premised on the holding of Kinsman v. Unocal Corp. (2005)). Reprinted courtesy of Frances Ma, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Ms. Ma may be contacted at fma@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Client Alert: Michigan Insurance Company Not Subject to Personal Jurisdiction in California for Losses Suffered in Arkansas

February 05, 2015 — R. Bryan Martin, Lawrence S. Zucker II, and Kristian B. Moriarty – Haight Brown & Bonesteel LLP
In Greenwell v. Auto-Owners Ins. Co. (No. C074546, Filed 1/27/2015) (“Greenwell”), the California Court of Appeal, Third Appellate District, held a California resident could not establish specific personal jurisdiction over an insurance company, located in Michigan, which issued a policy of insurance to the California resident where the claimed loss occurred in Arkansas. Plaintiff purchased a policy of insurance from defendant, Auto-Owners Ins. Co. (“Auto”), a Michigan corporation. The policy provided commercial property coverage for an apartment building owned by Plaintiff, located in Arkansas. The policy also provided commercial general liability coverage for plaintiff’s property ownership business, which plaintiff operated from California. Both coverage provisions insured certain risks, losses, or damages that could have arisen in California. The dispute which arose between Plaintiff and Defendant, however, involved two fires that damaged the apartment building in Arkansas. As a result of coverage decisions that Auto made in the handling of the claim, plaintiff filed suit for breach of contract and bad faith. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys R. Bryan Martin, Lawrence S. Zucker II and Kristian B. Moriarty Mr. Martin may be contacted at bmartin@hbblaw.com; Mr. Zucker may be contacted at lzucker@hbblaw.com; and Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Guilty Pleas Draw Renewed Interest In Nevada’s Construction Defect Laws

December 09, 2011 — CDJ STAFF

A report this week by David McGrath Schwarz of the Las Vegas Sun suggests that Nevada’s construction defect laws will be a point of much contention in upcoming legislative sessions. The report cites renewed interest in the state’s construction defect laws due to ongoing federal investigations of construction defect attorney Nancy Quon and construction company owner Leon Benzer. Guilty pleas have been entered by at least ten individuals including an attorney, property managers, straw purchasers, and former HOA board members.

The article suggests that Nevada’s Chapter 40 laws are easily manipulated to the detriment of Nevada’s homebuilding industry. Construction industry lobbyists have tried unsuccessfully to change the laws in past legislative sessions.

The Sun’s article speculates that the building industry might be able to gain legislative concessions due to the volume of guilty pleas and what it refers to as examples of Chapter 40 abuses. ”With federal authorities collecting guilty pleas, the construction industry has prime examples of the system being abused, and how lucrative it can be for attorneys.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Insurer Must Defend Faulty Workmanship Claims

May 02, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The court determined that the insurer improperly denied a defense for construction defect claims made against the insured. Amerisure Mut. Ins. Co. v. McMillin Tex. Homes, 2022 U.S. Dist. LEIS 40363 (W.D. Texas March 8, 2022). McMillin was a developer, general contractor and home seller. It constructed multiple homes in various communities in the San Antonio area. After the homes were completed, homeowners observed defects in the artificial stucco exterior finish. After claims were lodged against McMillin, the various claims were tendered to Amerisure. Amerisure filed for declaratory judgment that it had to duty to defend or indemnify and moved for summary judgment. Amerisure first argued the homeowners' faulty workmanship claims did not allege "property damage" under the policies. It argued there were no allegations that any property damage existed, but merely that the stucco suffered from construction defects. The court disagreed. Among the allegations was the statement that due to the construction defects, the homes suffered damage "not only to the exterior stucco, but also to the underlying wire lath, paper backing, house wrap, flashing, water resistive barriers, sheathing, interior walls, interior floors and/ or other property." Consequently, the underlying claims amounted to property damage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Living Not So Large: The sprawl of television shows about very small houses

March 12, 2015 — S Jhoanna Robledo – Bloomberg
Vince and Sam are newlywed twentysomethings who’ve been bunking with family for a year. Finally, they’ve saved up enough to buy a palace to call their own. Well, sort of: They want to shrink their footprint and expenses by living in a custom-built, 204-square-foot standalone house in southern New Jersey. It has to have room for gym equipment—they’re fitness buffs—and a study for Sam, who’s in medical school. Even Vince’s adorably headbanded mom isn’t sure how it will all fit. When Vince and Sam first see their new digs under construction, tall and narrow like a top-heavy garage, Vince admits they’re “freaking out on the inside.” So goes a standard episode of Tiny House Nation, the first of a half-dozen miniaturized real estate shows that have recently premiered. “We discovered that for millennials, there was an overriding social trend of extreme downsizing, and we wanted to dig deep into that,” says Gena McCarthy, executive producer of the show, which began airing last year after the Biography Channel morphed into the youth-focused FYI network. Last summer’s first season averaged 257,000 viewers per week, according to Nielsen; this season’s average viewership is up 77 percent, to 465,000. Read the court decision
Read the full story...
Reprinted courtesy of S Jhoanna Robledo, Bloomberg

Hong Kong Popping Housing Bubbles London Can’t Handle

July 30, 2014 — Frederik Balfour – Bloomberg
Take a look at the world’s dizzying surges in the price of housing for 12 months at the end of June: London, up 20 percent. Manhattan, 18 percent. Sydney, 15.4 percent. Then there are Singapore and Hong Kong: down 3.7 percent and 0.6 percent. Prompted by concerns over potential property bubbles and affordability for the middle class, the governments of the two Asian cities have been reining in home prices by imposing measures including mortgage caps, taxes on property flippers, and levies on foreign buyers as high as 15 percent. Read the court decision
Read the full story...
Reprinted courtesy of Frederik Balfour, Bloomberg
Mr. Balfour may be contacted at fbalfour@bloomberg.net

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES