CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Recent Decision Further Jeopardizes Availability of Additional Insured Coverage in New York

July 08, 2024 — Nina Catanzaro & Bethany L. Barrese - Saxe Doernberger & Vita, P.C.
Additional insured endorsements often provide “blanket” coverage to persons or organizations as required by a written contract. However, the wording of the “blanket” language is critically important, as the inclusion of certain phrases in an additional insured endorsement can result in a denial of coverage for the upstream party. For example, risk transfer issues can arise when an additional insured endorsement provides coverage to parties “when you [the named insured] and such person or organization [the additional insured] have agreed in writing in a contract or agreement.” Courts in New York (among other jurisdictions) have interpreted this phrase to require contractual privity – that is, only the entity that contracted directly with the named insured is entitled to additional insured coverage, even if the named insured agreed in that contract to provide additional insured coverage for others as well. The same goes for the phrase “any person or organization with whom you [the named insured] have agreed to add as an additional insured by written contract.” Reprinted courtesy of Nina Catanzaro, Saxe Doernberger & Vita, P.C. and Bethany L. Barrese, Saxe Doernberger & Vita, P.C. Ms. Catanzaro may be contacted at NCatanzaro@sdvlaw.com Ms. Barrese may be contacted at BBarrese@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Lumber Drops to Nine-Month Low, Extending Retreat From Record

August 30, 2021 — Marcy Nicholson - Bloomberg
Lumber futures slid to the lowest in more than nine months after sawmills ramped up production and demand from builders stabilized. September futures in Chicago fell as much as 4.4% to $482.90 per thousand board feet, the lowest for a most-active contract since Oct. 30. Prices have dropped more than 70% from the record high reached just three months ago. The tumble marks a stark turnaround for the common building material after strong U.S. construction demand during the pandemic spurred a surge in orders for lumber, causing prices to more than quadruple to their May peak and fueling inflation concerns. Sawmills have since increased output, and a shortage of other building supplies such as siding and windows has slowed the pace of construction, said Brian Leonard, an analyst with RCM Alternatives. Read the court decision
Read the full story...
Reprinted courtesy of Marcy Nicholson, Bloomberg

---

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

---

Contractor Side Deals Can Waive Rights

October 02, 2023 — Christopher G. Hill - Construction Law Musings
Here at Construction Law Musings, we are quite fond of the Federal Miller Act and it’s Virginia counterpart, the “Little” Miller Act. Both of these statutes allow a subcontractor or supplier on a government construction project the security to perform their work with the knowledge that a bonding company will back their claim for payment. These acts are necessary because a construction company cannot file a mechanic’s lien on a government owned piece of property. As a general rule the Miller Acts impose almost strict liability on a contractor and its surety to pay for work performed by a downstream supplier or subcontractor. However, as a recent case out of the Fourth Circuit Court of Appeals makes clear, this rule is not without exceptions. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Canada's Ex-Attorney General Set to Testify About SNC-Lavalin Scandal

April 03, 2019 — Associated Press - Engineering News-Record
TORONTO (AP) — Canada's former attorney general is expected to testify Wednesday about whether she was inappropriately pressured by Prime Minister Justin Trudeau's office to avoid prosecuting a major Canadian engineering company. Ex-Attorney General Jody Wilson-Raybould has said she wants to tell "her truth" and she will speak at a hearing of the Parliament justice committee. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

---

Pending Sales of U.S. Existing Homes Rise Most in Four Years

July 01, 2014 — Jeanna Smialek – Bloomberg
The number of contracts to purchase previously owned U.S. homes jumped in May by the most in more than four years, a sign the residential-real estate market is rebounding after a slow start to the year. The pending home sales index climbed 6.1 percent, the biggest advance since April 2010, after a revised 0.5 percent increase in April, the National Association of Realtors said today in Washington. The gain exceeded the most optimistic estimate in a Bloomberg survey of economists, whose median forecast called for a 1.5 percent gain. Housing demand is benefiting from cheaper borrowing costs, a stronger employment outlook and easier access to credit for some households. At the same time, higher prices and limited income gains are keeping the improvement in the residential real estate from becoming more broad-based. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

---

Massachusetts Lawyers Weekly Honors Construction Attorney

November 20, 2013 — CDJ STAFF
Massachusetts Lawyers Weekly has named Grace V. B. Garcia one of its 2013 Top Women of the Law. She is an attorney at Morrison Mahoney LLP in Boston, and her practice focuses on construction law, product liability, premises liability, commercial litigation, and American with Disability Act cases. Read the court decision
Read the full story...
Reprinted courtesy of

---

Is the Issuance of a City Use Permit Referable? Not When It Is an Administrative Act

January 10, 2018 — Adam E. Lang - Real Estate Litigation Blog
Arizona’s Constitution gives electors in cities, towns, and counties the ability to refer legislation that was enacted by their local elected officials to the ballot for popular vote. Ariz. Const. art. IV, Pt. 1 § 1(8). But only legislative acts are referable; administrative acts are not. In general, a legislative act makes new law and creates policy, is permanent in nature, and is generally applied. On the other hand, an administrative act is one that executes and implements a law already in place. Wennerstrom v. City of Mesa, 169 Ariz. 485, 489-90, 821 P.2d 146, 150-51 (1991). For more than fifty years, Arizona courts have been clear: zoning and rezoning ordinances are legislative acts and therefore referable to popular vote. City of Phoenix v. Fehlner, 90 Ariz. 13, 17, 363 P.2d 607, 609 (1961) (holding that “what constitutes an appropriate zone is primarily for the legislature”); Fritz v. City of Kingman, 191 Ariz 432, 432, 957 P.2d 337, 337 (1998) (noting “we reaffirm our view that zoning decisions are legislative matters subject to referendum”); Pioneer Trust Co. of Arizona v. Pima Cty., 168 Ariz. 61, 64–65, 811 P.2d 22, 25–26 (1991) (holding “that, in Arizona, zoning decisions are legislative acts subject to referendum” and that even a “conditional approval of . . . rezoning was a legislative act”); Cottonwood Dev. v. Foothills Area Coal. of Tucson, Inc., 134 Ariz. 46, 653 P.2d 694 (1982) (analyzing whether zoning referendum complied with statutory requirements); Wait v. City of Scottsdale, 127 Ariz. 107, 108, 618 P.2d 601, 602 (1980) (noting “that the enactment and amendment of zoning ordinances constitute legislative action”); City of Phoenix v. Oglesby, 112 Ariz. 64, 65, 537 P.2d 934, 935 (1975) (“The matter of zoning is appropriately one for the legislative branch of government.”); Queen Creek Land & Cattle Corp. v. Yavapai Cty. Bd. of Sup’rs, 108 Ariz. 449, 452, 501 P.2d 391, 394 (1972) (denying an attempt to enjoin referendum on county’s zoning decision). Read the court decision
Read the full story...
Reprinted courtesy of Adam E. Lang, Snell & Wilmer
Mr. Lang may be contacted at alang@swlaw.com

---