Fairfield Connecticut Building Expert Directory

Seven Proactive Steps to Avoid Construction Delay Disputes

September 29, 2021 — Michael Pink - Construction Executive
Delays, cost overruns and disputes have long been part of the commercial construction industry, making the work of reactive forensic analysis by consultants and attorneys a necessary component. Yet many internal practices and issues within construction companies strongly correlate with projects that result in legal disputes and financial losses. There are seven proactive steps that can help companies minimize losses and claims. Prepare a Cost- and Resource-Loaded Critical Path Method Schedule This is the first step any contractor can take to establish and document a manpower plan, a timeline and an intended flow for its work. Doing so is beneficial for two reasons: it will become the basis for measuring impacts and variances to both cost and schedule in a delay, dispute or claim setting; and it will serve as a great project management resource or tool. Without thinking through manpower, durations and workflow in great detail at the beginning of the project, contractors put themselves at risk of becoming delayed and blowing the budget. Reprinted courtesy of Michael Pink, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Uniform Rules Governing New York’s Supreme and County Courts Get An Overhaul

February 08, 2021 — Andrew I. Hamelsky, Jenifer A. Scarcella & Monica Doss - White and Williams LLP
By Administrative Order effective February 1, 2021, New York’s Uniform Civil Rules for the Supreme Court will incorporate a number of changes to the general part that reflect many of New York’s Commercial Division Rules, in an effort to streamline court processes. The general part rule changes are a step forward for improving the efficiency, modernization and cost-effectiveness of the New York Courts, and will require practitioners to be more conscientious of court appearances and deadlines. Judges will likely be strict on adherence to the new Uniform Rules. Some notable changes to the rules are highlighted below. Court Appearances and Scheduling Orders Uniform Rule 202.1 has been revised to require that counsel who appear before the court must be familiar with the case they are appearing for, and be fully prepared and authorized to discuss and resolve the issues that are the subject of the appearance. Reprinted courtesy of Andrew I. Hamelsky, White and Williams LLP, Jenifer A. Scarcella, White and Williams LLP and Monica Doss, White and Williams LLP Mr. Hamelsky may be contacted at hamelskya@whiteandwilliams.com Ms. Scarcella may be contacted at scarcellaj@whiteandwilliams.com Ms. Doss may be contacted at dossm@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Wilke Fleury Attorneys Featured in 2021 Best Lawyers in America and Best Lawyers: Ones To Watch!

August 16, 2021 — Wilke Fleury LLP
Wilke Fleury congratulates attorneys David Frenznick, Adriana Cervantes and Dan Egan on their inclusion in the 2021 Edition of Best Lawyers in America! Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 108,000 industry leading lawyers are eligible to vote (from around the world), and they have received over 13 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. For the 2021 Edition of The Best Lawyers in America©, 9.4 million votes were analyzed.

Daniel L. Egan

First year recognized in Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law: 2021

David A. Frenznick

First year recognized in Litigation – Real Estate: 2016

Adriana C. Cervantes

First year recognized in Medical Malpractice Law – Defendants: 2021

Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Another Colorado Construction Defect Reform Bill Dies

May 07, 2014 — Beverley BevenFlorez-CDJ STAFF
Colorado construction defects reform Senate Bill 220 died when “Senate President Morgan Carroll, D-Aurora, declined to call a second committee to hear” the bill, according to Ed Sealover writing for the Denver Business Journal. Sen. Carroll declared that the “bill backers” did not incorporate any of the “suggestions she or House Speaker Mark Ferrandino had given them.” “SB 220 would have required condo-unit owners to submit to alternative-dispute resolution such as arbitration or mediation if the unit developer required it,” Sealover reported. “And it would have required that a majority of members of a homeowners association agree to file a lawsuit, a standard significantly larger than the two-person bar that now must be met.” Bill Cosponsor Sen. Mark Scheffel, R-Castle Rock, “believes litigation reform” will become “an election issue and” that it “has strong momentum heading into the 2015 session.” Read the court decision
Read the full story...
Reprinted courtesy of

Milwaukee's 25-Story Ascent Stacks Up as Tall Timber Role Model

January 25, 2021 — Nadine M. Post - Engineering News-Record
In January 2019, Preston Cole left his post as Commissioner of the Milwaukee Dept. of Neighborhood Services and became Secretary of Wisconsin’s Dept. of Natural Resources. It was a step up for the 25-year veteran of public service—a forester by profession—who as the city’s top building official had reformed DNS by fostering a developer-friendly environment. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Developer Sues TVA After It Halts Nuke Site Sale

December 19, 2018 — Mary B. Powers - Engineering News-Record
The multibillion-dollar completion of a nuclear unit at the Tennessee Valley Authority’s unfinished 1,260-MW Bellefonte plant in Alabama is in limbo after the federal power producer refused to complete its sale to Nuclear Development LLC, which has since filed a breach of contract complaint in federal district court. Read the court decision
Read the full story...
Reprinted courtesy of Mary B. Powers, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Heatup of Giant DOE Nuclear Waste Melter Succeeds After 2022 Halt

August 21, 2023 — Tim Newcomb - Engineering News-Record
Before 56 million gallons of long-stored radioactive waste at the federal Hanford nuclear waste site in Washington state can be turned into vitrified glass for disposal beginning in 2024, crews from the U.S. Energy Dept and Bechtel National that built and are commissioning the site's giant waste vitrification plant need to heat up its two 300-ton melters, the world's largest, to 2,100° F. Reprinted courtesy of Tim Newcomb, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Skyline Bling: A $430 Million Hairpin Tower and Other Naked Bids for Tourism

January 21, 2015 — Toluse Olorunnipa – Bloomberg
American cities are starting an architectural arms race to the sky with super-sized Ferris wheels, a 100-story observation tower and maybe even a mammoth golf ball atop a 300-foot tee planted in the Arizona desert. From Phoenix to Camden, New Jersey, city officials and developers are seeking to punctuate their skylines with exclamation points, vying for the world’s attention with the next Eiffel Tower or London Eye. Read the court decision
Read the full story...
Reprinted courtesy of Toluse Olorunnipa, Bloomberg
Mr. Olorunnipa may be contacted at tolorunnipa@bloomberg.net

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES