Seattle Washington Building Expert Directory

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Lasso Needed to Complete Vegas Hotel Implosion

February 18, 2015 — Beverley BevenFlorez-CDJ STAFF
The Miami Herald reported that “demolition workers used an Old West method on Tuesday to finish an incomplete casino implosion in Las Vegas.” The Clarion Hotel and Casino owner Lorenzo Doumani told the Miami Herald that “[t]hey lassoed the building with steel cables, got a crane, and pulled and pulled and pulled.” Burke Construction used a 2-ton explosive punch to bring the structure down, however, the concrete building dropped four stories but remained upright. Burke Construction’s corporate safety coordinator, Anthony Schlect, told the Miami Herald that he was investigating the incident. Read the court decision
Read the full story...
Reprinted courtesy of

South Carolina Homeowners May Finally Get Class Action for Stucco Defects

December 04, 2013 — CDJ STAFF
Last year, Judge J. Michael Baxley approved a class action lawsuit over stucco problems in Sun City Hilton Head. The lawyers from S.C. State Plastering have already settled with about 140 defendants in that community, and they are trying to prevent the plaintiff’s lawyers from communicating with other residents. In June, a judge dismissed S.C. State Plastering’s request to block this communication, but the company has appealed. The South Carolina Supreme Court has heard the case regarding the notices and has yet to rule. The Chief Justice has recused herself, stating that she has a connection to the case, although she has not elaborated. Many homeowners have waited to repair their homes, hoping to receive compensation. Pulte Homes, the builder of the project, has also repaired some homes. It is not clear if those homeowners are eligible for the class action lawsuit. Read the court decision
Read the full story...
Reprinted courtesy of

Idaho Construction Executive Found Guilty of Fraud and Tax Evasion

October 01, 2013 — CDJ STAFF
A former president of the Associated General Contractors in Idaho has been found guilty of attempting to defraud the U.S. Government. Elaine Martin filed false income taxes, allowing her to participate in a program that helped economically and socially disadvantaged businesses. Ms. Martin has convicted on both the fraud tax evasion charges. Ms. Martin’s business partner, Darrell Swigert, has also been convicted. He was found guilty of obstruction of justice. Mr. Swigert helped Ms. Martin conceal the extent of her income. Read the court decision
Read the full story...
Reprinted courtesy of

Big Data Meets Big Green: Data Centers and Carbon Removal Compete for Zero-Emission Energy

October 15, 2024 — Robert A. James, Sidney L. Fowler & Ashleigh Myers - Gravel2Gavel Construction & Real Estate Law Blog
Artificial intelligence, data centers, carbon removal and zero-emission power may sound like a winning line (plus the Free Space) on a 2024 Buzzword Bingo card. But the concepts have come into dramatic real-world tension as private and public actors seek to accommodate the digital and environmental imperatives for green energy. After years of fairly stable demand, punctuated by declines during the pandemic and economic slumps, electricity demand is projected to double by 2050. A principal cause is the rapid expansion in the power needed to energize and cool servers amid explosive growth in the number and size of data centers, crypto miners, and other point sources of computation. Data centers were 3% of U.S. demand and are projected to be up to 9% or more by 2030; AI will drive a 160% surge in data center demand by 2030. A commentator notes, “We haven’t seen [growth like] this in a generation.” Reprinted courtesy of Robert A. James, Pillsbury, Sidney L. Fowler, Pillsbury and Ashleigh Myers, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Fowler may be contacted at sidney.fowler@pillsburylaw.com Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Berkeley Researchers Look to Ancient Rome for Greener Concrete

June 28, 2013 — CDJ STAFF
While modern concrete often crumbles after fifty years, some concrete laid down during the Roman Empire is still strong, even after 2,000 years. Researchers at UC Berkeley have been puzzling over the secrets of Roman concrete, using samples from a breakwater near Naples. The breakwater was built about 37 BC, and the concrete is still strong. Unlike modern concrete, the Romans made theirs with a mixture of lime and volcanic ash. Paulo Monteiro, a professor of civil and environmental engineering at Berkeley, noted that one of the drawbacks of Roman cement was that it hardens more slowly than modern concrete. An advantage is that it is more environmentally friendly, and the researchers are trying to determine if volcanic ash cement would be a good substitute. Professor Montiero hopes that fly ash and volcanic ash cements “could replace 40 percent of the world’s demand for Portland cement.” Read the court decision
Read the full story...
Reprinted courtesy of

When Can Customers Sue for Delays?

September 18, 2023 — Scott L. Baker - Los Angeles Litigation Blog
Construction projects are subject to many internal and external factors. Due to this, delays are not an uncommon occurrence. Whether delays are the result of bad weather conditions or supply chain issues, contractors and their clients cannot control every aspect of the project. Delay issues are very common construction disputes. Therefore, new and experienced contractors alike need to know when their clients may have a reason for a delay claim. 2 particular types of delays that pose a risk Common obstacles that contractors faced during the height of the COVID-19 global pandemic involved supply chain issues. The lack of materials put various projects on hold across California and the country. This widespread issue was out of contractors’ and clients’ control, meaning they were excusable delays. Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

Champagne Wishes and Caviar Dreams. Unlicensed Contractor Takes the Cake

August 31, 2020 — Garret Murai - California Construction Law Blog
Before the Kardashians, before Empire, before Crazy Rich Asians there was Lifestyles of the Rich and Famous with Robin Leach. The next case, Moore v. Teed, Case No. A153523 (April 24, 2020), 1st District Court of Appeals, is about the unfulfilled wishes and dashed dreams of the $13 million dollar “fixer upper.” Moore v. Teed The $13 Million Dollar “Fixer Upper” Justin Moore just wanted to buy a house in San Francisco. But he couldn’t afford one in the neighborhoods he preferred. But in 2011, luck struck, when Moore met Richard Teed, a real estate agent with “over 25 years of experience as a building contractor,” “an extensive background in historic restorations” and a “deep understanding of quality construction.” Teed told Moore that he could locate a “lower-priced fixer-upper in a choice neighborhood and then renovate it.” Moore was sold. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES