FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Waiver of Subrogation Enforced, Denying Insurers Recovery Against Additional Insured in $500 Million Off-Shore Oil Rig Loss

September 30, 2019 — Sergio F. Oehninger & Daniel Hentschel - Hunton Insurance Recovery Blog
The United States District Court for the Southern District of Texas recently rejected a claim by a group of insurance companies (“Underwriters”) against American Global Maritime Inc. for more than $500 million that the Underwriters paid the named insured under an Off-Shore Construction Risk insurance policy for losses resulting from the an alleged off-shore oil rig failure. The action arose out of alleged construction defects related to Chevron’s “Big Foot” oil-drilling platform in the Gulf of Mexico. Chevron hired American Global to be the marine warranty surveyor responsible for reviewing and certifying the project’s specifications and materials. American Global issued the certificate of approval required for the project to proceed; however, during the attempted installation of the platform in 2015, it was alleged that parts from the structure fell to the sea floor. The Underwriters paid more than $500 million in connection with the incident under an Off-Shore Construction insurance policy they had issued to Chevron. After paying the claim, the Underwriters filed a negligence action against American Global and other contractors involved in the project. Reprinted courtesy of Sergio F. Oehninger, Hunton Andrews & Kurth and Daniel Hentschel , Hunton Andrews & Kurth Mr. Oehninger may be contacted at soehninger@HuntonAK.com Mr. Hentschel may be contacted at dhentschel@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

The Prolonged Effects on Commercial Property From Extreme Weather

January 29, 2024 — The Hartford Staff - The Hartford Insights
As evidenced by the extraordinary heat in the Southwest, a string of tornadoes in South and Midwest, and heavy rains in California and Florida, 2023 was a banner year for extreme weather. However, 2024 may be no different, which means now is the time for businesses to rethink the way they approach volatile weather, as well as the frequency and severity of storms and natural disasters. The risks and challenges that businesses face as extreme weather becomes stronger and causes more property damage, requires innovative technology with specialized insurance solutions. Through updated building codes, advancements in technology and meaningful infrastructure improvements, businesses can make a difference in protecting their property and reducing losses. Stronger Building Codes To Withstand Storms It is not uncommon to see the destruction that a hurricane or tornado leaves behind. However, stronger building codes are one of the best ways to make sure property can withstand catastrophes. Florida for example implemented changes to its building codes after Hurricane Andrew, and then again in 2007 after the Hurricanes of 2004 and 2005. New construction since then has made houses and buildings significantly more hurricane proof. Buildings constructed 30 years ago were likely built with codes that may have neglected the impact of strong winds from an extreme hurricane or significant rainfall that a storm can bring, especially along the Atlantic and Gulf coasts. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

---

First-Time Buyers Home Sales Stagnates

October 22, 2014 — Beverley BevenFlorez-CDJ STAFF
Despite a rise overall in home sales, “first-time buyer share remained unchanged from the previous two months at 29%, far behind the historical average first-time buyer share of about 40%,” reported National Association of Home Builders’ Eye on Housing. However, “[e]xisting home sales increased to the highest level of the year, having posted gains for five of the last six months, despite weakness among first-time buyers. Existing home sales increased 2.4% in September, but remain 1.7% below the same period a year ago.” According to Eye on Housing, existing sales is expected to continue to increase throughout the year, though the first-time buyer segment is “the weak spot.” Read the court decision
Read the full story...
Reprinted courtesy of

---

California Case Is a Reminder That Not All Insurance Policies Are Alike Regarding COVID-19 Losses

April 05, 2021 — Neal I. Sklar & Joshua A. Morehouse - Peckar & Abramson, P.C.
A recent case from the Central District of California reminds us that not all insurance policies are alike. Depending on the particular policy, losses from the COVID-19 outbreak could qualify as property damage and therefore could be recoverable under an all-risk insurance policy. COVID-19 has in many cases imposed significant costs on contractors, and in a host of ways. Contractors’ attempts to recover these costs from owners or insurers have at times been frustrated by contractual or policy language written after a lengthy time, during which the risk of a pandemic on the scale of COVID-19 was not as much of a concern as it is now. This has led contractors to explore new, often creative legal theories in their attempts to recover costs flowing from COVID-19. A recent Complaint filed in the Central District of California focuses on all-risk property insurance policies and the potential for contractors who have purchased such policies to classify contamination from COVID-19 as an insurable property loss. In AECOM v. Zurich Insurance Company, Case No. 2:21-cv-00237-JAK-MRW (C.D. Cal), a contractor purchased “all-risk” property insurance from Zurich. This policy covered “economic losses from all risks not expressly excluded.” According to the Complaint, the presence of COVID-19 on its properties “physically alter[ed] air, airspace, and surfaces preventing… (the contractor) from using its properties for their intended purpose and function.” Reprinted courtesy of Neal I. Sklar, Peckar & Abramson, P.C. and Joshua A. Morehouse, Peckar & Abramson, P.C. Mr. Sklar may be contacted at nsklar@pecklaw.com Mr. Morehouse may be contacted at jmorehouse@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

BWBO Celebrating Attorney Award and Two New Partners

July 14, 2016 — Beverley BevenFlorez-CDJ STAFF
Congratulations is due to Nicole Whyte of Bremer Whyte Brown & O’Meara LLP (BWBO) for being recognized as one of America’s Top 100 Attorneys by America’s Top 100, which identifies the top 100 attorneys in each state. In an email release, the firm stated, “We are pleased to celebrate this lifetime achievement and it is an honor to have Ms. Whyte listed alongside her esteemed peers.” Furthermore, BWBO announced that two of their attorneys have been promoted to partner: Alex Giannetto and Benjamin Price. “Mr. Giannetto believes that hard work, dedication, caring about clients and work product, and surrounding himself with good people, has helped him become successful in his profession,” as stated in an email release. “To be successful you have to surround yourself with successful people,” Mr. Price stated. “A combination of humility, confidence, and hard work is also important.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Bond Principal Necessary on a Mechanic’s Lien Claim

September 07, 2020 — Christopher G. Hill - Construction Law Musings
As anyone that reads this construction law blog knows, mechanic’s liens are a big part of the Virginia landscape for a construction attorney like me. One option for dealing with a mechanic’s lien here in Virginia that we have not discussed but so often is the ability to “bond off” a lien. In short, the Virginia statute allows a party to essentially substitute a bond valued at a court set multiple of the principal amount of the mechanic’s lien for the memorandum. In exchange, the lien is released of record. Any enforcement action can still proceed with security for the claimant and the property owner feeling better about things because there will be no lien on the title to the land. In many ways this process provides an easier path to resolution for both owner and claimant. First of all, the claimant does not have to deal with a bank or other interest holders in the property (though a recent case discussed below reminds us that certain other parties are necessary). Second of all, the owner does not have the cloud on the title of a mechanic’s lien that may have been filed by a subcontractor over which he has no control. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

What You Should Know About Liquidated Damages and Liability Caps for Delay and Performance Liquidated Damages

May 06, 2024 — Chris Cazenave - ConsensusDocs
Liquidated damage clauses are omnipresent in today’s construction contracts—often considered in early negotiations to provide a degree of certainty and limit financial liability. There are two principal types of LDs appearing in construction contracts—(i.) damages for delay when a contractor fails to deliver a project by a certain milestone; and (ii.) performance damages when a contractor fails to meet specific performance requirements. Differentiating between LDs for delay and LDs for performance—especially when both LD types are combined in the same contract—is key to risk awareness and allocation during contract negotiations and throughout performance. This article briefly outlines what you should know about LDs for delay and LDs for failing to meet certain performance requirements. The article also covers how contractors can allocate and cap risks based on risks each party can either manage, insure, or otherwise limit. Read the court decision
Read the full story...
Reprinted courtesy of Chris Cazenave, Jones Walker LLP
Mr. Cazenave may be contacted at ccazenave@joneswalker.com

---