Seattle Washington Building Expert Directory

Congratulations to BWB&O’s 2024 Southern California Super Lawyers!

February 05, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
BWB&O is excited to announce that Partners Nicole Whyte, Keith Bremer, John Toohey, and Tyler Offenhauser have been selected in the 2024 Southern California Super Lawyers list as Super Lawyers for their work in Business Litigation, Family Litigation, Personal Injury Litigation, and Construction Litigation. To read Super Lawyers’ digital publication, please click here. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The objective of Super Lawyers’ patented multiphase selection process is to create a credible, comprehensive, and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. Please join us in congratulating Nicole, Keith, John, and Tyler on achieving this level of recognition! Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

Business Interruption Insurance Coverage Act of 2020: Yet Another Reason to Promptly Notify Insurers of COVID-19 Losses

May 25, 2020 — James Hultz - Newmeyer Dillion
Business interruption coverage stemming from the COVID-19 pandemic is a matter of intense debate. The number of policyholder lawsuits continues to rise sharply and an increasing number of state legislatures are considering laws to specifically address such coverage. Now, additional proposed legislation at the federal level could completely and definitively resolve the debate in favor of coverage for policyholders. The Business Interruption Insurance Coverage Act of 2020 On April 14, Congress introduced the Business Interruption Insurance Coverage Act of 2020 (the “Act”) which, if passed, would require insurance companies to cover business interruption losses due to “viral pandemics, forced closures of businesses, mandatory evacuations, and public safety power shut-offs.” The bill further states:

Any exclusion in a contract for business interruption insurance that is in force on the date of the enactment of this Act shall be void to the extent that it excludes losses specified . . . .

The draft legislation also specifies that it preempts state approval of any contrary exclusion and renders such approval “void to the extent that it excludes losses specified.” Read the court decision
Read the full story...
Reprinted courtesy of James Hultz, Newmeyer Dillion
Mr. Hultz may be contacted at james.hultz@ndlf.com

Another Colorado City Passes Construction Defects Ordinance

February 18, 2015 — Beverley BevenFlorez-CDJ STAFF
Lone Tree, Colorado’s City Council passed an ordinance to distinguish its construction defect laws from the state’s, according to the Denver Business Journal. The city of Lakewood passed a similar ordinance last October. The Denver Business Journal reported that the new “ordinance makes changes such as establishing time frames for notifying the builder of a construction defect, allowing the builder to inspect the property and allowing the builder to repair the problem, with the homeowners' agreement.” Read the court decision
Read the full story...
Reprinted courtesy of

Wisconsin High Court Rejects Insurer’s Misuse of “Other Insurance” Provision

March 04, 2019 — Michael S. Levine & David M. Costello - Hunton Andrews Kurth
The Wisconsin Supreme Court held last week in Steadfast Ins. Co. v. Greenwich Ins. Co. that two insurers must contribute proportionally to the defense of an additional insured under their comprehensive liability policies. In 2008, torrential rainstorms battered the Milwaukee area for two days. The downpour overwhelmed the city’s sewer system, causing significant flooding in homes throughout the region. Out of those floods sprang several lawsuits against the Milwaukee Metropolitan Sewerage District (“MMSD”) for negligent inspection, maintenance, repair, and operation of Milwaukee’s sewage system. MMSD was an additional insured under liability policies covering two other water service providers responsible for the city’s sewer systems. The first policy was issued by Greenwich Insurance Company for United Water Services Milwaukee, LLC, and the second was issued by Steadfast Insurance Company for Veolia Water Milwaukee, LLC. After learning of the lawsuits, MMSD tendered its defense of the sewage suits to both insurers. Steadfast accepted the defense; but Greenwich refused, claiming that its policy was excess to Steadfast’s based on an “other insurance” clause in Greenwich’s policy. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and David Costello, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Costello may be contacted at dcostello@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

California Court of Appeals Says, “We Like Eich(leay)!”

March 30, 2016 — Garret Murai – California Construction Law Blog
Time is money. And nowhere can than be best observed than on a construction project. Project delays can mean lost profits for owners, liquidated damages for general contractors, and increased material, labor, field overhead, and home office overhead costs for general contractors and subcontractors alike. Pricing the impact of delays, however, can be thorny. Particularly, for home office overhead. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Mortgage Interest Rates Increase on Newly Built Homes

April 30, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the National Association of Home Builders’ (NAHB) Eye on Housing, while the Federal Housing Financing Agency (FHFA) reported a decrease in mortgage interest rates for existing homes, there was an increase in mortgage rates on newly built homes: “The average contract interest rate on conventional mortgages used to purchase newly built homes actually increased in March, from 3.91 to 4.21 percent, reversing an anomalous drop to under 4 percent that occurred in February.” “The average price and loan size on conventional mortgages used to purchase newly built homes also reversed previous month declines in March,” reported Eye on Housing. “The average price increased 5.4 percent to $427,200—the second highest number on record.” Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (3/6/24) – Steep Drop in Commercial Real Estate Investment, Autonomous Robots Being Developed for Construction Projects, and Treasury Department Proposes Regulation for Real Estate Professionals

April 08, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, major league sports franchises turn to real estate to increase their value, the Associated Builders and Contractors releases a guide on artificial intelligence, New York City helps landlords convert empty office space into housing, and more!

The Treasury Department proposed a regulation that would require real estate professionals to report information to the agency about all-cash sales of residential real estate to legal entities, trusts and shell companies. (Fatima Hussein, AP)
For decades, major league teams depended on ticket sales, concessions and TV deals to generate revenue, but team owners in recent years have turned to real estate development to bring in extra cash and drive up the values of their franchises. (Nathaniel Meyersohn, CNN)
The U.S. commercial real estate market saw a steep drop in investment last year, with the market plummeting by more than 50% to the lowest level since 2012 and CBRE noting a 91% year-over-year drop in direct real estate company investments. (Yuheng Zhan, Business Insider)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES