Cambridge Massachusetts Building Expert Directory

Construction Industry on the Comeback, But It Won’t Be the Same

November 20, 2013 — CDJ STAFF
“The majority of contractors have readjusted and there’s cautious optimism, but there’s a new normal in construction,” Cam Dickinson, senior vice president of the construction group of Woodruff-Sawyer. But he cautioned that “it’s not going to come back like it was in the good old days.” Some places, like the Miami or New York City areas are doing well, although New York City has the perhaps unique advantage of its market. Brian Schofeld, Crystal & Co.’s senior managing director and construction practice leader noted that for one New York City project, “the penthouse went for the full value of the gut renovation and that left the other 17 floors as a profit.” Further signs of life are that “the residential private side is going gangbusters in the Bay Area and downtown San Francisco,” according to Bret Lawrence, vice president of construction for Woodruff-Sawyer, but he notes that “it’s nothing like it was.” Read the court decision
Read the full story...
Reprinted courtesy of

No Coverage for Sink Hole Loss

June 18, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found there was no coverage under the commercial property policy for loss suffered by the insured condominium association due to a sink hole. Bahama Bay II Condo. Ass'n. v. Untied Nat'l Ins. Co., 2019 U.S. Dist. LEXIS 67487 (M.D. Fla. April 11, 2019). The plaintiff condominium association had thirteen buildings inside their complex. On December 9, 2016, a sinkhole appeared near Building 43. The building was vacated and declared unsafe. Plaintiff's board excused Building 43 owners from paying association dues. Plaintiff submitted a claim to the insurer for benefits under the policy. The insurer inspected and accepted coverage for Building 43 under the policy's Catastrophic Ground Cover Collapse (CGCC) provision and issued a check for $290,000 for immediate repairs. The insurer denied coverage for Buildings 42, 44, and 45; repairs to the foundation of all buildings, the retaining wall and outdoor fences; land, landscaping, and patios, uncollected association dues, and condominium unit owner property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurer’s Broad Duty to Defend in Oregon, and the Recent Ruling in State of Oregon v. Pacific Indemnity Company

January 02, 2024 — Keith Sparks - Ahlers Cressman & Sleight PLLC
Oregon law mandates a broad duty to defend, requiring insurers to provide legal representation to their policyholders whenever there is a potential for coverage under the policy. The significance of this broad interpretation means that an insurer has a duty to defend an insured even in situations where the alleged facts only imply a covered claim, and even in situations where the underlying claim is ultimately not covered by the policy. The insurer’s duty to defend is triggered if the allegations of the complaint, reasonably interpreted, could result in the insured being held liable for damages covered by the policy. This is referred to as the “four-corners” rule; it is also sometimes referred to as the eight-corners rule (for the four corners of the complaint plus the four corners of the policy). Oregon’s adoption of a broad interpretation of the duty to defend affirmatively places the onus on insurers to err on the side of coverage. This broad duty to defend is based on the principle that an insured should not have to bear the expense of defending a lawsuit that the insurer may ultimately have to pay for. The duty to defend is also important because it helps ensure that insureds have access to legal representation when faced with a lawsuit. Read the court decision
Read the full story...
Reprinted courtesy of Keith Sparks, Ahlers Cressman & Sleight PLLC
Mr. Sparks may be contacted at keith.sparks@acslawyers.com

An Uncharted Frontier: Nevada First State to Prohibit Defense-Within-Limits Provisions

July 10, 2023 — Geoffrey B. Fehling & Andrew S. Koelz - Hunton Insurance Recovery Blog
Nevada recently became the first state to prohibit defense-within-limits provisions in liability insurance policies. Defense-within-limits provisions—resulting in what’s called “eroding” or “wasting” policies—reduce the policy’s applicable limit of insurance by amounts the insurer pays to defend the policyholder against a claim or suit. These provisions are commonly included in errors and omissions (E&O), directors and officers (D&O) and other management liability policies. This is in contrast to other policies, most commonly commercial general liability policies, which provide defense “outside of limits” where defense costs do not reduce the policy’s limit. Reprinted courtesy of Geoffrey B. Fehling, Hunton Andrews Kurth and Andrew S. Koelz, Hunton Andrews Kurth Mr. Fehling may be contacted at gfehling@HuntonAK.com Mr. Koelz may be contacted at akoelz@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

The Importance of the Recent Amendment to Rule 702 of the Federal Rules of Evidence

January 22, 2024 — Andrew G. Vicknair - The Dispute Resolver

Every litigator understands that expert witnesses play a key role in litigation, especially when dealing with construction issues. Expert testimony at trial can be a deciding factor in persuading a judge or jury in your client’s favor. It is so important that, as parties get closer to trial, litigators often spend considerable time filing motions to limit or disqualify certain aspects of expert testimony in an effort to gain an advantage at trial. Because experts are a key aspect of the trial process, it is important to understand the various rules governing use of expert testimony, primarily Rule 702 of the Federal Rules of Evidence.

On December 1, 2023, amendments to Rule 702 of the Federal Rules of Evidence went into effect which added the language in underline below and removed the language which is crossed out:

Rule 702. Testimony by Expert Witness

A witness who is qualified as an expert by knowledge, skill, experience, training, or education may testify in the form of an opinion or otherwise if the proponent demonstrates to the court that it is more likely than not that:

(a) the expert’s scientific, technical, or other specialized knowledge will help the trier of fact to understand the evidence or to determine a fact in issue;

(b) the testimony is based on sufficient facts or data;

(d) ~~the expert has reliably applied~~ expert’s opinion reflects a reliable application of the principles and methods to the facts of the case.

Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Los Angeles Wildfires Rage on, Destroying Structures and Displacing Residents

January 14, 2025 — Aileen Cho - Engineering News-Record
Wildfires in Los Angeles have already destroyed thousands of buildings, but the full extent of the damage will not be known for some time, according to local officials during a media briefing Jan. 9. Read the court decision
Read the full story...
Reprinted courtesy of Aileen Cho, Engineering News-Record
Ms. Cho may be contacted at choa@enr.com

Wisconsin Supreme Court Abandons "Integrated Systems Analysis" for Determining Property Damage

September 12, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The Wisconsin Supreme Court departed from its previous mechanism for determining property damage under the "integrated systems analysis" and found the insurers were not entitled to summary judgment as determined by the trial court. 5 Walworth, LLC v. Engerman Contracting, Inc., 2023 Wis. LEXIS 152 (Wis. June 20, 2023). 5 Walworth LLC hired Engerman as general contractor to construct a swimming pool complex. Engerman subcontracted with Downes Swimming Pool Co., Inc. to construct the pool complex. Otto Jacobs supplied Downes with a ready-mixed concrete called shotcrete, commonly used in swimming poll construction. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES