CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Tips for Drafting Construction Contracts

May 04, 2020 — Stuart Rosen - Construction Executive
When negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern. For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation. This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations. Contractor’s liability to the owner for delay damages It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.” Reprinted courtesy of Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Rosen may be contacted at srosen@proskauer.com

---

25 Days After Explosion, Another Utility Shuts Off Gas in Boston Area

October 30, 2018 — Johanna Knapschaefer - Engineering News-Record
Three hundred thirty-nine homes in Woburn, Mass., were without power on Oct. 8 after National Grid shut off gas meters following the inadvertent over-pressurization of the natural gas line on Oct. 8, according to the Woburn Fire Dept. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, ENR
ENR may be contacted at ENR.com@bnpmedia.com

---

Ohio Court Finds No Coverage for Construction Defect Claims

March 28, 2012 — Tred R. Eyerly - Insurance Law Hawaii

Charles and Valerie Myers hired Perry Miller to build their home. Myers v. United Ohio Ins. Co., 2012 Ohio App. LEXIS 287 (Ohio Ct. App. Jan. 26, 2012). After completion of the home, Miller was again hired to construct an addition which included a full basement, staircases, bathroom, bedroom, hallway and garage.



After the addition was completed, one of the basement walls began to crack and bow. Miller began to make repairs, but eventually stopped working on the project. Other contractors were hired to make repairs, but further problems developed. A second basement wall began to bow and crack, allowing water into the basement. The wall eventually had to be replaced. Subsequently, the roof over the addition began to leak in five or six places before the drywall could be painted. The leaks caused water stains on the drywall and caused it to separate and tear. It was discovered the roof needed to be replaced.



The Myers sued Miller and his insurer, United Ohio Insurance Company. The trial court ruled that the policy did not provide coverage for faulty workmanship, but did provide coverage for consequential damages caused by repeated exposure to the elements. United Ohio conceded liability in the amount of $2,000 to repair water damage to the drywall. United Ohio was also found liable for $51,576, which included $31,000 to repair the roof and ceiling and $18,576 to replace the basement wall.

Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

4 Steps to Take When a Worker Is Injured on Your Construction Site

March 27, 2023 — Zachary Perecman - Construction Executive
The construction industry continues to be one of the fastest-growing labor trades. According to the Center for Construction Research and Training, since 2019, 11.4 million U.S. workers have been employed in construction, a 25% increase from 2011. Amid this growth, the industry has remained one of the most dangerous, and workers are often at higher risk of injuries and deaths due to occupational incidents. According to the U.S. Bureau of Labor Statistics, there are 150,000 injuries on construction work sites annually. Under Occupational Health and Safety Administration (OSHA) law, employers have a responsibility to provide a safe work environment. That includes providing a workplace that is free of serious recognized hazards. Despite best efforts in implementing risk-mitigation and safety protocols, employers must be prepared with an incident procedure should an incident occur on a jobsite. Taking immediate, clear actions can impact the severity and outcome of injuries from a workplace incident. With this in mind, employers should take the lead in implementing safety procedures for injuries on construction sites and should inform all safety site managers and workers of the steps that should be taken. Reprinted courtesy of Zachary Perecman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Contract Not So Clear in South Carolina Construction Defect Case

November 07, 2012 — CDJ STAFF
The South Carolina Court of Appeals has reversed a partial summary judgment issued by one of the lower courts in the case of The Retreat at Edisto Co-Owners Association v. The Retreat at Edisto. The underlying issues of the case deal with a construction defect complaint. The lower court had concluded “Developer’s ‘First Amendment’ to the Master Deed required the Developer to satisfy the provision in the paragraph labeled ‘Master Deed Amendment or Phase II’ as a condition precedent to its election to proceed with the development of Phase II.” The appeals court found that “the language of the First Amendment to the Master Deed is susceptible to more than one interpretation.” The court additionally concluded that the “Developer presented the requisite scintilla of evidence on the question of its intent in order to establish a genuine issue of material fact. As the material facts were in dispute, the appeals court reversed the summary judgment and remanded the case to the circuit court for further proceedings. Read the court decision
Read the full story...
Reprinted courtesy of

---

Michigan Supreme Court Concludes No Statute of Repose on Breach of Contract

July 19, 2011 — CDJ STAFF

Judge Marilyn Kelly of the Michigan Supreme Court has remanded the case of Miller-Davis Co. v. Ahrens Constr. Inc. (Mich., 2011) to the Court of Appeals, after determining that the court had improperly applied the statute of repose. She reversed their judgment, pending a new trial.



Ahrens Construction was a subcontractor, hired by Miller-Davis to build and install a natatorium room at a YMCA camp in Kalamazoo, Michigan. After its installation, the YMCA discovered a severe condensation problem, causing moisture to “rain” from the roof. The architect, testifying for Miller-Davis, alleged that the problems were due to improper installation by Ahrens. Ahrens claimed that the condensation problem was due to a design error.



When the roof was removed and reconstructed, the moisture problem ended. Ahrens argued that the alleged defects were caused by the removal. Further, in trial Ahrens raised the issue of the statute of repose. The court found in favor of Miller-Davis and did not address the statute of repose.



The Court of Appeals reversed the trial court, determining that the statute of repose had barred the suit. This rendered the other issues moot.



The Michigan Supreme concluded that the issue at hand was “a suit for breach of contract,” and that the Michigan statute of repose is limited to tort actions. They remanded the case to the Court of Appeals to address the issues that had been mooted by the application of the statute of repose.



Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Caution to GCs! An Exception to Privette Can Leave You Open to Liability

February 01, 2023 — Nicole Whyte - Bremer Whyte Brown & O'Meara LLP
In a recent important decision, Brown v. Beach House Design & Development the Court of Appeal addressed an issue that frequently arises under the Privette doctrine—the extent to which a general contractor can be held liable for injuries to a subcontractor’s employee. The injuries in Brown arose when a window casing subcontractor’s employee fell from a scaffold erected by a plastering subcontractor at a construction site. According to evidence offered by the plaintiff in opposition to a motion for summary judgment filed by the general contractor, the scaffold was not properly secured to the building where the work was being performed. As a result the scaffold was defective and failed, causing the injuries. Read the court decision
Read the full story...
Reprinted courtesy of Nicole Whyte, Bremer Whyte Brown & O'Meara LLP
Ms. Whyte may be contacted at nwhyte@bremerwhyte.com

---

Bar to Raise on Green Standard

November 07, 2012 — CDJ STAFF
Next June, members of the U.S. Green Building Council will be voting on changes to the LEED green building standard. “The bar is getting raised,” said Navad Malin of BuildingGreen, a consulting and publishing firm, in an article in USA Today. Under the proposed guidelines, builders would have to project energy and water use for five years as part of the certification process. However, if the occupants aren’t as green as the builders anticipated, the buildings will not lose their certification. The new rules will include higher energy standards, award points for avoiding potentially hazardous materials, and even determine what kind of plumbing items can be used. Read the court decision
Read the full story...
Reprinted courtesy of

---