Seattle Washington Building Expert Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Check The Boxes Regarding Contractual Conditions Precedent to Payment

August 21, 2023 — David Adelstein - Florida Construction Legal Updates
Remember this: complying with contractual conditions precedent to payment is important. There is a reason why construction contracts include contractual conditions precedent to payment. The contract does not include this language for sh*ts and giggles. This language is included to establish what is required of the payee before payment becomes due. There may be conditions precedent to the payment of progress payments. There may be conditions precedent to the payment of final payment. Payment is not due until the conditions precedent have been satisfied. Do yourself a favor and consider this language in the construction contract, particularly if a dispute arises. If the condition precedent has not or cannot be satisfied, game plan as to the factual reason. The best thing to do is be prepared – check the boxes regarding conditions precedent to ensure you have considered this contractual language. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Lennar Profit Tops Estimates as Home Prices Increase

March 26, 2014 — John Gittelsohn – Bloomberg
Lennar Corp. (LEN), the biggest U.S. homebuilder by market value, reported a fiscal first-quarter profit that beat analysts’ estimates as the company sold more homes at increased prices. Net income climbed to $78.1 million, or 35 cents a share, in the three months through February, from $57.5 million, or 26 cents, a year earlier, the Miami-based company said in a statement today. Analysts expected earnings of 28 cents a share, the average of 17 estimates compiled by Bloomberg. Publicly traded builders have been increasing prices to take advantage of a tight supply of new and existing homes while using their economies of scale to reduce costs and widen profit margins. Lennar’s profit, deliveries and orders grew even as inclement weather threatened home sales in much of the U.S. during the quarter, according to Drew Reading, a Bloomberg Industries analyst. “Lennar followed KB Home (KBH) in reporting order trends indicating a strong start to the spring selling season,” Reading said in a note after the earnings were released. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelson may be contacted at johngitt@bloomberg.net

AMLO Hits Back at Vulcan, Threatens to Use Environmental Decree

December 04, 2023 — Maya Averbuch & Eric Martin - Bloomberg
Mexico’s president threatened to declare a disputed property owned by Vulcan Materials Co. an environmentally protected area, after failing to reach an agreement with the US construction firm. Andres Manuel Lopez Obrador said Vulcan continued work at the site even while in talks with his government over its potential purchase of the property, which was occupied by Mexican marines in March. Accusing the company of “vile trickery,” AMLO — as the president is known — told reporters Friday that he would act by decree if necessary to halt the destruction in “one of the most beautiful areas in the world.” His comments came a day after Bloomberg reported that the Alabama-based firm was seeking the Biden administration’s protection from what it sees as the threat of a hostile takeover of its property. The 2,400 hectare (5,930 acre) plot south of the resort city of Playa del Carmen includes a port and a quarry. Reprinted courtesy of Maya Averbuch, Bloomberg and Eric Martin, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

New California Construction Laws for 2020

March 09, 2020 — Smith Currie
The California Legislature introduced more than 3,033 bills in the first half of the 2019-2020 session. This article summarizes some of the more important bills affecting contractors in their roles as contractors, effective January 1, 2020, unless otherwise noted. Not addressed here are many other bills that will affect contractors in their roles as businesses, taxpayers, and employers. Each of the summaries is brief, focusing on what is most important to contractors. Because not all aspects of these bills are discussed, each summary’s title is a live link to the full text of the referenced bills for those wanting to explore the details of the new laws. BIDDING & PREQUALIFICATIONS Disabled Veteran Preferences Strengthened (AB 230, Brough) The California Legislature intends that every state procurement authority meet or exceed a DVBE participation goal of a minimum of 3% of total contract value. State departments must require prime contractors to certify at the completion of each contract the amount each DVBE received from the prime contractor, among other information. This new law requires the prime contractor to provide upon request proof of the amount and percentage of work the prime contractor committed to provide to one or more DVBEs under the contract in addition to proof of payment for work done by the DVBE. Additionally, prime contractors must now obtain permission before they may replace a listed DVBE. County of San Joaquin Now Authorized to Establish Bid Preferences (AB 1533, Eggman) This new law extends to the County of San Joaquin existing law that authorizes local agencies to establish preferences for small businesses, disabled veteran businesses, and social enterprises in facilitating contract awards. Read the court decision
Read the full story...
Reprinted courtesy of Smith Currie

Change #7- Contractor’s Means & Methods (law note)

March 28, 2018 — Melissa Dewey Brumback - Construction Law in North Carolina
First, a little history: as you know, means, methods, techniques, sequences, and procedures are all part of the Contractor’s responsibility on a construction site. However, when the AIA A201 was last revised, in 2007, there was a provision put in for that rare time when the Contract Documents gave specific instructions concerning a particular construction method. If the Contractor viewed such instructions as unsafe, he was to give notice to the Owner and Architect, and was not to proceed with that portion of the Work without further written instructions from the Architect. If the Architect directed him to proceed, the Contractor was absolved from any risks with following that instruction. Instead, the Owner assumed the responsibility for any loss or damage. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina

Not to Miss at This Year’s Archtober Festival

October 15, 2014 — Carrie Hojnicki – Bloomberg
New York architecture fanatics everywhere can rejoice: Archtober has arrived. In its fourth annual iteration, the monthlong festival throws a spotlight on the importance of architecture and design in the five boroughs, calling special attention to the city’s rich built history and exciting future. In addition to a lineup of lectures, openings, and workshops, the American Institute of Architects (AIA) New York Chapter–sponsored initiative highlights a “Building of the Day,” with on-site tours led by the architects themselves. Here are five events not to miss this Archtober. 1. AIA’s New York chapter puts its own spin on the architecture tour: a boat ride. Guides from the AIA will share their wisdom as the cruise circles the tip of Manhattan, passing architectural marvels aplenty. October 3, 10 am and 1:30 pm, Classic Harbor Line Read the court decision
Read the full story...
Reprinted courtesy of Carrie Hojnicki, Bloomberg

Licensing Reciprocity Comes to Virginia

May 15, 2023 — Christopher G. Hill - Construction Law Musings
Remember my admonishment to get your Virginia contractor’s license? Well, that will get easier for experienced construction professionals that hold a license from a state or territory outside of Virginia beginning on July 1, 2023. In this past session of the General Assembly, the Youngkin administration pushed and the legislature passed a universal licensure statute that (with some exceptions for professional services as defined in Va. Code 2.2-4301) will allow those (including contractors) who are licensed in other states to use that license to obtain a Virginia license. The new legislation will require DPOR to recognize another state’s license where the contractor meets the following requirements:

The individual holds a current and valid professional or occupational license or government certification in another state in a profession or occupation with a similar scope of practice, as determined by the board in the Commonwealth

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES