Seattle Washington Building Expert Directory

A Word to the Wise: The AIA Revised Contract Documents Could Lead to New and Unanticipated Risks - Part II

October 16, 2018 — George Talarico - Construction Executive
Part I addressed general conditions, revised insurance terms, revisions that affect owner’s required insurance and revisions that affect contractor’s required insurance. REVISIONS THAT AFFECT DISPUTE RESOLUTION A seemingly minor but noteworthy change is to the definition of “Claim.” Under Section 15.1 a “Claim” is defined to:

include a request for a modification of contract time; and
exclude any requirement that an owner must file a claim to impose liquidated damages.

Notably, any request relating to contract time must be brought within the specified time period for Notice of Claim and in the prescribed manner. There are at least two traps for the unwary. First, even though email is regularly used for communications among the parties, the revised contract documents do not recognize email as an acceptable form of delivery of a Notice of Claim. Second, an unwary contractor may wrongly assume that an owner’s failure to assert a claim for LDs means that LDs will not be imposed. This may lull the contractor into failing to timely assert its own claim for a time extension and thereby waiving its ability to do so. Reprinted courtesy of George Talarico, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Talarico may be contacted at gtalarico@sillscummis.com

Medical Center Builder Sues Contracting Agent, Citing Costly Delays

March 19, 2014 — Beverley BevenFlorez-CDJ STAFF
The Pennsylvania firm Bedwell Co. “has sued the Camden County Improvement Authority, saying it is owed $4.6 million for construction of [the Cooper Medical School of Rowan University]” in Camden, New Jersey, according to the Courier-Post. The Bedwell Co. alleges that its expenses exceeded fifty million, “but that it has been paid only $46 million.” The lawsuit states, as quoted by the Courier-Post, “From its inception, the project was plagued by delays due to defects in the design document and other circumstances that were beyond Bedwell’s control.” Furthermore, there were “an abnormally large quantity of design changes, schedule disputes, schedule disruptions and work-activity interference.” “Representatives of the CCIA and HDR could not be reached for comment Wednesday,” according to the Courier-Post. “Bedwell declined to comment on the allegations in the suit.” Read the court decision
Read the full story...
Reprinted courtesy of

A Few Things You Might Consider Doing Instead of Binging on Netflix

April 13, 2020 — Garret Murai - California Construction Law Blog
Governments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips. 1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

#8 CDJ Topic: The Las Vegas HOA Fraud Case Concludes but Controversy Continues

December 30, 2015 — Beverley BevenFlorez-CDJ STAFF
In the long-running case involving the scheme to take over and defraud homeowner associations in Las Vegas, Nevada, the Las Vegas Review-Journal reported that a “total of 43 defendants either pleaded guilty or were convicted at trial in what prosecutors say is the largest public corruption case ever in Nevada.” Despite the conclusion of the trial and the convictions, “U.S. Magistrate Judge George Foley Jr. denied a June request by the Las Vegas Review-Journal to dissolve two protective orders keeping secret 6 million pages of documents, including 10,000 pages of FBI and other law enforcement reports.” Read the full story... Reported in an editorial, the Las Vegas Review-Journal attorney Maggie McLetchie stated after Judge Foley’s ruling: “It’s our view the public and the newspaper should be able to evaluate a law enforcement investigation including assessing why the government may have gone more lightly on some people. Given the issues…within the U.S. attorney’s office, it’s in the public’s interest to probe what occurred.” Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

There's No Such Thing as a Free House

April 01, 2015 — Megan McArdle – Bloomberg
Should people be able to get a free house by refusing to pay their mortgage? That's the question Florida has to answer. The housing crisis is over, and the housing market is healing itself, though slowly in some places. But a backlog of foreclosures still remains ... and it has been going on so long that some homes are now past the statute of limitations for collecting debt. Lawyers for the homeowners are arguing that this means they get to keep the house. Lawyers for the banks are, unsurprisingly, arguing that each month they fail to pay the mortgage payment starts the statutory clock anew. Both arguments create problems if the courts endorse them. If failing to pay really restarted the clock every month, then there wouldn't be a statute of limitations on debt -- creditors could just keep sending you bills forever and dun you right up to the edge of your grave. There's a very good reason that we have statutes of limitations on most crimes and most debts: The law recognizes that our interests in justice and contract rights must be balanced against other considerations. People need to be able to plan their lives without decades-old problems coming back to bite them, and also, as cases age, they get harder and harder to prove as witnesses die, evidence gets lost and memories fade. Read the court decision
Read the full story...
Reprinted courtesy of Megan McArdle, Bloomberg
Ms. McArdle may be contacted at mmcardle3@bloomberg.net

Fannie-Freddie Propose Liquidity Rules for Mortgage Insurers

July 16, 2014 — Clea Benson and Zachary Tracer – Bloomberg
Ms. Benson may be contacted at cbenson20@bloomberg.net; Mr. Tracer may be contacted at ztracer1@bloomberg.net Private mortgage insurers looking to do business with Fannie Mae and Freddie Mac would have to hold minimum amounts of liquid assets under standards proposed by the companies and their regulator. To back loans packaged into securities by the U.S.-owned mortgage-finance giants, insurers would have to hold liquid assets worth at least 5.6 percent of their risk exposure, and possibly more depending on the quality of the loans they cover, according to the proposal released today by the companies and the Federal Housing Finance Agency. “Mortgage insurance counterparties must be able to fulfill their intended role of providing private capital, even in adverse market conditions,” FHFA Director Melvin L. Watt said in an e-mailed statement. Ms. Benson may be contacted at cbenson20@bloomberg.net; Mr. Tracer may be contacted at ztracer1@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Clea Benson and Zachary Tracer, Bloomberg

The American Rescue Plan Act: What Restaurants Need to Act on NOW

March 22, 2021 — Michael Krueger - Newmeyer Dillion
The American Rescue Plan Act (“Act”) was passed by the Senate over the weekend and passed by the House today. President Biden is set to sign the Act into law on Friday, March 12th. The Act has $1.9 Trillion in relief funds with $28.6 Billion set aside for the restaurant industry in the Restaurant Revitalization Fund (“Fund”). The Fund has apportioned funds into two funding groups; $5 Billion for restaurants with annual gross revenue under $500,000 and $23.6 Billion for restaurants over $500,000 in annual gross revenue. Differences from the Paycheck Protection Program (“PPP”) This is a grant program with no loan documents or forgiveness applications. Instead, each restaurant entity can apply for and receive up to $10M in grant funds through the Act. The amount a restaurant receives is based on the sum of the restaurant’s gross revenue in 2019 minus the gross revenue in 2020 minus PPP and EIDL money received. For example, Restaurant A made $7M gross revenue in 2019, made $3M gross revenue in 2020 and received $1M in PPP and EIDL combined. ($7M - $3M -$1M =$3M) The restaurant will receive $3M in grant funds directly from the SBA (as long as funds are available). Read the court decision
Read the full story...
Reprinted courtesy of Michael Krueger, Newmeyer Dillion
Mr. Krueger may be contacted at michael.krueger@ndlf.com

Denial of Coverage for Bulge in Wall Upheld

November 26, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The insurer properly denied coverage for a bulge in a warehouse wall that the insured claimed was caused by Hurricane Ike. Russell v. Scottsdale Ins. Co., 2014 U.S. Dist. LEXIS 143882 (S.D. Tex. Sept. 30, 2014). Hurricane Ike displaced metal roof coverings on the insured's warehouse, causing interior water damage to several rooms. Scottsdale eventually paid $84,820.36 for the loss of the roof, less the deductible. The parties disagreed on whether a horizontal bulge on the north wall of the warehouse was also caused by the hurricane. The bulging portion of the wall was not cracked, but cracks were seen around the corners and windows. The insured admitted to an engineer retained by Scottsdale that the cracks in the exterior walls had been filled with caulking on several occasions prior to Hurricane Ike. Scottsdale denied coverage for the damage to the north wall under exclusions for soil sinking, rising, or shifting and for damage from faulty, inadequate or defective design, construction, and repair.The insured later sent a demand for $800,000 for the damage to the wall. A suit was eventually filed by the insured. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES