Cambridge Massachusetts Building Expert Directory

The Texas Storm – Guidance for Contractors

March 08, 2021 — Curtis W. Martin & Paulo Flores - Peckar & Abramson, P.C.
The Texas snow and ice storm of February 2021 will long be remembered. It has affected everyone across the State, and its impacts continue to be felt a week later. This Alert provides the construction industry with guidance and recommendations for navigating commercial risk resulting from the storm. The potential impacts to your projects may be wide reaching. Consequences on a project site can include damage to the site, delays to work from the storm or from government orders, or simply the lack of help from trades who are dealing with serious personal catastrophes. Offsite impacts can cover a much broader scope of issues, including supply production issues or transportation interruptions. So, what can contractors facing such impacts do to avoid losses, mitigate the impacts, and prepare for what’s to come? Reprinted courtesy of Curtis W. Martin, Peckar & Abramson, P.C. and Paulo Flores, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Flores may be contacted at PFlores@Pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Illinois Court Addresses Rip-And-Tear Coverage And Existence Of An “Occurrence” In Defective Product Suit

September 04, 2018 — Brian Bassett - TLSS Insurance Law Blog
In Lexington Ins. Co. v. Chi. Flameproof & Wood Specialties Corp., 2018 U.S. Dist. LEXIS 135871, 2018 WL 3819109 (N.D. Ill. Aug. 10, 2018), the U.S. District Court for the Northern District of Illinois found that rip-and-tear costs could qualify as covered “property damage,” but the court rejected coverage for claims that the insured intentionally sold a noncompliant product as the suit did not allege an “occurrence.” Lexington Insurance Company (“Lexington”) issued a CGL policy to Chicago Flameproof & Wood Specialties Corp. (“Flameproof”). During the policy period, a third party ordered fire-retardant-treated lumber from Flameproof for construction in Minnesota. Flameproof instead sent materials that were not tested, certified, or labeled as compliant. The third party installed the materials, discovered the non-compliance, and then removed the materials. Removing the materials allegedly damaged other portions of the building on the project. The third party then sued Flameproof, alleging costs associated with replacing the lumber as well as property damage to the other materials from the removal of the lumber. Flameproof tendered the claim to Lexington seeking a defense. Lexington filed a declaratory action in the Northern District of Illinois. Read the court decision
Read the full story...
Reprinted courtesy of Brian Bassett, Traub Lieberman Strauss & Shrewsberry LLP
Mr. Bassett may be contacted at bbassett@tlsslaw.com

Spearin Doctrine 100 Years Old and Still Thriving in the Design-Build Delivery World

January 09, 2019 — John P. Ahlers - Ahlers Cressman & Sleight PLLC
The Supreme Court’s ruling in United States v. Spearin, [1] also referred to as the Spearin doctrine, is a landmark construction decision.[2] The Spearin doctrine provides that the Owner impliedly warrants the information, plans and specifications which an Owner provides to a General Contractor. If a Contractor is bound to build according to plans and specifications prepared by the Owner, the Contractor will not be responsible for the consequences of defects in the plans and specifications. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers Cressman & Sleight PLLC
Mr. Ahlers may be contacted at john.ahlers@acslawyers.com

Fifth Circuit Rules that Settlements in Underlying Action Constitute "Other Insurance"

April 17, 2019 — Tiffany Casanova - Saxe Doernberger & Vita, P.C.
The Fifth Circuit ruled that settlements between an insured and its subcontractors qualified as “other insurance” to the extent those settlements were used to pay for damages covered by an excess insurance policy. Policyholders should note the outcome of this case as it demonstrates the significant impact that settlements can have on coverage. Satterfield & Pontikes Construction, Inc. v. Amerisure Mutual Ins. Co.1 was the result of a construction project gone wrong. Zapata County, Texas hired Satterfield & Pontikes (“S&P”) as a general contractor for the construction of a courthouse building. When the project did not go as planned, Zapata County terminated S&P, hired new subcontractors to complete the project, and sued S&P. S&P, in turn, sought indemnification from its subcontractors, who were contractually obligated to indemnify S&P and procure insurance for any damage the subcontractors caused at the project. S&P also sought coverage from its own primary insurers, American Guarantee and Liability Insurance Company (“AGLIC”) and Amerisure Mutual Insurance Company (“Amerisure”), and its excess insurer, U.S. Fire Insurance Company (“U.S. Fire”) who provided liability coverage for S&P’s potential liabilities at the project. The policies contained exclusions for losses arising from mold and did not provide coverage for attorney’s fees or similar legal costs. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Casanova, Saxe Doernberger & Vita, P.C.
Ms. Casanova may be contacted at tlc@sdvlaw.com

Real Estate & Construction News Roundup (04/26/23) – The Energy Transition and a Bit of Brick-and-Mortar Blues

May 01, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In today’s roundup, Americans can buy homes with bitcoin, new tech aims to engineer a novel building material, federal investments boost the coastline (and construction sales), and more.

A bitcoin real estate marketplace, claiming it can close deals within one business day, made its U.S. debut. (Carla Mozée, Markets Insider)
Amid record-setting real estate prices in Dubai, the $34 million sale of a parcel of empty land on a luxury island marks a new high. (Megan Cerullo, CBS)
Analysts at Goldman Sachs and UBS weigh in on a predicted commercial real estate downturn. (Alena Botros, Fortune)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

The Practical Distinction Between Anticipatory Breach and Repudiation and How to Deal with Both on Construction Projects

June 10, 2024 — Devon Griger - ConsensusDocs
When a multilevel construction project is underway and a contractor or subcontractor isn’t performing as expected, it can be difficult to know how to address the low performance without putting the parties’ contract and good working relationship at risk. However, there may come a time when poor performance lapses into a something much worse: an anticipatory breach or repudiation of the subject contract. Imagine Scenario One: You are a general contractor managing a large-scale construction project and one of your subcontractors is falling behind on their work. The project manager for the subcontractor calls you and says, “Look, I don’t think we’re going to be able to hit our next milestone, and probably not the next one after that.” A conversation like this would generally trigger concern for most general contractors, but it would not necessarily invoke panic. These types of delay conversations are not uncommon on large scale projects. Compare that example, however, with Scenario Two, where the subcontractor instead says, “We received an offer to work another job for much more money, so we’re leaving the project site today and will not be returning.” This is obviously different (and potentially worse) than Scenario One, and likely cause for much greater concern. Read the court decision
Read the full story...
Reprinted courtesy of Devon Griger, Jones Walker
Ms. Griger may be contacted at dgriger@joneswalker.com

Contractor Sentenced to Seven Years for Embezzling $3 Million

July 20, 2020 — Garret Murai - California Construction Law Blog
Michael Medeiros was not a good guy. Ok, on a scale of 1 to 10, maybe not a 9 or 10 (when you’re including guys like Charles Manson), but a solid 6 or 7 at least. The next case, People v. Medeiros, Case No. A155648, 1st District Court of Appeals (March 26, 2020), is less important for its legal holding than as a reminder that while most legal disputes on construction projects end up with one party owing the other party money, sometimes, when a party’s conduct has been really bad, it can end in a loss of liberty (i.e., jail time) as well. People v. Medeiros Medeiros was a painting contractor operating under the name Professional Painting Company, Inc. In the early 1990s, Medeiros met Susan Lambert, who served as the property manager for a homeowners’ association, Woodlake Association, in Hayward, California. Lambert was an alcoholic. Following a series of surgeries in 2005 and 2007 she became addicted to opiates as well. She also had a gambling problem. As a result, Lambert regularly found herself in financial difficulty. And this is where Lambert and Medeiros found that they shared common ground. At some point, Medeiros confided to Lambert that he was having cash flow and tax problems. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Water Damage: Construction’s Often Unnoticed Threat

November 02, 2020 — Yaron Dycian - Construction Executive
Fire damage to commercial buildings might get headlines, but water damage, whether to projects under construction or completed buildings, delivers massive financial blows to owners, developers and contractors. The impact is massive, reaching many billions of dollars per year. One water leak on the 19th floor at a construction site of a high-end apartment building in New York City resulted in $30 million in property damage and millions in delayed delivery penalties. Imagine this all-too-typical scenario: A 20-story building has thousands of pipe connections and many tens of thousands throughout the entire building. It only takes one of those joints failing, perhaps due to human oversight. Early on a Saturday morning when no one is onsite, one of the connections inside a wall begins to leak, slowly at first. In a couple hours the connection fails completely, sending a cascade of water into the building. The site is located next to a highway, so the security guards don’t hear the water flowing. The leak goes undetected until crews come back onsite on Monday morning. By that point, lower levels of the building have been inundated with thousands of gallons of water that has destroyed construction material, carpeting and electrical switchgear. It’s flowed into the elevator pits and mechanical room. Reprinted courtesy of Yaron Dycian, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Dycian may be contacted at yaron@wint.ai

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES