Cambridge Massachusetts Building Expert Directory

Nationwide Immigrant Strike May Trigger Excusable Delay and Other Contract Provisions

February 23, 2017 — Adam P. Handfinger & Meredith N. Reynolds – Peckar & Abramson, P.C.
Yesterday, February 16, 2017, media outlets reported a nationwide strike by immigrants and businesses referred to as “A Day Without Immigrants”. The protest, organized largely through social media, was a response by some to the Trump Administration’s immigration and foreign trade policies. Participating businesses shut down and immigrants refused to work or spend money in an eff ort to demonstrate the role of foreign-born workers in the U.S. economy. While the number of businesses and individuals that participated is not yet known, several contractors reported labor shortages and construction project delays or temporary shut downs as a result of the protest. Reprinted courtesy of Adam P. Handfinger, Peckar & Abramson, P.C. and Meredith N. Reynolds, Peckar & Abramson, P.C. Mr. Handfinger may be contacted at ahandfinger@pecklaw.com Ms. Reynolds may be contacted at mreynolds@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Victoria Kajo Named One of KNOW Women's 100 Women to KNOW in America for 2024

May 13, 2024 — Lewis Brisbois Newsroom
Los Angeles, Calif. (April 30, 2024) – Los Angeles Partner Victoria Kajo has been named to global media company KNOW Women's 2024 100 Women to KNOW in America list, which honors the top 100 female leaders across North America. The honorees were recognized at the annual KNOW Women Summit, held from April 21-23 at The Palomar Hotel in Phoenix, Arizona. The annual 100 Women to KNOW in America award, presented by JPMorgan Chase, recognizes women entrepreneurs, executives, creatives, and philanthropists who "exemplify what it means to be high achieving and ambitious on the next level and who continue to pour into their communities as they do so," according to KNOW Women. Ms. Kajo was selected as one of this year's honorees following a nomination and interview process. Ms. Kajo is a member of Lewis Brisbois' Professional Liability Practice. She has extensive experience with professional liability litigation, having defended lawyers, design professionals and real estate professionals against claims of alleged negligent acts and omissions in the performance of their professional services. Ms. Kajo also has broad experience in general civil litigation matters involving errors and omissions, real estate, wrongful foreclosures, labor and employment law, civil rights, fraud, personal injury, breach of contract and unlawful detainer matters, amongst others. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

A Word to the Wise: The AIA Revised Contract Documents Could Lead to New and Unanticipated Risks - Part II

October 16, 2018 — George Talarico - Construction Executive
Part I addressed general conditions, revised insurance terms, revisions that affect owner’s required insurance and revisions that affect contractor’s required insurance. REVISIONS THAT AFFECT DISPUTE RESOLUTION A seemingly minor but noteworthy change is to the definition of “Claim.” Under Section 15.1 a “Claim” is defined to:

include a request for a modification of contract time; and
exclude any requirement that an owner must file a claim to impose liquidated damages.

Notably, any request relating to contract time must be brought within the specified time period for Notice of Claim and in the prescribed manner. There are at least two traps for the unwary. First, even though email is regularly used for communications among the parties, the revised contract documents do not recognize email as an acceptable form of delivery of a Notice of Claim. Second, an unwary contractor may wrongly assume that an owner’s failure to assert a claim for LDs means that LDs will not be imposed. This may lull the contractor into failing to timely assert its own claim for a time extension and thereby waiving its ability to do so. Reprinted courtesy of George Talarico, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Talarico may be contacted at gtalarico@sillscummis.com

Traub Lieberman Partner Colleen Hastie and Associate Jeffrey George Successfully Oppose Plaintiff’s Motion to Vacate Dismissal

September 11, 2023 — Colleen E. Hastie & Jeffrey George - Traub Lieberman
Traub Lieberman Partner Colleen Hastie and Associate Jeffrey George successfully opposed Plaintiff’s motion to vacate a prior dismissal of plaintiff’s medical malpractice action brought before the Supreme Court of the State of New York, Bronx County. The lawsuit, commenced by Plaintiff in 2015, alleged medical malpractice stemming from treatment Plaintiff received at a New York medical facility after falling out of a window at a rental property owned by Traub Lieberman’s client (“Property Owner”). Property Owner moved to dismiss Plaintiff’s complaint or preclude Plaintiff from offering evidence in support of its claims, or in the alternative, compel plaintiff to produce all outstanding discovery. The Medical Facility cross-moved for the same relief. Defendants agreed to adjourn the motion until after plaintiff’s deposition, but plaintiff made no effort to secure an adjournment with the court and plaintiff filed no opposition to the motion, allowing the motion to be granted on default. Plaintiff waited nearly a year to file a motion to vacate the default judgment, despite receiving notification of the default from defense counsel. Property Owner, in opposing plaintiff’s motion, pointed to plaintiff’s long history of dilatory conduct and failure to comply with discovery orders in support of its position that plaintiff failed to show any good cause for its default on the motion to dismiss. Reprinted courtesy of Colleen E. Hastie, Traub Lieberman and Jeffrey George, Traub Lieberman Ms. Hastie may be contacted at chastie@tlsslaw.com Mr. George may be contacted at jgeorge@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Spain Risks €10.6 Billion Flood Damage Bill, Sanchez Says

November 25, 2024 — Rodrigo Orihuela, Macarena Munoz Montijano & Jorge Zuloaga - Bloomberg
Spanish Prime Minister Pedro Sanchez announced the first financial package for victims of the storms that killed more than 200 people in the country’s eastern region of Valencia. Spain will earmark as much as €10.6 billion ($11.5 billion) for its first relief package and more will be announced in the future, Sanchez said in a press conference Tuesday in Madrid. The package includes direct aid for households, self-employed workers and firms; state-backed credit guarantees for companies and residents; and funds for city governments to pay for repairs and reconstruction. Reprinted courtesy of Rodrigo Orihuela, Bloomberg, Macarena Munoz Montijano, Bloomberg and Jorge Zuloaga, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Federal District Court Finds Coverage Barred Because of Lack of Allegations of Damage During the Policy Period and Because of Late Notice

December 29, 2020 — Robert Dennison - Traub Lieberman
In American Bankers Ins. Co. of Florida v. National Fire Ins. Co. of Hartford, 2020 WL 5630017 (Sept. 21, 2020), the Northern District of California of the United States District Court had occasion to consider whether allegations in an underlying complaint triggered a duty to defend and a late notice defense to coverage. The underlying actions were a suit against the City of Walnut Creek for damages from flooding allegedly caused by the City’s failure to develop and maintain its storm drains.The City settled the cases then sued its liability insurers who issued its coverage in the period 1968 to 1986 for indemnification of the amounts spent to defend and settle the cases.The published decision involved three Travelers’ policies issued to the City between 1968 and 1976, as to which Travelers sought summary judgment as to the lack of coverage in its policies. The district court first found that the definition of an “occurrence” in the policies, in one policy “an event or a continuous or repeated exposure to conditions which causes injury to person or damage to property during the policy period” and in the other two “an accident, including injurious exposure to conditions, which results during the period this policy is in effect, in bodily injury or property damage,” fell within the rule of Montrose Chemical Corp. v. Admiral Ins. Co. (1995) 10 Cal.4th 645, that injury or damage during the policy period must occur in order for the policy to be triggered.The court agreed with Travelers that while there were allegations of flooding for many years, the only claims/allegations of property damage were for the period 2000 and later.Therefore the property damage coverage in the policies was never triggered. Read the court decision
Read the full story...
Reprinted courtesy of Robert Dennison, Traub Lieberman
Mr. Dennison may be contacted at rdennison@tlsslaw.com

Boys (and Girls) of Summer: New Residential Solar Energy System Disclosures Take Effect January 1, 2019

October 02, 2018 — Garret Murai - California Construction Law Blog
As we come to the end of Summer, the California Contractors State License Board advises licensees that it has finalized its Solar Energy System Disclosure Document. The Solar Energy System Disclosure Document, required under Business and Professions Code Section 7169 as amended by Assembly Bill 1070 in 2017, requires that the disclosure language of the document be:

Included in all contracts providing for the installation of a “solar energy system” on a residential building;
Included on the front page or cover page of the contract;

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Reconciling Prompt Payments and Withholding of Retention Payments

March 30, 2016 — Eric J. Rollins, Esq. – Newmeyer & Dillion, LLP
It is common in California for the owners of a project to make monthly payments to a contractor for work as it is completed, but withhold a certain percentage as a guarantee of future satisfactory performance. Contractors almost always pass these withholdings on to their subcontractors. Unsurprisingly, disputes can arise regarding when the withheld retentions must be paid. Civil Code section 8814, subdivision (a), states that a direct contractor must pay each subcontractor its share of a retention payment within ten days after receiving all or part of a retention payment. However, an exception exists -- a direct contractor may withhold from the retention paid to a subcontractor an amount not in excess of 150 percent of the estimated value of the disputed amount, whenever a “good faith dispute exists between the direct contractor and a subcontractor.” (See Cal. Civ. Code, § 8814, subd. (c).) The problem with the statute is that it offers no help in defining a “good faith dispute,” and the California courts have historically not provided much guidance either. Can a “good faith dispute” be any dispute between the contracting parties, e.g., a dispute regarding change orders, mismanagement, etc.? Or must the dispute relate specifically to the retention? Unfortunately for California litigants, the answer may depend on the appellate district in which the parties find themselves. Read the court decision
Read the full story...
Reprinted courtesy of Eric J. Rollins, Esq., Newmeyer & Dillion, LLP
Mr. Rollins may be contacted at eric.rollins@ndlf.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES