COLUMBUS OHIO BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

---

Schools Remain Top Priority in Carolinas as Cleanup From Storms Continues

November 06, 2018 — Joanna Masterson - Construction Executive
A month after Hurricane Florence dumped more than 30 inches of rain on the Carolinas, Hurricane Michael delivered additional flash flooding, power outages and wind damage. While the construction-related impact of Hurricane Michael is still being assessed (stay tuned for more on that front in the coming weeks), Moody’s Analytics estimates total property damage from Florence at $17 billion to $22 billion, factoring in losses from homes, roads, crops, livestock, coal ash ponds and more. While it’s difficult to pinpoint which counties were hit the hardest, the majority of the damage was in the eastern coastal areas of North Carolina. According to Rob Beale, a vice president in W.M. Jordan’s Wilmington, North Carolina, office, Carteret and Onslow counties took the brunt of the storm, while Columbus and Brunswick counties experienced the biggest flooding impact. Reprinted courtesy of Joanna Masterson, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

A Murder in Honduras Reveals the Dark Side of Clean Energy

October 12, 2020 — Monte Reel - Bloomberg
Berta Cáceres campaigned to stop a renewable energy project, and the long fight turned her into one of Central America’s most prominent environmentalists. She won a prestigious international prize known as the “Green Nobel” for protecting a river, using some of the award money to purchase a modest bungalow in La Esperanza, her hometown in central Honduras. Her activism is also what brought three gunmen to her back door. The men broke into her kitchen around 11:30 p.m. on March 2, 2016. Cáceres heard a noise and called out from her bedroom: “Who’s out there?” Within seconds, a gunman entered her room and shot her dead. Read the court decision
Read the full story...
Reprinted courtesy of Monte Reel, Bloomberg

---

World Cup May Pull Out of Brazil because of Construction Delays

January 28, 2014 — Beverley BevenFlorez-CDJ STAFF
Back in October of last year, CNN reported that a judge suspended construction at one of the stadiums being built for this summer’s World Cup in Brazil. The judge stated that the dangers for construction workers included "being buried, run over, falling from heights and being hit by material, among other serious risks,” according to CNN. Recently, the Los Angeles Times reported that FIFA is threatening to pull out of Brazil because of construction delays: “We cannot organize a match without a stadium,” Jerome Valcke, FIFA’s secretary general, as quoted in the Los Angeles Times. “This has reached a critical point.” The deadline for completion of the 12 World Cup stadiums was January 1st, but various delays—including “fatal construction accidents at stadiums in Sao Paulo, Brasilia, and Manaus” as well as worker walk offs over pay—forced FIFA to “relax” the deadline. Read the full story at CNN... Read the full story at the Los Angeles Times... Read the court decision
Read the full story...
Reprinted courtesy of

---

Balancing Risk and Reward: The Complexities of Stadium Construction Projects

April 15, 2024 — Gregory A. Eichorn - Peckar & Abramson, P.C.
From grand designs to opening day, stadium construction projects present a captivating blend of high-profile opportunities and significant challenges and risks. Navigating this complex landscape is not easy, but when managed properly, the potential rewards, both in terms of reputation and finances, can make it a gamble worth taking. While each stadium project is different, some of the more common risks include:

1. Securing adequate labor, materials and equipment based on the size of the project;
2. Logistical concerns regarding the concurrent performance of multiple trade scopes on a single site;
3. Protection of work in place from weather due to the large footprint of the stadium project;
4. Cash flow issues caused by protracted change order processing, conflicting and/or onerous payment requirements from project financing entities, and reimbursement of considerable monthly general condition costs; and
5. Meeting the schedule requirements for the project.

Read the court decision
Read the full story...
Reprinted courtesy of Gregory A. Eichorn, Peckar & Abramson, P.C.
Mr. Eichorn may be contacted at geichorn@pecklaw.com

---

Save a Legal Fee: Prevent Costly Lawsuits With Claim Limitation Clauses

April 25, 2012 — Douglas Reiser, Builders Council Blog

Ever had that lingering problem with a contracting partner that went away for awhile and then came back to bite you ? years later? In Washington, construction contract claims can be raised for up to six years after substantial completion. Six years!? Why would I want to wait that long to find out if I have a problem? You don’t have to.



Over the past few years, I have discussed the notion of “contractual claim periods” on The Builders Counsel. For today’s Save a Legal Fee column, I cannot think of a better topic. These provisions are specifically intended to save you from unnecessary legal fees that might arise if a problem goes unnoticed for too long.



Contractual claim periods are simply a way to reduce the amount of time that a contracting party has to raise a claim against its contracting partner. For example, a subcontractor might require that a general contractor raise any claim that it might have ? for defective or incomplete work, injury, damages, etc ? within a particular amount of time or forever lose the ability to raise the claim in a legal proceeding.



Read the full story…



Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

No Concrete Answers on Whether Construction Defects Are Occurrences

February 14, 2013 — CDJ STAFF
Aaron Mandel and Stevi Raab of Sedgwick Law write Construction Defect Coverage Quarterly addressing the question of “whether defective construction constitutes an ‘occurrence’ (and therefore may be covered) under liability insurance policies.” They note that some courts have held that construction defects are not an occurrence but instead are the “natural consequence of performing substandard work.” Other courts conclude that while construction defects are not occurrences, “the resulting damage may be covered because it was fortuitous and unintended.” And, finally, other courts have concluded that “defective construction work itself is accidental and the inured rarely expects construction defects.” Mandel and Raab put forth that “these decisions essentially provide insured with huge, unintended and unfair windfalls – performance bonds for basically no premium.” Legislatures have also looked at this issue, passing laws that mandate that construction defects are occurrences. These are all fairly recent and the courts have yet to address these laws, and Mandel and Raab note that “it is unclear what their ultimate effect on the ‘occurrence’ issue will be.” They do not expect the laws to end litigation over whether construction defects are occurrences. Finally, they discuss what the ultimate results of these court decisions and laws will be. Insurers might write more policy exclusions, or increase premiums, or even cease insuring construction. Read the court decision
Read the full story...
Reprinted courtesy of

---

Expert Excluded After Never Viewing Damaged Property

October 28, 2015 — Tred R. Eyerly – Insurance Law Hawaii
Plaintiff's expert was excluded for never having seen the property. Wehman v. State Farm Fire and Casualty Co., 2015 U.S. Dist. LEXIS 117445 (D. N.J. Sept. 3, 2015). Plaintiff's home was damaged by Superstorm Sandy on October 29, 2012. He reported his loss to State Farm on Octorber 25, 2013, claiming that some roof shingles had come loose during the storm. No other damage was reported. An investigator for State Farm visited the property. The investigator determined that the damage to the roof was not caused by Sandy, but by age, wear and tear, all of which were excluded causes under the policy. Plaintiff informed the investigator there was no damage to the interior of the home and denied the investigator's request to enter the house to inspect. Plaintiff then sued State Farm for breach of contract and bad faith. Plaintiff designated Timothy Fife of Gulf Coast Estimating Services as his expert in the litigation. Fife's estimate of damages consisted of twelve pages of allegedly required repairs for both the interior and exterior of Plaintiff's property totaling $86,351.01. Fife never visited the property to inspect and never spoke with Plaintiff regarding the condition of the property prior to Sandy or the damage allegedly caused by Sandy. Instead, Fife relied upon an inspection conducted by someone else. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---