Cambridge Massachusetts Building Expert Directory

Tokyo Tackles Flood Control as Typhoons Swamp Subways

August 20, 2014 — Jacob Adelman – Bloomberg
Below the condos and boutiques of Tokyo’s upscale Minato ward -- which includes Roppongi Hills, home to Goldman Sachs Group’s Japan headquarters -- a boring machine has carved out the city’s newest defense against floods. “There are many buildings, there’s a freeway,” said Satoshi Yamamoto, who’s directing the Tokyo government’s 24.5 billion yen ($240 million) project to build a giant subterranean reservoir -- the city’s second of three -- to handle flood waters from the Furukawa river that winds through the area. “We decided the best approach was to go underground.” When it’s completed in 2016, the 3.3-kilometer (2-mile) reservoir will be able to handle 135,000 cubic meters of water, enough to fill 54 Olympic-sized swimming pools. Tokyo is becoming increasingly reliant on this solution as more typhoons hit the country each year, a trend that Yamamoto said may be linked to global warming. The flooding is exacerbated by the city’s sprawling concrete footprint that keeps rainwater from seeping safely into the ground. Read the court decision
Read the full story...
Reprinted courtesy of Jacob Adelman, Bloomberg
Mr. Adelman may be contacted at jadelman1@bloomberg.net

“Incidental” Versus “Direct” Third Party Beneficiaries Under Insurance Policies in Which a Party is Not an Additional Insured

April 18, 2023 — Garret Murai - California Construction Law Blog
As they say, when it rains, it pours. Indemnity and insurance are the “Big Two” when it comes to risk avoidance on construction projects. The next case, LaBarbera v. Security National Security Company, 86 Cal.App.5th 1329 (2022), involves both. It’s an interesting case, which I think could have gone either way, involving claims by a higher-tiered party that they were a third party beneficiary under an insurance policy in which they were not named as an additional insured. The LaBarbera Case The Indemnity Provision and Insurance Policy In June 1016, Chris LaBarbera hired Richard Knight doing business as Knight Construction to remodel his house in Carmichael, California. The construction contract included an indemnity provision which provided that Knight would defend and indemnify LaBarbera from all claims arising out the remodeling work except for claims arising from LaBarbera’s sole negligence and willful misconduct. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Home-Rentals Wall Street Made Say Grow or Go: Real Estate

July 23, 2014 — Heather Perlberg and John Gittelsohn – Bloomberg
Alexander Philips joined the rush to buy foreclosed U.S. homes four years ago, spending $40 million on houses in California and Nevada to operate as rentals. Now his firm, Twinrock Partners LLC, is getting ready to sell. “We didn’t want to be the last one standing when the music stopped,” Philips, 38, said in a telephone interview. “We view this as a trade, not as a business.” The U.S. home-rental industry, transformed over the past two years by Wall Street-backed companies that were built on the rubble of the housing crash, is poised to be reshaped again as landlords like Philips get out. Corporate owners with limited capital or deadlines to repay investors are now selling houses in bulk, or one by one, after a 26 percent surge in prices from a March 2012 low. For bigger firms, swallowing smaller competitors is among the best opportunities for growth as they shift their focus to managing scattered properties. Ms. Perlberg may be contacted at hperlberg@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Heather Perlberg and John Gittelsohn, Bloomberg

We Knew Concrete Could Absorb Carbon—New Study Tells How Much

December 08, 2016 — Thomas F. Armistead – Engineering News-Record
Concrete’s large carbon footprint—that is, the amount of carbon dioxide emitted during the cement manufacturing process—is estimated to be 5% of industrial CO2 emissions, a source of concern in the battle against human-caused climate change. But last month, an international research team reported that substantial quantities of CO2 are reabsorbed, or sequestered, by cement-based products over their life cycle. Read the court decision
Read the full story...
Reprinted courtesy of Thomas F. Armistead, Engineering News-Record
ENR may be contacted at enr.com@bnpmedia.com

Traub Lieberman Attorneys Recognized as 2022 New York – Metro Super Lawyers®

October 17, 2022 — Traub Lieberman
Traub Lieberman is pleased to announce that seven Partners from the Hawthorne, NY Office have been selected to the 2022 New York - Metro Super Lawyers list. 2022 New York – Metro Super Lawyers
Copernicus Gaza – Insurance Coverage

Jonathan Harwood – Professional Liability

Lisa Rolle – Construction Litigation

Christopher Russo – Professional Liability

Lisa Shrewsberry – Professional Liability

Stephen Straus – Insurance Coverage

Richard Traub – Insurance Coverage
Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman
Massive Fire Destroys Building, Firefighters Rescue Construction Worker
March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
A “5-alarm fire burned down a residential building under construction in the Montrose area” of Houston, Texas, reported Click 2 Houston. Almost 200 emergency personnel were on the scene. Captain Ruy Lozano told Click 2 Houston that “firefighters worked to contain the blaze, before the imminent collapse because the fire suppression systems were not yet in place for the under-construction building.” ABC News reported that fire fighters rescued Curtis Reissig, a construction worker from the fire. “It’s burning my eyes, my throat. I can’t breathe and I can’t hardly see anything,” Reissig told ABC News. “I could see a window. I went to that window. Trying to open that window in a panic. I couldn’t get the thing open. Smoke was getting heavier, just trying to get some air.” ABC News reported that Reissig jumped down from a fifth story balcony to a ledge below, where “firefighters pulled him to safety.” Read the full story at Click 2 Houston... Read the full story at ABC News... Read the court decision
Read the full story...
Reprinted courtesy of
California to Build ‘Total Disaster City’ for Training
July 30, 2014 — Beverley BevenFlorez-CDJ STAFF
California is building a “world-class $56 million training facility in eastern Sacramento County that would pit fire crews against a variety of realistic, pressure-packed simulated disasters,” according to the Sacramento Bee. Construction has begun on the Emergency Response Training Center in Mather Field in Rancho Cordova. “The project is a joint effort between Henke’s fire department, the Governor’s Office of Emergency Services and the Sacramento Fire Department,” reported the Sacramento Bee. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES