Fairfield Connecticut Building Expert Directory

Construction Litigation Roundup: “Sudden Death”

October 17, 2023 — Daniel Lund III - Lexology
It’s not football, though. Rather, just when you thought it was safe in Louisiana to wait to file a garden-variety construction contract payment claim, an appellate court slams the door on it – applying a statute of “repose” to your claim. “Personal actions” – such as an action on contract – are generally subject in Louisiana to a 10-year “liberative prescription,” the applicable statute of limitations pursuant to Louisiana Civil Code article 3499. Like some other states, Louisiana has a statute of “repose” – imposing “peremption” rather than prescription for claims having to do with construction projects – limiting those claims (generally speaking) to five years post-completion. Like other statutes of “repose,” Louisiana Revised Statute 9:2772 provides that claims on construction projects may not be filed after five years, a duration which is not subject to interruption or extension. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Hawaii Federal District Court Denies Motion for Remand

December 21, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court refused to remand the insureds' case after the insurer removed from state court. Maui Land & Pineapple Co. v. Liberty Ins. Underwriters, 2016 U.S. Dist. LEXIS 15681 (D. Haw. Nov. 10, 2016). The underlying case was filed in state court on Maui. The underlying plaintiffs were condominium owners who brought claims against the insured, Maui Land and Pineapple Co., Inc. (MLP), and other defendants allegedly involved in the development of the project. Ryan Churchill, one of the named defendants, served as president of MLP and was on the board of the project's Association of Apartment Owners (AOAO). The underlying plaintiffs asserted claims for: breach of fiduciary duty; seeking access to books and records of the AOAO; and for injunctive/declaratory relief against MLP, Mr. Churchill, and all other defendants. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Montrose III: Vertical Exhaustion Applies in Upper Layers of Excess Coverage

May 18, 2020 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Montrose Chemical Corp. of Cal. v. Superior Court (No. S244737, filed 4/6/20) (Montrose III), the California Supreme Court held that, as between excess insurers at differing levels of coverage, a rule of “vertical exhaustion” or “elective stacking” applies, whereby the insured may access any excess policy once it has exhausted other excess policies with lower attachment points in the same policy period. The Court limited the rule to excess insurance, stating that “[b]ecause the question is not presented here, we do not decide when or whether an insured may access excess policies before all primary insurance covering all relevant policy periods has been exhausted.” Montrose manufactured the insecticide DDT in Torrance from 1947 to 1982. In 1990, the state and federal governments sued Montrose for environmental contamination and Montrose entered into partial consent decrees agreeing to pay for cleanup. Montrose claimed to have expended in excess of $100 million doing so, and asserted that its future liability could exceed that amount. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Norristown, PA to Stop Paying Repair Costs for Defect-Ridden Condo

February 10, 2014 — Beverley BevenFlorez-CDJ STAFF
The city of Norristown, Pennsylvania has already paid “$3.4 million for construction repairs and legal expenses” for the 26-unit condominium on 770 Sandy Street, according to The Times Herald. Therefore city officials recently declared that “they will no longer pay the $40,000 annual cost for maintenance, electricity and repairs” for the building. “At some point, the folks that own it have to step up and take responsibility for it,” Norristown Council President William Caldwell told The Times Herald. “No later than February 28, the municipality will cease to provide or pay for maintenance of 770 Sandy Street.” Previously, Norristown had received court orders to repair the building, after numerous construction defects turned up including “missing firestops in numerous walls, missing grout and steel rebar in block-wall, emergency stair towers, faulty electrical wiring and no provision for firestopping in the first-floor garage ceiling.” City officials “were faulted by Montgomery County Common Pleas Court judges for not properly inspecting the construction.” Charles Madracchia, past Customers Bank attorney and current Homeowner attorney, is “continuing active litigation in both federal and state court.” Read the court decision
Read the full story...
Reprinted courtesy of

What I Love and Hate About Updating My Contracts From an Owners’ Perspective

July 25, 2022 — ConsensusDocs
The Construction Owners Association of America (COAA) is the largest association of construction owners in the United States. COAA just held its Spring Connect conference in downtown Baltimore on the University of Maryland, Baltimore (UMB) campus. One session featured “What I Love and Hate About Updating My Contracts from an Owners’ Perspective.” ConsensusDocs’ Executive Director & Senior Counsel Brian Perlberg spoke on a panel with Joe Cleves of Taft Law and Pen Wolf from the Cleveland Clinic. Pen Wolf from Cleveland Clinic outlined the process he used to update his contracts recently. The Cleveland Clinic builds facilities annually and owns different facilities at different locations. The clinic employs over 75,000 employees. For an owner with a broad reach like the Cleveland Clinic, Wolf recommended using outside counsel with construction expertise to update contracts. He concluded that while it was a significant effort, the endeavor to update the Clinic’s contracts was absolutely worth the time commitment and expense. Wolf shared that updating the Clinic’s contracts has generated positive reviews internally and externally. Now their written agreements better reflect their business practices in their construction design and construction program. Read the court decision
Read the full story...
Reprinted courtesy of ConsensusDocs

Trumark Homes Hired James Furey as VP of Land Acquisition

April 08, 2014 — Beverley BevenFlorez-CDJ STAFF
According to GlobeSt.com, “Homebuilder Trumark Homes has hired James Furey as VP of land acquisition.” The “veteran developer” has held positions at Meritage Homes, Richmond American Homes, and Beazer Homes USA. “James is a versatile manager who brings a wealth of experience in many elements of the homebuilding process,” Jason Kliewer, partner and general counsel for Trumark, told GlobeSt.com. “He will be an invaluable asset as Trumark moves aggressively in the California market.” Read the court decision
Read the full story...
Reprinted courtesy of

Breaking with Tradition, The Current NLRB is on a Rulemaking Tear: Election Procedures, Recognition Bar, and 9(a) Collective Bargaining Relationships

September 09, 2019 — Keahn Morris, John Bolesta & James Hays - Construction and Infrastructure Law Blog
In its 84-year history, the National Labor Relations Board (NLRB, Board or Agency) has promulgated a very small number of rules pursuant to the Administrative Procedures Act, relying, instead, on individualized adjudications to establish the Board’s legislative policies. However, breaking with that long tradition, the current Board now appears to be on the verge of a formal rulemaking jag for on May 22, the Board released its “Unified Agenda” of anticipated regulatory actions which, in addition to proceeding with rulemaking regarding joint employer standards, announced the Board’s intention to consider formal rulemaking in a number of critical areas. Consistent with that wide-ranging Agenda, on August 12, the Board published a Notice of Proposed Rulemaking (NPRM) over the objection of Democratic appointee, Lauren McFerran, that would amend the Agency’s rules and regulations governing the filing and processing of election petitions in three very important ways. This NPRM, therefore, deserves attention. The first possible amendment will modify the Board’s administrative election blocking charge practice by establishing a regulation-based vote and impound procedure to be used when a party, typically a union facing possible decertification, files an unfair labor practice (ULP) charge and, based thereon, seeks to block the holding of an election. The second possible amendment will modify the Board’s current recognition bar case law by codifying prior Board case doctrine and creating a regulation-based requirement of notice of voluntary recognition to affected employees and a 45-day open period within which affected employees may call for an election before that voluntary recognition will be allowed to operate as a bar to employees raising later questions concerning the union’s representative status (QCR). Reprinted courtesy of Sheppard Mullin attorneys Keahn Morris, John Bolesta and James Hays Mr. Morris may be contacted at kmorris@sheppardmullin.com Mr. Bolesta may be contacted at jbolesta@sheppardmullin.com Mr. Hays may be contacted at jhays@sheppardmullin.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES