Fairfield Connecticut Building Expert Directory

Client Alert: Expert Testimony in Indemnity Action Not Limited to Opinions Presented in Underlying Matter

February 18, 2015 — R. Bryan Martin and Kristian B. Moriarty – Haight Brown & Bonesteel, LLP
In National Union Fire Insurance Co. of Pittsburgh Pa. v. Tokio Marine and Nichido Fire Insurance Co. (filed 2/4/2015, B24899 and B247258), the California Court of Appeal, Second District, held that the insurer of Costco Wholesale Corporation, in a subsequent indemnity action, could offer expert opinions which were not developed by the third-party plaintiff’s experts in an underlying dispute. Jack Daer filed suit against Costco and Yokohama Tire Corporation, alleging a tire manufactured by Yokohama (and sold by Costco), was defective and caused an accident resulting in Mr. Daer’s injuries. The case proceeded through expert discovery and depositions. On the first day of trial, Costco settled with Daer for $5.5 million, and Yokohama settled for $1.1 million. Reprinted courtesy of R. Bryan Martin, Haight Brown & Bonesteel LLP and Kristian B. Moriarty, Haight Brown & Bonesteel LLP Mr. Martin may be contacted at bmartin@hbblaw.com, Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Insurer Must Defend and Indemnify Construction Defect Claims Under Iowa Law

February 23, 2017 — Tred R. Eyerly – Insurance Law Hawaii
Applying Iowa law, the federal district court found that the insurer had to defend and indemnify construction defect claims for damage to property caused by the insured's subcontractors. Van Der Weide v. Cincinnati Ins., 2017 U.S. Dist. LEXIS 4469 (N.D. Iowa Jan. 12, 2017). Van Der Weide contracted with Bouma & Company, Inc. to construct a house in 1996. Before construction began, Bouma purchased a CGL policy and a separate umbrella policy from Cincinnati, which were in effect from January 30, 1996 to January 30, 1999. Bouma used various subcontractors to build the home, including Elkato Masonry, which did the brick veneer and masonry work. The house was completed in February 1998 and Van Der Weide moved in during August 1998. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurers Must Defend Allegations of Faulty Workmanship

June 20, 2022 — Tred R. Eyerly - Insurance Law Hawaii
Granting the insured's motion for partial judgment on the pleadings, the court determined the insurers had a duty to defend. Suez Treatment Solutions, Inc. v. Ace Am. Ins. Co. & Liberty Mut. Fire Ins. Co., 2022 U.S. Dist. LEXIS 59044 (S. D. N. Y. March 30, 2022). Suez Treatment Solutions, Inc. held policies from Chubb and Liberty Mutual Fire Insurance Company to cover its operations in connection with the development of a pollution treatment system in North Carolina. When the project ultimately failed, an underlying action sought damages from Suez, alleging breach of contract, negligence, and fraud. Suez filed this case seeking a declaratory judgment that Chubb and Liberty were each obligated to defend and indemnify Suez in the underlying case. The City of High Point hired Suez to upgrade the facilities at its wastewater treatment plant staring in 2021. Because mercury levels were too high in emissions from sewage-sludge incinerators, Suez began working on the installation of a Mercury Removal System. After installation, a leak occurred in a component known as the heat exchanger. The leak caused the system to shut down and weeks-long repairs began. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Builders Association Seeks to Cut Down Grassroots Green Building Program (Guest Post)

October 04, 2021 — Christopher G. Hill - Construction Law Musings
For this week’s year end Guest Post Friday here at Musings, we welcome Michael Anschel. Michael is the owner of Otogawa-Anschel Design-Build, a member of BATC, lead the development of and serves as a board member to MN GreenStar, the CEO of Verified Green, Inc., and writes the green blog for Remodeling Magazine Online. If you have been following the sad state of affairs in Minnesota recently (no not the elections) you might be scratching a bald spot on your head in amazement. To my knowledge it is the only state in which the local builders association [ www.batconline.org ] has actually sued the local Green building program (MN GreenStar [ www.mngreenstar.org ]; going as far as filing a restraining order to keep them from certifying any new homes in the state. This is, in my opinion, a tragic move in the wrong direction for everyone; builders and homeowners alike. The builders group widely know for The Parade of Homes claims to have no interest in using the program or the brand MN GreenStar, so why seek to shut the program down? Even the lawyers have been scratching their heads trying to make sense of this bizarre and highly aggressive move. And things just get more bizarre from there. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

9th Circuit Closes the Door on “Open Shop” Contractor

September 04, 2018 — Garret Murai - California Construction Law Blog
At the height of the Great Depression nearly one-quarter of Americans were unemployed. In response, Congress enacted a series of laws including the Smoot-Hawley Tariffs Act, which raised tariffs on foreign goods in an effort to spur domestic investment and to increase the number of jobs. Sound familiar? Background The Davis-Bacon Act Among the new laws enacted by Congress was the Davis-Bacon Act which required contractors on federal works projects to pay their workers the wages prevailing in the area where a project was located, also known as “prevailing wages,” in an effort to stem the practice of employers bringing in lower-wage workers from outside the area. The same year that the Davis-Bacon Act was enacted, California enacted its own prevailing wage law modeled after the Davis-Bacon Act and applicable to state and local public works projects. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Napa Quake Seen Costing Up to $4 Billion as Wineries Shut

August 27, 2014 — Michael B. Marois, Zachary Tracer and Dan Hart – Bloomberg
The earthquake that struck northern California yesterday will lead to economic losses of as much as $4 billion, fueled by damaged wineries and shuttered businesses that rely on tourists. Insurers will probably cover about $2.1 billion, according to an estimate from Kinetic Analysis Corp., which projected total losses of about twice that sum. Costs borne by the industry may be limited because many homeowners don’t have earthquake coverage, according to the Insurance Information Institute. “The main source of claims could well be commercial claims, those coming from wineries and vineyards and other commercial interests,” Robert Hartwig, the institute’s president, said in an interview today. “It will take a while for the business owners to sort this out.” Mr. Marois may be contacted at mmarois@bloomberg.net; Mr. Tracer may be contacted at ztracer1@bloomberg.net; Mr. Hart may be contacted at dahart@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Michael B. Marois, Zachary Tracer and Dan Hart, Bloomberg

How Do You Get to the Five Year Mark? Some Practical Advice

August 26, 2015 — Christopher G. Hill – Construction Law Musings
For this week’s Guest Post Friday here at Construction Law Musings, we would like to welcome back (again) Sean Lintow Sr. of SLS Construction & Building Solutions . Sean has over 20 years working directly in the trenches in the construction arena. Since moving to Illinois, the focus of his business has shifted to helping builders, trade professionals& even code officials not only understand and meet the latest energy codes but how to improve their methods to accomplish it better and more affordably. Currently he is RESNET Rater, AEE CEA (Certified Energy Auditor), ENERGY STAR partner & verifier, EPA Indoor airPLUS verifier, Level 2 Infrared Thermographer, Volunteer Energy Rater for Habitat for Humanity, and Builders Challenge Partner & Verifier. You may also want to check out his great resources on The HTRC (Homeowners & Trades Resource Center). I would like to thank Chris for inviting me back for my 6th musing on this great site. I would also like to give him a Belated Happy Birthday for reaching 5 years since going solo. Reaching five years is a big milestone for many businesses as most new ventures (I think it is 85% or maybe even 90%) fail during that time. Therefore, a big congrats to you Chris & here is to another five plus years. For the most part the blame game for failure comes down to; wrong product offerings (market to saturated, not interested in, etc…), their ability to market, or poor business skills (not charging enough, realizing what they are spending, etc…) as the main point of failures. There is another group though that never seems to get much press and that is the ones that seemingly are blindsided by the dreaded “ignorance of the law” is no excuse… Not only does this effect many large companies but also many solo operations which is where I do want to focus today, especially on 4 “lesser” known issues. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES